Contract UNDPTLS2622022 - Central Hill - For Countersignature

DocuSign Envelope ID: 650EC340-1BD1-40A6-B45E-4658A696D21B
Contract for Civil Works
between
UNDP Timor-Leste
and
CENTRAL HILL UNIPESSOAL LDA for the Renovation works of STAE
Office Building in Baucau, Timor-Leste
Contract Ref. no: UNDP/TLS/RFQ/2022/003
19 August 2022
Rev Nov 2021 1

INT: ___
CONTRACT FOR CIVIL WORKS
Date: 19 August 2022
Contract no.: UNDP/TLS/CW/2022/026
Dear Sir,
The United Nations Development Programme (hereinafter referred to as "UNDP"), wishes to

engage, CENTRAL HILL UNIPESSOAL LDA duly incorporated under the Laws of Timor
Leste (hereinafter referred to as the "Contractor") in order to perform: Renovation works of STAE
Office Building in Baucau, Timor-Leste (hereinafter referred to as the "Works"), in accordance
with the following Contract:
1.Contract Documents
1.1 This Contract is subject to the UNDP General Conditions for Civil Works, (Revised Oct
2000), attached hereto as Annex I. The provisions of such Annex shall control the
interpretation of this Contract and in no way shall be deemed to have been derogated by the
contents of this letter and any other Annexes, unless otherwise expressly stated under section
4 of this letter, entitled "Special Conditions".
1.2 The Contractor and UNDP also agree to be bound by the provisions contained in the
following documents, which shall take precedence over one another in case of conflict in the
following order:
a) this letter;
b) General Conditions of Contract for Civil Works attached hereto as Annex I;
c) Technical Specifications, Terms of Reference, Drawings and Bill of Quantity attached
hereto as Annex II;
d) Contractor's proposal documentation dated 20 June 2022- not attached here but in
possession of both parties;
e) UNDP/TLS/RFQ/2022/003 - not attached here but in possession of both parties;
1.3 All the above shall form the Contract between the Contractor and UNDP, superseding the
contents of any other negotiations and/or agreements, whether oral or in writing, pertaining
to the subject of this Contract.
Rev Nov 2021 2

INT: ___
2. Obligations of the Contractor
2.1 The Contractor shall commence work within 3 (three) days from the date on which he shall
have been given access to the Site and received the notice to commence from the Engineer,
and shall perform and substantially complete the Works by 22 December 2022 in accordance
with the Contract. The Contractor shall provide all materials, supplies, labour and other
services necessary to that end.
2.2 The Contractor shall submit to the Engineer the Programme of Work referred to in Clause
13 of the General Conditions by 24 August 2022.
2.3 The Contractor represents and warrants the accuracy of any information or data provided to
UNDP for the purpose of entering into this Contract, as well as the quality of the Works
foreseen under this Contract in accordance with the highest industrial and professional
standards.
3. Price and Payment
3.1 In full consideration of the complete and satisfactory performance of the Works under this
Contract, UNDP shall pay the Contractor a fixed contract price of US $16,160.60 (Sixteen
Thousand One Hundred Sixty United States Dollar point Sixty cents Only).
3.2 The price of this Contract is not subject to any adjustment or revision because of price or
currency fluctuations, or the actual costs incurred by the Contractor in the performance of
the Contract.
3.3 Invoices shall be submitted by the Contractor to the Engineer upon achievement of the
corresponding milestones and for the following amounts:
No. % of Target % Amount

Deliverable/Output
Progress Due Date Disbursement
Installment 1:
 Site mobilization done
 CGI roof and ridge has been changed
 Ceiling has been changed
 Masonry work completed 65% 8,080.00
1
 Ramp construction completed
55 days 50%
 Construction of water reservoir is
completed.
 Construction of water tower completed.
 Civil work for hand washing station
completed.
Installment 2: 6,464.00
2  CGI roof and ridge painting completed 55 days 40%
 Ceiling painting completed 100%
Rev Nov 2021 3

INT: ___
 Painting of masonry work completed

 Railing work of ramp completed
 Painting, pipe work and water tank
supplying work for water tower is
completed
 Piping work for hand washing station
completed.
 All the work as mentioned in the BoQ
and/or modified by the Engineer-In-
Charge is completed.
 All the electrical work is completed
 All the work assigned newly is
completed
 Final version of BoQ submitted to UNDP
for final invoice
 Signing off the project and the project is
accepted by UNDP and CNE/STAE
management
3 Installment 3: DLP 12 10% 1,616.60
 End of Defect Liability Period (Twelve Monitoring Months
Months after Substantial Completion)
Total = 100% US $16,160.60
3.4 UNDP shall effect payment of the invoices after receipt of the certificate of payment issued
by the Engineer, approving the amount contained in the invoice. The Engineer may make
corrections to that amount, in which case UNDP may effect payment for the amount so
corrected. The Engineer may also withhold invoices if the work is not performed at any time
in accordance with the terms of the Contract or if the necessary insurance policies or
performance security are not valid and/or in order. The Engineer shall process the invoices
submitted by the Contractor within 15 days of their receipt.
3.5 Payments effected by UNDP to the Contractor shall be deemed neither to relieve the
Contractor of its obligations under this Contract nor as acceptance by UNDP of the
Contractor's performance of the Works.
3.6 Payment of the final invoice shall be effected by UNDP after issuance of the Certificate of
Final Completion by the Engineer.
4. Special conditions
4.1 According to Clause 45 of the General Conditions, the liquidated damages for delay shall be
0.33% of the price of the Contract per day of delay, up to a maximum of 10% of the final
price of the Contract.
5. Submission of invoices
Rev Nov 2021 4

INT: ___
5.1 One original and one copy of every Certificate of Completion and Invoice shall be submitted
by hand or mail by the Contractor for each payment under the Contract to the Engineer's
address specified in clause 8.2.
5.2 Invoices and Certificates of Completion submitted by fax shall not be accepted by UNDP.
6. Time and manner of payment
6.1 Invoices shall be paid within thirty (30) days of the date of their receipt and acceptance by
UNDP.
6.2 All payments shall be made by UNDP to the following Bank account of the Contractor:
NAME OF THE BANK: BANK MANDIRI DILI
ACCOUNT NUMBER: 601-00-0047364-8
BANK ADDRESS: Dili, Timor-Leste
7. Modifications
7.1 Any modification to this Contract shall require an amendment in writing between both parties
duly signed by the authorized representatives of the Contractor and UNDP.
8. Notifications
8.1 For the purpose of notifications under the Contract, the addresses of UNDP and the
Contractor are as follows:
For the UNDP:
Name: Tito De Jesus Filipe Da Costa

Title: Project Manager
Address: UN House Obrigado Barracks, Caicoli, Dili, Timor-Leste
Telephone number: +670 7726 9279

Email: [email protected]
Ref. UNDP/ TLS/CW/2022/026
Rev Nov 2021 5

INT: ___
For the Contractor:
Name: Aderito da Costa Correia

Title: Director
Address: Rua; Tirilolo, Baucau, Timor Leste
Telephone number: +670 77256112

8.2 For the purposes of communications with the Engineer, the address of the Engineer shall be
as follows:
Name: Reinaldo Soares Da Costa

Title: National Engineer (Civil Engineer)
Address: UN House Obrigado Barracks, Caicoli Dili
Telephone number: +670 77407070

If the above terms and conditions meet with your agreement as typed in this letter and in the Contract
Documents, please initial every page of this letter and its attachments and return to this office one
original of this Contract, duly signed and dated.
Yours sincerely,
Munkhtuya Altangerel
Resident Representative
UNDP Timor-leste
21-Aug-2022
Signature: _______________________________ Date: ______________________
For: Central Hill Unipessoal Lda
Agreed and Accepted:
Signature ____________________________
Name Aderito da Costa Correia
Title Director
Date ____________________________
Rev Nov 2021 6

INT: ___
ANNEX II
TECHNICAL SPECIFICATIONS AND DRAWINGS (Attached separately)
Rev Nov 2021 7

INT: ___
ANNEX I
UNDP GENERAL CONDITIONS

OF CONTRACT FOR WORKS
General Conditions of Contract for Civil Works
1. Definitions
2. Singular and Plural
3. Headings or Notes
4. Legal Relationships
5. General Duties/Powers of Engineer
6. Contractor's General Obligations/Responsibilities
7. Assignment and Subcontracting
8. Drawings
9. Work Book
10. Performance Security
11. Inspection of Site
12. Sufficiency of Tender
13. Programme of Work to be Furnished
14. Weekly Site Meeting
15. Change Orders
16. Contractor's Superintendence
17. Contractor's Employees
18. Setting-Out
19. Watching and Lighting
20. Care of Works
21. Insurance of Works, Etc.
22. Damage to Persons and Property
23. Liability Insurance
24. Accident or Injury to Workmen
25. Remedy on Contractor's Failure to Insure
26. Compliance with Statutes, Regulations, Etc.
27. Fossils, Etc.
28. Copyright, Patents and Other Proprietary Rights, and Royalties
29. Interference With Traffic and Adjoining Properties
Rev Nov 2021 8

INT: ___
30. Extraordinary Traffic and Special Loads

31. Opportunities for Other Contractors
32. Contractor to Keep Site Clean
33. Clearance of Site on Substantial Completion
34. Labour
35. Returns of Labour, Plant, Etc.
36. Materials, Workmanship and Testing
37. Access to Site
38. Examination of Work Before Covering Up
39. Removal of Improper Work and Materials
40. Suspension of Work
41. Possession of Site
42. Time for Completion
43. Extension of Time for Completion
44. Rate of Progress
45. Liquidated Damages for Delay
46. Certificate of Substantial Completion
47. Defects Liability
48. Alterations, Additions and Omissions
49. Plant, Temporary Works and Materials
50. Approval of Materials, Etc., Not Implied
51. Measurement of Works
52. Liability of the Parties
53. Authorities
54. Urgent Repairs
55. Increase and Decrease of Costs
56. Taxation
57. Blasting
58. Machinery
59. Temporary Works and Reinstatement
60. Photographs and Advertising
61. Prevention of Corruption
62. Date Falling on Holiday
63. Notices
64. Language, Weights and Measures
65. Records, Accounts, Information and Audit
66. Force Majeure
67. Suspension by the UNDP
68. Termination by the UNDP
69. Termination by the Contractor
70. Rights and Remedies of the UNDP
71. Settlement of Disputes
72. Privileges and Immunities
Appendix I: Formats of Performance Security

Performance Bank Guarantee
Rev Nov 2021 9

INT: ___
Performance Bond
1. DEFINITIONS
For the purpose of the Contract Documents the words and expressions below shall have the
following meanings:
a) "Employer" means the United Nations Development Programme (UNDP).
b) "Contractor" means the person whose tender has been accepted and with whom the Contract
has been entered into.
c) "Engineer" means the person whose services have been engaged by UNDP to administer the
Contract as provided therein, as will be notified in writing to the Contractor.
d) "Contract" means the written agreement between the Employer and the Contractor, to which
these General Conditions are annexed.
e) "The Works" means the works to be executed and completed under the Contract.
f) "Temporary Works" shall include items to be constructed which are not intended to be
permanent and form part of the Works.
g) "Drawings" and "Specifications" mean the Drawings and Specifications referred to in the
Contract and any modification thereof or addition thereto furnished by the Engineer or
submitted by the Contractor and approved in writing by the Engineer in accordance with the
Contract.
h) "Bill of Quantities" is the document in which the Contractor indicates the cost of the Works,
on the basis of the foreseen quantities of items of work and the fixed unit prices applicable to
them.
i) "Contract Price" means the sum agreed in the Contract as payable to the Contractor for the
execution and completion of the Works and for remedying of any defects therein in
accordance with the Contract.
j) "Site" means the land and other places on, under, in or through which the Works or
Temporary Works are to be constructed.
2. SINGULAR AND PLURAL
Words importing persons or parties shall include firms or companies and words importing
the singular only shall also include the plural and vice versa where the context requires.
Rev Nov 2021 10

INT: ___
3. HEADINGS OR NOTES
The headings or notes in the Contract Documents shall not be deemed to be part thereof or be
taken into consideration in their interpretation.
4. LEGAL RELATIONSHIPS
The Contractor and the sub-contractor(s), if any, shall have the status of an independent
contractor vis-à-vis the Employer. The Contract Documents shall not be construed to create
any contractual relationship of any kind between the Engineer and the Contractor, but the
Engineer shall, in the exercise of his duties and powers under the Contract, be entitled to
performance by the Contractor of its obligations, and to enforcement thereof. Nothing
contained in the Contract Documents shall create any contractual relationship between the
Employer or the Engineer and any subcontractor(s) of the Contractor.
5. GENERAL DUTIES/POWERS OF ENGINEER
a) The Engineer shall provide administration of Contract as provided in the Contract

Documents. In particular, he shall perform the functions hereinafter described.
b) The Engineer shall be the Employer's representative vis-à-vis the Contractor during
construction and until final payment is due. The Engineer shall advise and consult with the
Employer. The Employer's instructions to the Contractor shall be forwarded through the
Engineer. The Engineer shall have authority to act on behalf of the Employer only to the
extent provided in the Contract Documents as they may be amended in writing in accordance
with the Contract. The duties, responsibilities and limitations of authority of the Engineer as
the Employer's representative during construction as set forth in the Contract shall not be
modified or extended without the written consent of the Employer, the Contractor and the
Engineer.
c) The Engineer shall visit the Site at intervals appropriate to the stage of construction to
familiarize himself generally with the progress and quality of the Works and to determine in
general if the Works are proceeding in accordance with the Contract Documents. On the
basis of his on-site observations as an Engineer, he shall keep the Employer informed of the
progress of the Works.
d) The Engineer shall not be responsible for and will not have control or charge of construction
means, methods, techniques, sequences or procedures, or for safety precautions and programs
in connection with the Works or the Temporary Works. The Engineer shall not be
responsible for or have control or charge over the acts or omissions of the Contractor
(including the Contractor's failure to carry out the Works in accordance with the Contract)
and of Sub-contractors or any of their agents or employees, or any other persons performing
services for the Works, except if such acts or omissions are caused by the Engineer's failure
to perform his functions in accordance with the contract between the Employer and the
Engineer.
Rev Nov 2021 11

INT: ___
e) The Engineer shall at all times have access to the Works wherever and whether in
preparation or progress. The Contractor shall provide facilities for such access so that the
Engineer may perform his functions under the Contract.
f) Based on the Engineer's observations and an evaluation of the documentation submitted by

the Contractor together with the invoices, the Engineer shall determine the amounts owed to
the Contractor and shall issue Certificates for Payment as appropriate.
g) The Engineer shall review and approve or take other appropriate action upon the Contractor's
submittals such as Shop Drawings, Product Data and Samples, but only for conformity with
the design concept of the Works and with the provisions of the Contract Documents. Such
action shall be taken with reasonable promptness so as to cause no delay. The Engineer's
approval of a specific item shall not indicate approval of an assembly of which the item is a
component.
h) The Engineer shall interpret the requirements of the Contract Documents and judge the
performance thereunder by the Contractor. All interpretations and orders of the Engineer
shall be consistent with the intent of and reasonably inferable from the Contract Documents
and shall be in writing or in the form of drawings. Either party may make a written request
to the Engineer for such interpretation. The Engineer shall render the interpretation
necessary for the proper execution of the Works with reasonable promptness and in
accordance with any time limit agreed upon. Any claim or dispute arising from the
interpretation of the Contract Documents by the Engineer or relating to the execution or
progress of the Works shall be settled as provided in Clause 71 of these General Conditions.
i) Except as otherwise provided in the Contract, the Engineer shall have no authority to relieve
the Contractor of any of his obligations under the Contract nor to order any work involving
delay in completion of the Works or any extra payment to the Contractor by the Employer, or
to make any variations to the Works.
j) In the event of termination of the employment of the Engineer, the Employer shall appoint
another suitable professional to perform the Engineer's duties.
k) The Engineer shall have authority to reject work which does not conform to the Contract
Documents. Whenever, in his opinion, he considers it necessary or advisable for the
implementation of the intent of the Contract Documents, he will have authority to require
special inspection or testing of the work whether or not such work be then fabricated,
installed or completed. However, neither the Engineer's authority to act nor any reasonable
decision made by him in good faith either to exercise or not to exercise such authority shall
give rise to any duty or responsibility of the Engineer to the Contractor, any subcontractor,
any of their agents or employees, or any other person performing services for the Works.
l) The Engineer shall conduct inspections to determine the dates of Substantial Completion and
Final Completion, shall receive and forward to the Employer for the Employer's review
written warranties and related documents required by the Contract and assembled by the
Rev Nov 2021 12

INT: ___
Contractor, and shall issue a final Certificate for Payment upon compliance with the
requirements of Clause 47 hereof and in accordance with the Contract.
m) If the Employer and Engineer so agree, the Engineer shall provide one or more Engineer's
Representative(s) to assist the Engineer in carrying out his responsibilities at the site. The
Engineer shall notify in writing to the Contractor and the Employer the duties,
responsibilities and limitations of authority of any such Engineer's Representative(s).
6. CONTRACTOR'S GENERAL OBLIGATIONS/RESPONSIBILITIES
6.1.Obligation to Perform in Accordance with Contract
The Contractor shall execute and complete the Works and remedy any defects therein in
strict accordance with the Contract, with due care and diligence and to the satisfaction of the
Engineer, and shall provide all labor, including the supervision thereof, materials,
Constructional Plant and all other things, whether of a temporary or permanent nature,
required in and for such execution, completion and remedying of defects, as far as the
necessity for providing the same is specified in or is reasonably to be inferred from the
Contract. The Contractor shall comply with and adhere strictly to the Engineer's instructions
and directions on any matter, touching or concerning the Works.
6.2 Responsibility for Site Operations
The Contractor shall take full responsibility for the adequacy, stability and safety of all site
operations and methods of construction, provided that the Contractor shall not be responsible,
except as may be expressly provided in the Contract, for the design or specification of the
Permanent Works or of any Temporary Works prepared by the Engineer.
6.3.Responsibility for Employees
The Contractor shall be responsible for the professional and technical competence of his
employees and will select for work under this Contract, reliable individuals who will perform
effectively in the implementation of the Contract, respect local customs and conform to a
high standard of moral and ethical conduct.
6.4.Source of Instructions
The Contractor shall neither seek nor accept instructions from any authority external to the
Employer, the Engineer or their authorized representatives in connection with the
performance of his services under this Contract. The Contractor shall refrain from any action
which may adversely affect the Employer and shall fulfill his commitments with fullest
regard for the interest of the Employer.
6.5.Officials Not to Benefit
Rev Nov 2021 13

INT: ___
The Contractor warrants that no official of the Employer has been or shall be admitted by the
Contractor to any direct or indirect benefit arising from this Contract or the award thereof.
The Contractor agrees that breach of this provision is a breach of an essential term of the
Contract.
6.6.Use of Name, Emblem or Official Seal of UNDP or the United Nations
The Contractor shall not advertise or otherwise make public the fact that he is performing, or
has performed services for the Employer or use the name, emblem or official seal of the
Employer or the United Nations or any abbreviation of the name of the Employer or the
United Nations for advertising purposes or any other purposes.
6.7.Confidential Nature of Documents
All maps, drawings, photographs, mosaics, plans, reports, recommendations, estimates,

documents and all other data compiled by or received by the Contractor under the Contract
shall be the property of the Employer, shall be treated as confidential and shall be delivered
only to the duly authorized representative of the Employer on completion of the Works; their
contents shall not be made known by the Contractor to any person other than the personnel of
the Contractor performing services under this Contract without the prior written consent of
the Employer.
7. ASSIGNMENT AND SUBCONTRACTING
7.1.Assignment of Contract
The Contractor shall not, except after obtaining the prior written approval of the Employer,
assign, transfer, pledge or make other disposition of the Contract or any part thereof or of any
of the Contractor's rights, claims or obligations under the Contract.
7.2.Subcontracting
In the event the Contractor requires the services of subcontractors, the Contractor shall obtain
the prior written approval of the Employer for all such subcontractors. The approval of the
Employer shall not relieve the Contractor of any of his obligations under the Contract, and
the terms of any subcontract shall be subject to
and be in conformity with the provisions of the Contract.
7.3.Assignment of Subcontractor's Obligations
In the event of a subcontractor having undertaken towards the Contractor in respect of the
work executed or the goods, materials, Plant or services supplied by such subcontractor for
the Works, any continuing obligation extending for a period exceeding that of the Defects
Liability Period under the Contract, the Contractor
shall at any time after the expiration of such Period, assign to the Employer, at the
Employer's request and cost, the benefit of such obligation for the unexpired duration thereof.
Rev Nov 2021 14

INT: ___
8. DRAWINGS
8.1.Custody of drawings
The drawings shall remain in the sole custody of the Employer but two (2) copies thereof
shall be furnished to the Contractor free of cost. The Contractor shall provide and make at
his own expense any further copies required by him. At the completion of the Works, the
Contractor shall return to the Employer all drawings provided under the Contract.
8.2.One copy of Drawings to be kept on Site
One copy of the Drawings furnished to the Contractor as aforesaid shall be kept by the
Contractor on the Site and the same shall at all reasonable times be available for inspection
and use by the Engineer and by any other person authorized in writing by the Engineer.
8.3.Disruption of Progress
The Contractor shall give written notice to the Engineer whenever planning or progress of the
Works is likely to be delayed or disrupted unless any further drawing or order, including a
direction, instruction or approval, is issued by the Engineer within a reasonable time. The
notice shall include details of drawing or order required and of why and by when it is
required and of any delay or disruption likely to be suffered if it is late.
9. WORK BOOK
The Contractor shall maintain a Work Book at the Site with numbered pages, in one original
and two copies. The Engineer shall have full authority to issue new orders, drawings and
instructions to the Contractor, from time to time and as required for the correct execution of
the Works. The Contractor shall be bound to follow such orders, drawings and instructions.
Every order shall be dated and signed by the Engineer and the Contractor, in order to account
for its receipt.
Should the Contractor want to refuse an order in the Work Book, he shall so inform the
Employer, through the Engineer, by means of an annotation in the Work Book made within
three (3) days from the date of the order that the Contractor intends to refuse. Failure by the
Contractor to adhere to this procedure shall result in the order being deemed accepted with
no further possibility of refusal.
The original of the Work Book shall be delivered to the Employer at the time of Final
Acceptance of the Works. A copy shall be kept by the Engineer and another copy by the
Contractor.
10. PERFORMANCE SECURITY
Rev Nov 2021 15

INT: ___
a) As guarantee for his proper and efficient performance of the Contract, the Contractor shall on
signature of the Contract furnish the Employer with a Performance Security issued for the
benefit of the Employer. The amount and character of such security (bond or guarantee) shall
be as indicated in the Contract.
b) The Performance Bond or Bank Guarantee must be issued by an acceptable insurance

company or accredited bank, in the format included in Appendix I to these General
Conditions, and must be valid up to twenty-eight days after issuance by the Engineer of the
Certificate of Final Completion. The Performance Bond or Bank Guarantee shall be returned
to the Contractor within twenty-eight days after the issuance by the Engineer of the
Certificate of Final Completion, provided that the Contractor shall have paid all money owed
to the Employer under the Contract.
c) If the surety of the Performance Bond or Bank Guarantee is declared bankrupt or becomes
insolvent or its right to do business in the country of execution of the Works is terminated,
the Contractor shall within five (5) days thereafter substitute another bond or guarantee and
surety, both of which must be acceptable to the Employer.
11. INSPECTION OF SITE
The Contractor shall be deemed to have inspected and examined the site and its surroundings
and to have satisfied himself before submitting his Tender and signing the Contract as to all
matters relative to the nature of the land and subsoil, the form and nature of the Site, details
and levels of existing pipe lines, conduits, sewers, drains, cables or other existing services,
the quantities and nature of the work and materials necessary for the completion of the
Works, the means of access to the Site, and the accommodation he may require, and in
general to have himself obtained all necessary information as to risk contingencies, climatic,
hydrological and natural conditions and other circumstances which may influence or affect
his Tender, and no claims will be entertained in this connection against the Employer.
12. SUFFICIENCY OF TENDER
The Contractor shall be deemed to have satisfied himself before tendering as to the
correctness and sufficiency of his Tender for the construction of the Works and of the rates
and prices, which rates and prices shall, except in so far as it is otherwise provided in the
Contract, cover all his obligations under the Contract and all matters and things necessary for
the proper execution and completion of the Works.
13. PROGRAMME OF WORK TO BE FURNISHED
Within the time limit specified in the Contract, the Contractor shall submit to the Engineer
for his consent a detailed Programme of Work showing the order of procedure and the
method in which he proposes to carry out the Works. In preparing his Programme of Work
the Contractor shall pay due regard to the priority required by certain works. Should the
Engineer, during the progress of work, require further modifications to the Programme of
Work, the Contractor shall review the said program. The Contractor shall also whenever
Rev Nov 2021 16

INT: ___
required by the Engineer submit particulars in writing of the Contractor's arrangements for
carrying out the Works and of the Constructional Plant and Temporary Works which the
Contractor intends to supply, use or construct as the case may be. The submission of such
program, or any modifications thereto, or the particulars required by the Engineer, shall not
relieve the Contractor of any of his duties or obligations under the Contract nor shall the
incorporation of any modification to the Programme of Work either at the commencement of
the contract or during its course entitle the Contractor to any additional payments in
consequence thereof.
14. WEEKLY SITE MEETING
A weekly site meeting shall be held between the UNDP Project Coordinator or engineer, if
any, the representative of the Contractor and the Engineer or the Engineer's Representative,
in order to verify that the Works are progressing normally and are executed in accordance
with the Contract.
15. CHANGE ORDERS
a) The Engineer may instruct the Contractor, with the approval of the Employer and by means
of Change Orders, all variations in quantity or quality of the Works, in whole or in part, that
are deemed necessary by the Engineer.
b) Processing of change orders shall be governed by clause 48 of these General Conditions.
16. CONTRACTOR'S SUPERINTENDENCE
The Contractor shall provide all necessary superintendence during the execution of the
Works and as long thereafter as the Engineer may consider necessary for the proper
fulfillment of the Contractor's obligations under the Contract. The Contractor or a competent
and authorized agent or representative of the Contractor approved in writing by the Engineer,
which approval may at any time be withdrawn, shall be constantly on the site and shall
devote his entire time to the superintendence of the Works. Such authorized agent or
representative shall receive on behalf of the Contractor directions and instructions from the
Engineer. If the approval of such agent or representative shall be withdrawn by the Engineer,
as provided in Clause 17(2) hereinafter, or if the removal of such agent or representative shall
be requested by the Employer under Clause 17(3) hereinafter, the Contractor shall as soon as
it is practicable after receiving notice of such withdrawal remove the agent or representative
from the Site, and replace him by another agent or representative approved by the Engineer.
Notwithstanding the provision of Clause 17(2) hereinafter, the Contractor shall not thereafter
employ, in any capacity whatsoever, a removed agent or representative again on the Site.
17. CONTRACTOR'S EMPLOYEES
a) The Contractor shall provide and employ on the Site in connection with the execution and
completion of the Works and the remedying of any defects therein:
Rev Nov 2021 17

INT: ___
i. Only such technical assistants as are skilled and experienced in their respective callings and
such sub-agent foremen and leading hands as are competent to give proper supervision to the
work they are required to supervise, and
ii. Such skilled, semi-skilled, and unskilled labour as is necessary for the proper and timely
execution and completion of the Works.
b) The Engineer shall be at liberty to object to and require the Contractor to remove forthwith
from the Works any person employed by the Contractor in or about the execution or
completion of the Works, who in the opinion of the Engineer is misconducting himself, or is
incompetent or negligent in the proper performance of his duties, or whose employment is
otherwise considered reasonably by the Engineer to be undesirable, and such person shall not
be again employed on the Site without the written permission of the Engineer. Any person
so removed from the Works shall be replaced as soon as reasonably possible by a competent
substitute approved by the Engineer.
c) Upon written request by the Employer, the Contractor shall withdraw or replace from the Site
any agent, representative or other personnel who does not conform to the standards set forth
in paragraph (1) of this Clause. Such request for withdrawal or replacement shall not be
considered as termination in part or in whole of this Contract. All costs and additional
expenses resulting from any withdrawal or replacement for whatever reason of any of the
Contractor's personnel shall be at the Contractor's expense.
18. SETTING-OUT
The Contractor shall be responsible for the true and proper setting out of the Works in
relation to original points, lines and levels of reference given by the Engineer in writing and
for the correctness of the position, levels, dimensions and alignment of all parts of the Works
and for the provision of all necessary instruments, appliances and labor in connection
therewith. If, at any time during the progress of the Works, any error shall appear or arise in
the position, levels, dimensions or alignment of any part of the Works, the Contractor, on
being required so to do by the Engineer, shall, at his own cost, rectify such error to the
satisfaction of the Engineer.
19. WATCHING AND LIGHTING
The Contractor shall in connection with the Works provide and maintain at his own cost all
lights, guards, fencing and watching when and where necessary or required by the Engineer
or by any duly constituted authority for the protection of the Works and the materials and
equipment utilized therefor or for the safety and convenience of the public or others.
20. CARE OF WORKS
a) From the commencement date of the Works to the date of substantial completion as stated in
the Certificate of Substantial Completion, the Contractor shall take full responsibility for the
care thereof and of all Temporary Works. In the event that any damage or loss should happen
Rev Nov 2021 18

INT: ___
to the Works or to any part thereof or to any Temporary Works from any cause whatsoever
(save and except as shall be due to Force Majeure as defined in Clause 66 of these General
Conditions), the Contractor shall at his own cost repair and make good the same so that, at
completion, the Works shall be in good order and condition and in conformity in every
respect with the requirements of the Contract and the Engineer's instructions. The Contractor
shall also be liable for any damage to the Works occasioned by him in the course of any
operations carried out by him for the purpose of complying with his obligations Clause 47
hereof.
b) The Contractor shall be fully responsible for the review of the Engineering design and details
of the Works and shall inform the Employer of any mistakes or incorrectness in such design
and details which would affect the Works.
21. INSURANCE OF WORKS, ETC.
Without limiting his obligations and responsibilities under Clause 20 hereof, the Contractor
shall insure immediately following signature of this Contract, in the joint names of the
Employer and the Contractor (a) for the period stipulated in Clause 20(1) hereof, against all
loss or damage from whatever cause arising, other than cause of Force majeure as defined in
clause 66 of these General Conditions, and (b) against loss or damage for which the
Contractor is responsible, in such manner that the Employer and the Contractor are covered
for the period stipulated in Clause 20 (1) hereof and are also covered during the Defects
Liability Period for loss or damage arising from a cause occurring prior to the
commencement of the Defects Liability Period and for any loss or damage occasioned by the
Contractor in the course of any operations carried out by him for the purpose of complying
with his obligations under Clause 47 hereof:
a) The Works, together with the materials and Plant for incorporation therein, to their full
replacement cost, plus an additional sum of ten (10) per cent of such replacement cost, to
cover any additional costs of and incidental to the rectification of loss or damage including
professional fees and the cost of demolishing and removing any part of the Works and of
removing debris of whatsoever nature;
b) The Contractor's equipment and other things brought on to the Site by the Contractor to the
replacement value of such equipment and other things;
c) An insurance to cover the liabilities and warranties of Section 52(4);
Such insurance shall be effected with an insurer and in terms approved by the Employer,
which approval shall not be unreasonably withheld, and the Contractor shall, whenever
required, produce to the Engineer the policy or policies of insurance and the receipts for
payment of the current premiums.
22. DAMAGE TO PERSONS AND PROPERTY
Rev Nov 2021 19

INT: ___
The Contractor shall (except if and so far as the Contract provides otherwise) indemnify,
hold and save harmless and defend at his own expense the Employer, its officers, agents,
employees and servants from and against all suits, claims, demands, proceedings, and
liability of any nature or kind, including costs and expenses, for injuries or damages to any
person or any property whatsoever which may arise out of or in consequence of acts or
omissions of the Contractor or its agents, employees, servants or subcontractors in the
execution of the Contract. The provision of this Clause shall extend to suits, claims,
demands, proceedings and liability in the nature of workmen's compensation claims and
arising out of the use of patented inventions and devices. Provided always that nothing herein
contained shall be deemed to render the Contractor liable for or in respect of or with respect
to:
a) The permanent use or occupation of land by the Works or any part thereof;
b) The right of the Employer to construct the Works or any part thereof on, over, under, or
through any land.
c) Interference whether temporary or permanent with any right of light, airway or water or other
easement or quasi-easement which is the unavoidable result of the construction of the Works
in accordance with the Contract.
d) Death, injuries or damage to persons or property resulting from any act or neglect of the
Employer, his agents, servants or other contractors, done or committed during the validity of
the Contract.
23. LIABILITY INSURANCE
23.1. Obligation to take out Liability Insurance
Before commencing the execution of the Works, but without limiting his obligations and
responsibility under Clause 20 hereof, the Contractor shall insure against his liability for any
death, material or physical damage, loss or injury which may occur to any property,
including that of the Employer or to any person, including any employee of the Employer by
or arising out of the execution of the Works or in the carrying out of the Contract, other than
due to the matters referred to in the proviso to Clause 22 hereof.
23.2. Minimum Amount of Liability Insurance
Such insurance shall be effected with an insurer and in terms approved by the Employer,
which approval shall not be unreasonably withheld, and for at least the amount specified in
the contract. The Contractor shall, whenever required by the Employer or the Engineer,
produce to the Engineer the policy or policies of insurance and the receipts for payment of
the current premiums.
23.3. Provision to Indemnify Employer
Rev Nov 2021 20

INT: ___
The insurance policy shall include a provision whereby, in the event of any claim in respect
of which the Contractor would be entitled to receive indemnity under the policy, being
brought or made against the Employer, the insurer shall indemnify the Employer against such
claims and any costs, charges and expenses in respect thereof.
24. ACCIDENT OR INJURY TO WORKMEN
a) The Employer shall not be liable for or in respect of any damages or compensation payable at
law in respect or in consequence of any accident or injury to any workman or other person in
the employment of the Contractor or any sub-Contractor, save and except an accident or
injury resulting from any act or default of the Employer, his agents or servants. The
Contractor shall indemnify, hold and save harmless the Employer against all such damages
and compensation, save and except as aforesaid, and against all claims, proceedings, costs,
charges and expenses whatsoever in respect thereof or in relation thereto.
b) Insurance Against Accident, etc., to Workmen
The Contractor shall insure against such liability with an insurer approved by the Employer,
which approval shall not be unreasonably withheld, and shall continue such insurance during
the whole of the time that any persons are employed by him for the Works and shall, when
required, produce to the Engineer such policy of insurance and the receipt for payment of the
current premium. Provided always that, in respect of any persons employed by any
subcontractor, the Contractor's obligation to insure as aforesaid under this sub-clause shall be
satisfied if the subcontractor shall have insured against the liability in respect of such persons
in such manner that the Employer is indemnified under the policy but the Contractor shall
require such subcontractor to produce to the Engineer when required such policy of insurance
and the receipt for the current premium, and obtain the insertion of a provision to that effect
in its contract with the subcontractor.
25. REMEDY ON CONTRACTOR'S FAILURE TO INSURE
If the Contractor shall fail to effect and keep in force any of the insurances referred to in
Clauses 21, 23 and 24 hereof, or any other insurance which he may be required to effect
under the terms of the Contract, the Employer may in any such case effect and keep in force
any such insurance and pay such premium as may be necessary for that purpose and from
time to time deduct the amount so paid by the Employer as aforesaid from any monies due or
which may become due to the Contractor, or recover the same as a debt due from the
Contractor.
26. COMPLIANCE WITH STATUTES, REGULATIONS, ETC.
a) The Contractor shall give all notices and pay all fees and charges required to be given or paid
by any national or State Statutes, Ordinances, Laws, Regulations or By-laws, or any local or
other duly constituted authority in relation to the execution of the Works or of any
Temporary Works and by the Rules and Regulations of all public bodies and companies
Rev Nov 2021 21

INT: ___
whose property or rights are affected or may be affected in any way by the Works or any
Temporary Works.
b) The Contractor shall conform in all respects with any such Statutes, Ordinances, Laws,
Regulations, By-laws or requirements of any such local or other authority which may be
applicable to the Works and shall keep the Employer indemnified against all penalties and
liabilities of every kind for breach of any such Statutes, Ordinances, Laws, Regulations, By-
laws or requirements.
27. FOSSILS, ETC.
All fossils, coins, articles of value or antiquity and structures and other remains or things of
geological or archaeological interest discovered on the Site of the Works shall as between the
Employer and the Contractor be deemed to be the absolute property of the Employer and the
Contractor shall take reasonable precautions to
prevent his workmen or any other persons from removing or damaging any such article or
thing and shall immediately upon discovery thereof and before removal acquaint the
Employer of such discovery and carry out at the expense of the Employer the Engineer's
orders as to the disposal of the same.
28. COPYRIGHT, PATENT AND OTHER PROPRIETARY RIGHTS, AND

ROYALTIES
a) The Contractor shall hold harmless and fully indemnify the Employer from and against all
claims and proceedings for or on account of infringement of any patent rights, design
trademark or name or other protected rights in respect of any Plant, equipment, machine,
work or material used for or in connection with the Works or Temporary Works and from
and against all claims, demands proceedings, damages, costs, charges and expenses
whatsoever in respect thereof or in relation thereto, except where such infringement results
from compliance with the design or Specification provided by the Engineer.
b) Except where otherwise specified, the Contractor shall pay all tonnage and other royalties,
rent and other payments or compensation, if any, for getting stone, sand, gravel, clay or other
materials required for the Works or Temporary Works.
29. INTERFERENCE WITH TRAFFIC AND ADJOINING PROPERTIES
All operations necessary for the execution of the Works and for the Construction of any
Temporary Works shall, so far as compliance with the requirements of the Contract permits,
be carried on so as not to interfere unnecessarily or improperly with the public convenience,
or the access to, use and occupation of, public or private roads and footpaths to or of
properties whether in the possession of the Employer or of any other person. The Contractor
shall hold harmless and indemnify the Employer in respect of all claims, demands,
proceedings, damages, costs, charges and expenses whatsoever arising out of or in relation to
any such matters in so far as the Contractor is responsible therefor.
Rev Nov 2021 22

INT: ___
30. EXTRAORDINARY TRAFFIC AND SPECIAL LOADS
a) The Contractor shall use every reasonable means to prevent any of the roads or bridges
communicating with or on the routes to the Site from being damaged by any traffic of the
Contractor or any of his sub-contractors and, in particular, shall select routes, choose and use
vehicles and restrict and distribute loads so that any such extraordinary traffic as will
inevitably arise from the moving of plant and material from and to the Site shall be limited as
far as reasonably possible and so that no unnecessary damage may be occasioned to such
roads and bridges.
b) Should it be found necessary for the Contractor to move any load of Constructional Plant,
machinery, preconstructed units or parts of units of work, or other thing, over part of a road
or bridge, the moving whereof is likely to damage any such road or bridge unless special
protection or strengthening is carried out, then the Contractor shall before moving the load on
to such road or bridge, save insofar as the Contract otherwise provide, be responsible for and
shall pay for the cost of strengthening any such bridge or altering or improving any such road
to avoid such damage, and the Contractor shall indemnify and keep the Employer
indemnified against all claims for damage to any such road or bridge caused by such
movement, including such claim as may be made directly against the Employer, and shall
negotiate and pay all claims arising solely out of such damage.
31. OPPORTUNITIES FOR OTHER CONTRACTORS
The Contractor shall in accordance with the requirements of the Engineer afford all
reasonable opportunities for carrying out their work to any other contractors employed by the
Employer and their workmen and to the workmen of the Employer and of any other duly
constituted authorities who may be employed in the execution on or near the Site of any work
not included in the Contract or of any contract which the Employer may enter into in
connection with or ancillary to the Works. If work by other contractors of the Employer as
above-mentioned involves the Contractor in any direct expenses as a result of using his Site
facilities, the Employer shall consider payment to the Contractor of such sum or sums as may
be recommended by the Engineer.
32. CONTRACTOR TO KEEP SITE CLEAN
During the progress of the Works, the Contractor shall keep the Site reasonably free from all
unnecessary obstruction and shall store or dispose of any Constructional Plant and surplus
materials and clear away and remove from the Site any wreckage, rubbish or Temporary
Works no longer required.
33. CLEARANCE OF SITE ON SUBSTANTIAL COMPLETION
On the substantial completion of the Works, the Contractor shall clear away and remove
from the Site all Constructional Plant surplus materials, rubbish and Temporary Works of
every kind and leave the whole of the Site and Works clean and in a workmanlike condition
to the satisfaction of the Engineer.
Rev Nov 2021 23

INT: ___
34. LABOUR
34.1 Engagement of Labour
The Contractor shall make his own arrangements for the engagement of all labour local or
otherwise.
34.2 Supply of Water
The Contractor shall provide on the Site to the satisfaction of the Engineer an adequate
supply of drinking and other water for the use of the Contractor's staff and work people.
34.3 Alcoholic Drinks or Drugs
The Contractor shall comply with Government laws and regulations and orders in force as
regards the import, sale, barter or disposal of alcoholic drinks or narcotics and he shall not
allow or facilitate such importation, sale, gift, barter or disposal by his sub-contractors,
agents or employees.
34.4 Arms and Ammunition
The restrictions specified in clause 34.3 above shall include all kinds of arms and
ammunition.
34.5 Holiday and Religious Customs
The Contractor shall in all dealings with labour in his employ have due regard to all holiday,
recognized festivals and religious or other customs.
34.6 Epidemics
In the event of any outbreak of illness of an epidemic nature the Contractor shall comply with
and carry out such regulations, orders, and requirements as may be made by the Government
or the local medical or sanitary authorities for the purpose of dealing with and overcoming
the same.
34.7 Disorderly Conduct, etc.
The Contractor shall at all times take all reasonable precautions to prevent any unlawful
riotous or disorderly conduct by or amongst his employees and for the preservation of peace
and the protection of persons and property in the neighborhood of the Works against the
same.
34.8 Observance by Sub-Contractors
Rev Nov 2021 24

INT: ___
The Contractor shall be considered responsible for the observance of the above provisions by
his Sub-Contractors.
34.9 Legislation applicable to Labour
The Contractor shall abide by all applicable legislation and regulation with regard to labour.
35 RETURNS OF LABOUR, PLANT, ETC.
The Contractor shall, if required by the Engineer, deliver to the Engineer at his office, a
return in detail in the form and at such intervals as the Engineer may prescribe showing the
supervisory staff and the numbers of the several classes of labour from time to time
employed by the Contractor on the Site and such information respecting Constructional plant
as the Engineer may require.
36 MATERIALS, WORKMANSHIP AND TESTING
36.1 Materials and Workmanship
a) All materials and workmanship shall be of the respective kinds described in the Contract and
in accordance with the Engineer's instructions and shall be subjected from time to time to
such tests as the Engineer may direct at the place of manufacture or fabrication, or on the Site
or at all or any of such places. The Contractor shall provide such assistance, instruments,
machines, labour and materials as are normally required for examining, measuring and
testing any work and the quality, weight or quantity of any materials used and shall supply
samples of materials before incorporation in the Works for testing as may be selected and
required by the Engineer. All testing equipment and instruments provided by the Contractor
shall be used only by the Engineer or by the Contractor in accordance with the instructions of
the Engineer.
b) No material not conforming with the Specifications in the Contract may be used for the
Works without prior written approval of the Employer and instruction of the Engineer,
provided always that if the use of such material results or may result in increasing the
Contract Price, the procedure in Clause 48 shall apply.
36.2 Cost of Samples
All samples shall be supplied by the Contractor at his own cost unless the supply thereof is
clearly intended in the Specifications or Bill of Quantities to be at the cost of the Employer.
Payment will not be made for samples which do not comply with the Specifications.
36.3 Cost of Tests
The Contractor shall bear the costs of any of the following tests:
a) Those clearly intended by or provided for in the Contract Documents.
Rev Nov 2021 25

INT: ___
b) Those involving load testing or tests to ensure that the design of the whole of the Works or
any part of the Works is appropriate for the purpose which it was intended to fulfill.
37 ACCESS TO SITE
The Employer and the Engineer and any persons authorized by either of them shall, at all
times, have access to the Works and to the Site and to all workshops and places where work
is being prepared or whence materials, manufactured articles or machinery are being
obtained for the Works and the Contractor shall afford every facility for and every assistance
in or in obtaining the right to such access.
38 EXAMINATION OF WORK BEFORE COVERING UP
No work shall be covered up or put out of view without the approval of the Engineer and the
Contractor shall afford full opportunity for the Engineer to examine and measure any work
which is about to be covered up or put out of view and to examine foundations before
permanent work is placed thereon. The Contractor shall give due notice to the Engineer
whenever any such work or foundations is or are ready or about to be ready for examination
and the Engineer shall without unreasonable delay unless he considers it unnecessary and
advises the Contractor accordingly attend for the purpose of examining and measuring such
work or of examining such foundations.
39 REMOVAL OF IMPROPER WORK AND MATERIALS
39.1 Engineer's power to order removal
The Engineer shall during the progress of the Works have power to order in writing from
time to time, and the Contractor shall execute at his cost and expense, the following
operations:
a) The removal from the Site within such time or times as may be specified in the order of any
materials which in the opinion of the Engineer are not in accordance with the Contract;
b) The substitution of proper and suitable materials; and
c) The removal and proper re-execution (notwithstanding any previous test thereof or interim
payment therefore) of any work which in respect of materials or workmanship is not in the
opinion of the Engineer in accordance with the Contract.
39.2 Default of Contractor in carrying out Engineer's Instructions
In case of default on the part of the Contractor in carrying out an instruction of the Engineer,
the Employer shall be entitled to employ and pay other persons to carry out the same and all
expenses consequent thereon or incidental thereto shall be borne by the Contractor and shall
Rev Nov 2021 26

INT: ___
be recoverable from him by the Employer and may be deducted by the Employer from any
monies due or which may become due to the Contractor.
40 SUSPENSION OF WORK
The Contractor shall on the written order of the Engineer suspend the progress of the Works
or any part thereof for such time or times and in such manner as the Engineer may consider
necessary and shall, during such suspension, properly protect and secure the Works so far as
it is necessary in the opinion of the Engineer. The Employer should be notified and his
written approval should be sought for any suspension of work in excess of three (3) days.
41 POSSESSION OF SITE
41.1 Access to Site
The Employer shall with the Engineer's written order to commence the Works, give to the
Contractor possession of so much of the Site as may be required to enable the Contractor to
commence and proceed with the construction of the Works in accordance with the
Programme referred to in Clause 13 hereof and otherwise in accordance with such reasonable
proposals of the Contractor as he shall make to the Engineer by notice in writing, and shall
from time to time as the Works proceed give to the Contractor possession of such further
portions of the Site as may be required to enable the Contractor to proceed with the
construction of the Works with due dispatch in accordance with the said Programme or
proposals, as the case may be.
41.2 Wayleaves, etc.
The Contractor shall bear all expenses and charges for special temporary wayleaves required
by him in connection with access to the Site. The Contractor shall also provide at his own
cost any additional accommodation outside the Site required by him for the purpose of the
Works.
41.3 Limits of the Site
Except as defined below, the limits of the Site shall be as defined in the Contract. Should the
Contractor require land beyond the Site, he shall provide it entirely at his own expense and
before taking possession shall supply the Engineer with a copy of the necessary permits.
Access to the Site is available where the Site adjoins a public road but it is not provided
unless shown on the Drawings. When necessary for the safety and convenience of workmen,
public or livestock or for the protection of the Works, the Contractor shall, at his own
expense, provide adequate temporary fencing to the whole or part of the Site. The Contractor
shall not disturb, damage or pull down any hedge, tree or building within the Site without the
written consent of the Engineer.
42 TIME FOR COMPLETION
Rev Nov 2021 27

INT: ___
a) Subject to any requirement in the Contract as to completion of any section of the Works
before completion of the whole, the whole of the Works shall be completed, in accordance
with the provisions of Clause 46 and 47 hereof, within the time stated in the Contract.
b) The completion time includes weekly rest days, official holidays, and days of inclement
weather.
43 EXTENSION OF TIME FOR COMPLETION
If, subject to the provisions of the Contract, the Engineer orders alterations or additions in the
Works in accordance with Clause 48 hereof, or if circumstances constituting force majeure as
defined in the Contract have occurred, the Contractor shall be entitled to apply for an
extension of the time for completion of the Works specified in the Contract. The Employer
shall, upon such application, determine the period of any such extension of time; provided
that in the case of alterations or additions in the Works, the application for such an extension
must be made before the alterations or additions in the Works are undertaken by the
Contractor.
44 RATE OF PROGRESS
The whole of the materials, plant and labour to be provided by the Contractor and the mode,
manner and speed of execution and completion of the Works are to be of a kind and
conducted in a manner to the satisfaction of the Engineer. Should the rate of progress of the
Works or any part thereof be at any time in the opinion of the
Engineer too slow to ensure the completion of the Works by the prescribed time or extended
time for completion, the Engineer shall so notify the Contractor in writing and the Contractor
shall thereupon take such steps as the Contractor may think necessary and the Engineer may
approve to expedite progress so as to complete the Works by the prescribed time or extended
time for completion. If the work is not being carried on by day and by night and the
Contractor shall request permission to work by night as well as by day, then, if the Engineer
shall grant such permission, the Contractor shall not be entitled to any additional payment.
All work at night shall be carried out without unreasonable noise and disturbance. The
contractor shall indemnify the Employer from and against any claims or liability for damages
on account of noise or other disturbance created while or in carrying out the work and from
and against all claims, demands, proceedings, costs and expenses whatsoever in regard or in
relation to such noise or other disturbance. The Contractor shall submit in triplicate to the
Engineer at the end of each month signed copies of explanatory Drawings or any other
material showing the progress of the Works.
45 LIQUIDATED DAMAGES FOR DELAY
a) If the Contractor shall fail to complete the Works within the time for completion prescribed
in the Contract, or any extended time for completion in accordance with the Contract, then
the Contractor shall pay to the Employer the sum specified in the Contract as liquidated
damages, for the delay between the time prescribed in the Contract or the extended time for
completion, as the case may be, and the date of substantial completion of the Works as stated
Rev Nov 2021 28

INT: ___
in the Certificate of Substantial Completion, subject to the applicable limit stated in the
Contract. The said sum shall be payable by the sole fact of the delay without the need for any
previous notice or any legal proceedings, or proof of damage, which shall in all cases be
considered as ascertained. The Employer may, without prejudice to any other method of
recovery, deduct the amount of such liquidated damages from any monies in its hands due or
which may become due to the Contractor. The payment or deduction of such damages shall
not relieve the Contractor from his obligation to complete the Works or from any other of his
obligations and liabilities under the Contract.
b) If, before the time for completion of the whole of the Works or of a Section of the Works, a
Certificate of Substantial Completion has been issued for any part or Section of the Works,
the liquidated damages for delay in completion of the remainder of the Works or of that
Section may, for any period of delay after the date stated in such Certificate of Substantial
Completion, and in the absence of alternative provisions in the Contract, be reduced in the
proportion which the value of the part or Section so certified bears to the total value of the
whole of the Works or Section, as applicable. The provisions of this Sub-Clause shall only
apply to the rate of liquidated damages and shall not affect the limit thereof.
46 CERTIFICATE OF SUBSTANTIAL COMPLETION
46.1 Substantial Completion of the Works
When the whole of the Works have been substantially completed and have satisfactorily
passed any test on completion prescribed by the Contract, the Contractor may give a notice to
that effect to the Engineer accompanied by an undertaking to finish any outstanding work
during the Defects Liability Period. Such notice and undertaking shall be in writing and shall
be deemed to be a request by the Contractor, for the Engineer to issue a Certificate of
Substantial Completion in respect of the Works. The Engineer shall, within twenty-one (21)
days of the date of delivery of such notice either issue to the Contractor, with a copy to the
Employer, a Certificate of Substantial Completion stating the date on which, in his opinion,
the Works were substantially completed in accordance with the Contract or give instructions
in writing to the Contractor specifying all the work which, in the Engineer's opinion, requires
to be done by the Contractor before the issuance of such Certificate. The Engineer shall also
notify the Contractor of any defects in the Works affecting substantial completion that may
appear after such instructions and before completion of the work specified therein. The
Contractor shall be entitled to receive such Certificate of Substantial Completion within
twenty-one (21) days of completion, to the satisfaction of the Engineer, of the work so
specified and making good any defect so notified. Upon issuance of the Certificate of
Substantial Completion of the Works, the Contractor shall be deemed to have undertaken to
complete with due expedition any outstanding work during the Defects Liability Period.
46.2 Substantial Completion of Sections or Parts of the Works
In accordance with the procedure in Sub-Clause (1) of this Clause and on the same
conditions as provided therein, the Contractor may request the Engineer to issue, and the
Engineer may issue, a Certificate of Substantial Completion in respect of any Section or part
Rev Nov 2021 29

INT: ___
of the Works which has been substantially completed and has satisfactorily passed any tests
on completion prescribed by the Contract, if:
a) a separate time for completion is provided in the Contract in respect of such Section or part
of the Works;
b) such Section or part of the Works has been completed to the satisfaction of the Engineer and
is required by the Employer for his occupation or use.
Upon the issuance of such Certificate, the Contractor shall be deemed to have undertaken to
complete any outstanding work during the Defects Liability Period.
47 DEFECTS LIABILITY
47.1 Defects Liability Period
The expression "Defects Liability Period" shall mean the period of twelve (12) months,
calculated from the date of completion of the Works stated in the Certificate of Substantial
Completion issued by the Engineer or, in respect of any Section or part of the Works for
which a separate Certificate of Substantial Completion has been issued, from the date of
completion of that Section or part as stated in the relevant Certificate. The expression "the
Works" shall, in respect of the Defects Liability Period, be construed accordingly.
47.2 Completion of Outstanding Work and Remedying of Defects
During the Defects Liability Period, the Contractor shall finish the work, if any, outstanding
at the date of the Certificate of Substantial Completion, and shall execute all such work of
repair, amendment, reconstruction, rectification and making good defects, imperfections,
shrinkages or other faults as may be required of the Contractor in writing by the Engineer
during the Defects Liability Period and within fourteen (14) days after its expiration, as a
result of an inspection made by or on behalf of the Engineer prior to expiration of the Defects
Liability Period.
47.3 Cost of Execution of Work of Repair, etc.
All such outstanding work shall be carried out by the Contractor at his own expense if the
necessity thereof shall, in the opinion of the Engineer, be due to the use of material or
workmanship not in accordance with the Contract, or to neglect or failure on the part of the
Contractor to comply with any obligation expressed or implied, on the Contractor's part
under the Contract.
47.4 Remedy on Contractor's Failure to Carry Out Work Required
If the Contractor shall fail to do any such work outstanding on the Works, the Employer shall
be entitled to employ and pay other persons to carry out the same, and all expenses
consequent thereon or incidental thereto shall be recoverable from the Contractor by the
Rev Nov 2021 30

INT: ___
Employer, and may be deducted by the Employer from any monies due or which may
become due to the Contractor.
47.5 Certificate of Final Completion
Upon satisfactory completion of the work outstanding on the Works, the Engineer shall
within twenty eight (28) days of the expiration of the Defects Liability period issue a
Certificate of Final Completion to the Contractor. The Contract shall be deemed to be
completed upon issuance of such Certificate, provided that the provisions of the Contract
which remain unperformed and the Settlement of Disputes provision in the Contract shall
remain in force for as long as is necessary to dispose of any outstanding matters or issues
between the Parties.
48 ALTERATIONS, ADDITIONS AND OMISSIONS
1 Variations
The Engineer may within his powers introduce any variations to the form, type or quality of
the Works or any part thereof which he considers necessary and for that purpose or if for any
other reasons it shall, in his opinion be desirable, he shall have power to order the Contractor
to do and the Contractor shall do any of the following:
(a) increase or decrease the quantity of any work under the Contract;
(b) omit any such work;
(c) change the character or quality or kind of any such work;
(d) change the levels, lines, positions and dimensions of any part of the Works;
(e) execute additional work of any kind necessary for the completion of the Works, and no such
variation shall in any way vitiate or invalidate the Contract.
2 Variations Increasing Cost of Contract or altering the Works.
The Engineer shall, however, obtain the written approval of the Employer before giving any
order for any variations which may result in an increase of the Contract Price or in an
essential alteration of the quantity, quality or character of the Works.
3 Orders for Variations to be in Writing
No variations shall be made by the Contractor without an order in writing from the Engineer.
Variations requiring the written approval of the Employer under paragraph (2) of this Clause
shall be made by the Contractor only upon written order from the Engineer accompanied by a
copy of the Employer's approval. Provided that, subject to the provisions of the Contract, no
Rev Nov 2021 31

INT: ___
order in writing shall be required for any increase or decrease in the quantity of any work
where such increase or decrease is not the result of an order given under this Clause but is the
result of the quantities exceeding or being less than those stated in the Bill of Quantities.
4 Valuation of Variations
The Engineer shall estimate to the Employer the amount to be added or deducted from the
Contract Price in respect of any variation, addition or omission. In the case of any variation,
addition or omission which may result in an increase of the Contract Price, the Engineer shall
communicate such estimate to the Employer together with his request for the Employer's
written approval of such variation, addition or omission. The value of any variation, addition
or omission shall be calculated on the basis of the unit prices contained in the Bill of
Quantities.
49 PLANT, TEMPORARY WORKS AND MATERIALS
1 Plant, etc., Exclusive Use for the Works
All Constructional Plant, Temporary Works and Materials provided by the Contractor shall,
when brought on the Site, be deemed to be exclusively intended for the construction and
completion of the Works and the Contractor shall not remove the same or any part thereof
(save for the purpose of moving it from one part of the Site to another) without the consent in
writing of the Engineer which shall not be unreasonably withheld.
2 Removal of Plant, etc.
Upon completion of the Works the Contractor shall remove from the Site all the said
Constructional Plant and Temporary Works remaining thereon and any unused materials
provided by the Contractor.
3 Employer not liable for Damage to Plant
The Employer shall not be at any time liable for the loss of any of the said Constructional
plant, Temporary Works or Materials save if such loss results from the act or neglect of the
Employer, its employees or agents.
4 Ownership of paid material and work
All material and work covered by payments made by the Employer to the Contractor shall
thereupon become the sole property of the Employer, but this provision shall not be
construed as relieving the Contractor from the sole responsibility for all material and work
upon which payments have been made or the restoration of any damaged work or as waiving
the right of the Employer to require the fulfillment of all of the terms of the Contract.
5 Equipment and supplies furnished by Employer
Rev Nov 2021 32

INT: ___
Title to any equipment and supplies which may be furnished by the Employer shall rest with
the Employer and any such equipment and supplies shall be returned to the Employer at the
conclusion of the Contract or when no longer needed by the Contractor. Such equipment
when returned to the Employer, shall be in the same condition as when delivered to the
Contractor, subject to normal wear and tear.
50 APPROVAL OF MATERIALS ETC., NOT IMPLIED
The operation of Clause 49 hereof shall not be deemed to imply any approval by the
Engineer of the materials or other matters referred to therein nor shall it prevent the rejection
of any such materials at any time by the Engineer.
51 MEASUREMENT OF WORKS
The Engineer shall, when he requires any part or parts of the Works to be measured, give
notice to the Contractor or the Contractor's authorized agent or representative who shall
forthwith attend or send a qualified agent to assist the Engineer in making such measurement
and shall furnish all particulars required by either of them. Should the Contractor not attend
or neglect or omit to send such agent, then the measurement made by the Engineer or
approved by him shall be taken to be the correct measurement of the work. The purpose of
measuring is to ascertain the volume of work executed by the Contractor and therefore
determine the amount of the monthly payments.
52 LIABILITY OF THE PARTIES
1 The Works shall not be considered as completed until a Certificate of Final Completion shall
have been signed by the Engineer and delivered to the Employer stating that the Works have
been completed and that the Contractor has fulfilled all his obligations under Clause 47 to his
satisfaction.
2 The Employer shall not be liable to the Contractor for any matter arising out of or in
connection with the Contract or the execution of the Works unless the Contractor shall have
made a claim in writing in respect thereof before the giving of the Certificate of Final
Completion and in accordance with the Contract.
3 Unfulfilled Obligations
Notwithstanding the issue of the Certificate of Final Completion, the Contractor shall remain
liable for the fulfillment of any obligation incurred under the provisions of the Contract prior
to the issuance of the Certificate of Final Completion and which remains unperformed at the
time such Certificate is issued. For the purpose of determining the nature and extent of any
such obligation the Contract shall be deemed to remain in force between the parties hereto.
Rev Nov 2021 33

INT: ___
4 Contractor Responsible
Notwithstanding any other provisions in the Contract documents, the Contractor shall be
totally responsible for and shall bear any and all risks of loss or damage to or failure of the
Works or any part thereof for a period of ten years after issuance of the Certificate of Final
Completion, provided always that such risks, damage or failure result from acts, defaults and
negligence of the Contractor, his agents, employees or workmen and such contractors.
53 AUTHORITIES
1 The Employer shall have the right to enter upon the Site and expel the Contractor therefrom
without thereby voiding the Contract or releasing the Contractor from any of his obligations
or liabilities under the Contract or affecting the rights and powers conferred on the Employer
and the Engineer by the Contract in any of the following cases:
(a) If the Contractor is declared bankrupt or claims bankruptcy or court protection against his
creditors or if the Contractor is a company or member of a company which was dissolved by
legal action;
(b) If the Contractor makes arrangements with his creditors or agrees to carry out the Contract
under an inspection committee of his creditors;
(c) If the Contractor withdraws from the Works or assigns the Contract to others in whole or in
part without the Employer's prior written approval;
(d) If the Contractor fails to commence the Works or shows insufficient progress to the extent
which in the opinion of the Engineer will not enable him to meet the target completion date
of the Works;
(e) If the Contractor suspends the progress of the Works without due cause for fifteen (15) days
after receiving from the Engineer written notice to proceed;
(f) If the Contractor fails to comply with any of the Contract conditions or fails to fulfill his
obligations and does not remedy the cause of his failure within fifteen (15) days after being
notified to do so in writing;
(g) If the Contractor is not executing the work in accordance with standards of workmanship
specified in the Contract;
(h) If the Contractor gives or promises to give a present or loan or reward to any employee of the
Employer or of the Engineer.
Then the Employer may himself complete the Works or may employ any other contractor to
complete the Works and the Employer or such other contractor may use for such completion
so much of Constructional Plant, Temporary Works and Materials, which have been deemed
Rev Nov 2021 34

INT: ___
to be reserved exclusively for the construction and completion of the Works under the
provision of the Contract as he or they may think proper and the Employer may at any time
sell any of the said Constructional Plant, Temporary Works and unused materials and apply
the proceeds of sale in or towards the satisfaction of any sums due or which may become due
to him from the Contractor under the Contract.
2 Evaluation after Re-entry
The Engineer shall as soon as may be practicable after any such entry and expulsion by the
Employer notify the Contractor to attend the necessary evaluation of the Works. In the event
that for any reason the Contractor does not attend such evaluation the Engineer shall
undertake the said evaluation in the absence of the Contractor and shall issue a certificate
stating the sum, if any, due to the Contractor for work done in accordance with the Contract
up to the time of entry and expulsion by the Employer which has been reasonably
accumulated to the Contractor in respect of the Works he has executed in such case in
accordance with the Contract. The Engineer shall indicate the value of the materials whether
unused or partially used and the value of construction equipment and any part of the
Temporary Works.
3 Payment After Re-entry
If the Employer shall enter and expel the Contractor under this Clause he shall not be liable
to pay the Contractor any money on account of the Contract until the expiration of the
Defects Liability Period, and thereafter until the costs of completion and making good any
defects of the Works, damages for delay in completion (if any), and all other expenses
incurred by the Employer have been ascertained and their amount certified by the Engineer.
The Contractor shall then be entitled to receive only such sum or sums (if any) as the
Engineer may certify would have been due to him upon due completion by him after
deducting the said amount. But if such amount shall exceed the sum which would have been
payable to the Contractor on due completion by him,, then the Contractor shall upon demand
pay to the Employer the amount of such excess. The Employer in such case may recover this
amount from any money due to the Contractor from the Employer without the need to resort
to legal procedures.
54 URGENT REPAIRS
If by reason of any accident or failure or other event occurring to, in or in connection with
the Works or any part thereof either during the execution of the Works or during the Defects
Liability Period any remedial or other work or repair shall in the opinion of the Engineer be
urgently necessary for security and the Contractor is unable or unwilling at once to do such
work or repair, the Employer may by his own or other workmen do such work or repair as
the Engineer may consider necessary. If the work or repair so done by the Employer is work
which in the opinion of the Engineer the Contractor was liable to do at his own expense
under the Contract, all costs and charges properly incurred by the Employer in so doing shall
on demand be paid by the Contractor to the Employer or may be deducted by the Employer
Rev Nov 2021 35

INT: ___
from any monies due or which may become due to the Contractor provided always that the
Engineer shall as soon after the occurrence of any such emergency as may be reasonably
practicable notify the Contractor thereof in writing.
55 INCREASE AND DECREASE OF COSTS
Except if otherwise provided by the Contract, no adjustment of the Contract Price shall be
made in respect of fluctuations of market, prices of labour, materials, plant or equipment,
neither due to fluctuation in interest rates nor devaluation or any other matters affecting the
Works.
56 TAXATION
The Contractor shall be responsible for the payment of all charges and taxes in respect of
income including value added tax, all in accordance with and subject to the provisions of the
income tax laws and regulations in force and all amendments thereto. It is the Contractor's
responsibility to make all the necessary inquiries in this respect and he shall be deemed to
have satisfied himself regarding the application of all relevant tax laws.
57 BLASTING
The Contractor shall not use any explosives without the written permission of the Engineer
who shall require that the Contractor has complied in full with the regulations in force
regarding the use of explosives. However, the Contractor, before applying to obtain these
explosives, has to provide well arranged storage facilities. The Engineer's approval or refusal
to permit the use of explosives shall not constitute ground for claims by the Contractor.
58 MACHINERY
The Contractor shall be responsible for coordinating the manufacture, delivery, erection and
commissioning of plant machinery and equipment which are to form a part of the Works. He
shall place all necessary orders as soon as possible after the signing of the Contract. These
orders and their acceptance shall be produced to the Engineer on request. The Contractor
shall also be responsible for ensuring that all sub-contractors adhere to such programs as are
agreed and are needed to ensure completion of the Works within the period for completion.
Should any sub-contracted works be delayed, the Contractor shall initiate the necessary
action to speed up such completion. This shall not prejudice the Employer's right to exercise
his remedies for delay in accordance with the Contract.
59 TEMPORARY WORKS AND REINSTATEMENT
Rev Nov 2021 36

INT: ___
The Contractor shall provide and maintain all temporary roads and tracks necessary for
movement of plant and materials and clear same away at completion and make good all
works damaged or disturbed. The Contractor shall submit drawings and full particulars of all
Temporary Works to the Engineer before commencing same. The Engineer may require
modifications to be made if he considers them to be insufficient and the Contractor shall give
effect to such modifications but shall not be relieved of his responsibilities. The Contractor
shall provide and maintain weather-proof sheds for storage of material pertinent to the Works
both for his own use and for the use of the Employer and clear same away at the completion
of the Works. The Contractor shall divert as required, at his own cost and subject to the
approval of the Engineer, all public utilities encountered during the progress of the Works,
except those specially indicated on the drawings as being included in the Contract. Where
diversions of services are not required in connection with the Works, the Contractor shall
uphold, maintain and keep the same in working order in existing locations. The Contractor
shall make good, at his own expense, all damage to telephone, telegraph and electric cable or
wires, sewers, water or other pipes and other services, except where the Public Authority or
Private Party owning or responsible for the same elects to make good the damage. The costs
incurred in so doing shall be paid by the Contractor to the Public Authority or Private Party
on demand.
60 PHOTOGRAPHS AND ADVERTISING
The Contractor shall not publish any photographs of the Works or allow the Works to be
used in any form of advertising whatsoever without the prior approval in writing from the
Employer.
61 PREVENTION OF CORRUPTION
The Employer shall be entitled to cancel the Contract and to recover from the Contractor the
amount of any loss resulting from such cancellation, if the Contractor has offered or given
any person any gift or consideration of any kind as an inducement or reward for doing or
intending to do any action in relation to the obtaining or the execution of the Contract or any
other contract with the Employer or for showing or intending to show favour or disfavour to
any person in relation to the Contract or any other contract with the Employer, if the like acts
shall have been done by any persons employed by him or acting on his behalf whether with
or without the knowledge of the Contractor in relation to this or any other Contract with the
Employer.
62 DATE FALLING ON HOLIDAY
Where under the terms of the Contract any act is to be done or any period is to expire upon a
certain day and that day or that period fall on a day of rest or recognized holiday, the
Contract shall have effect as if the act were to be done or the period to expire upon the
working day following such day.
Rev Nov 2021 37

INT: ___
63 NOTICES
1 Unless otherwise expressly specified, any notice, consent, approval, certificate or

determination by any person for which provision is made in the Contract Documents shall be
in writing. Any such notice, consent, approval, certificate or determination to be given or
made by the Employer, the Contractor or the Engineer shall not be
2 unreasonably withheld or delayed.
3 Any notice, certificate or instruction to be given to the Contractor by the Engineer or the
Employer under the terms of the Contract shall be sent by post, cable, telex or facsimile at
the Contractor's principal place of business specified in the Contract or such other address as
the Contractor shall nominate in writing for that purpose, or by
4 delivering the same at the said address against an authorized signature certifying the receipt.
5 Any notice to be given to the Employer under the terms of the Contract shall be sent by post,
cable, telex or facsimile at the Employer's address specified in the Contract, or by delivering
the same at the said address against an authorized signature certifying the receipt.
6 Any notice to be given to the Engineer under the terms of this Contract shall be sent by post,
cable, telex or facsimile at the Engineer's address specified in the Contract, or by delivering
the same at the said address against an authorized signature certifying the receipt.
64 LANGUAGE, WEIGHTS AND MEASURES
Except as may be otherwise specified in the Contract, English shall be used by the Contractor
in all written communications to the Employer or the Engineer with respect to the services to
be rendered and with respect to all documents procured or prepared by the Contractor
pertaining to the Works. The metric system of weights and measures shall be used in all
instances.
65 RECORDS, ACCOUNTS, INFORMATION AND AUDIT
The Contractor shall maintain accurate and systematic records and accounts in respect of the
work performed under this Contract.
The Contractor shall furnish, compile or make available at all times to the UNDP any records
or information, oral or written, which the UNDP may reasonably request in respect of the
Works or the Contractor's performance thereof.
The Contractor shall allow the UNDP or its authorized agents to inspect and audit such
records or information upon reasonable notice.
Rev Nov 2021 38

INT: ___
66 FORCE MAJEURE
Force majeure as used herein means Acts of God, war (whether declared or not), invasion,
revolution, insurrection or other acts or events of a similar nature or force.
In the event of and as soon as possible after the occurrence of any cause constituting force
majeure, the Contractor shall give notice and full particulars in writing to the UNDP and to
the Engineer of such force majeure if the Contractor is thereby rendered unable, wholly or in
part, to perform its obligations and meet its responsibilities under this Contract. Subject to
acceptance by the UNDP of the existence of such force majeure, which acceptance shall not
be unreasonably withheld, the following provisions shall apply:
(a) The obligations and responsibilities of the Contractor under this Contract shall be suspended
to the extent of his inability to perform them and for as long as such inability continues.
During such suspension and in respect of work suspended, the Contractor shall be reimbursed
by the UNDP substantiated costs of maintenance of the Contractor's equipment and of per
diem of the Contractor's permanent personnel rendered idle by such suspension;
(b) The Contractor shall within fifteen (15) days of the notice to the UNDP of the occurrence of
the force majeure submit a statement to the UNDP of estimated costs referred to in sub-
paragraph (a) above during the period of suspension followed by a complete statement of
actual expenditures within thirty (30) days after the end of the
(c) suspension;
(d) The term of this Contract shall be extended for a period equal to the period of suspension
taking however into account any special condition which may cause the additional time for
completion of the Works to be different from the period of suspension;
(e) If the Contractor is rendered permanently unable, wholly or in part, by reason of force
majeure, to perform his obligations and meet his responsibilities under the Contract, the
UNDP shall have the right to terminate the Contract on the same terms and conditions as
provided for in Clause 68 of these General Conditions, except that the period of notice shall
be seven (7) days instead of fourteen (14) days, and
(f) For the purpose of the preceding sub-paragraph, the UNDP may consider the Contractor
permanently unable to perform in case of any suspension period of more than ninety (90)
days.
67 SUSPENSION BY THE UNDP
The UNDP may by written notice to the Contractor suspend for a specified period, in whole
or in part, payments to the Contractor and/or the Contractor's obligation to continue to
perform the Works under this Contract, if in the UNDP' sole discretion:
Rev Nov 2021 39

INT: ___
(a) any conditions arise which interfere, or threaten to interfere with the successful execution of
the Works or the accomplishment of the purpose thereof, or
(b) the Contractor shall have failed, in whole or in part, to perform any of the terms and
conditions of this Contract.
After suspension under sub-paragraph (a) above, the Contractor shall be entitled to
reimbursement by the UNDP of such costs as shall have been duly incurred in accordance
with this Contract prior to the commencement of the period of such suspension.
The term of this Contract may be extended by the UNDP for a period equal to any period of
suspension, taking into account any special conditions which may cause the additional time
for completion of the Works to be different from the period of suspension.
68 TERMINATION BY THE UNDP
The UNDP may, notwithstanding any suspension under Clause 67 above, terminate this
Contract for cause or convenience in the interest of the UNDP upon not less than fourteen
(14) days written notice to the Contractor.
Upon termination of this Contract:
(a) The Contractor shall take immediate steps to terminate his performance of the Contract in a
prompt and orderly manner and to reduce losses and to keep further expenditures to a
minimum, and
(b) The Contractor shall be entitled (unless such termination has been occasioned by the
Contractor's breach of this Contract), to be paid for the part of the Works satisfactorily
completed and for the materials and equipment properly delivered to the Site as of the date of
termination for incorporation to the Works, plus substantiated costs resulting from
commitments entered into prior to the date of termination as well as any reasonable
substantiated direct costs incurred by the Contractor as a result of the termination, but shall
not be entitled to receive any other or further payment or damages.
69 TERMINATION BY THE CONTRACTOR
In the case of any alleged breach by the UNDP of the Contract or in any other situation
which the Contractor reasonably considers to entitle him to terminate his performance of the
Contract, the Contractor shall promptly give written notice to the UNDP detailing the nature
and the circumstances of the breach or other situation. Upon acknowledgement in writing by
the UNDP of the existence of such breach and the UNDP' inability to remedy it, or upon
failure of the UNDP to respond to such notice within twenty (20) days of receipt thereof, the
Contractor shall be entitled to terminate this Contract by giving 30 days written notice
thereof. In the event of disagreement between the Parties as to the existence of such breach
Rev Nov 2021 40

INT: ___
or other situation referred to above, the matter shall be resolved in accordance with Clause 71
of these General Conditions.
Upon termination of this Contract under this Clause the provisions of sub-paragraph (b) of
Clause 68 hereof shall apply.
70 RIGHTS AND REMEDIES OF THE UNDP
Nothing in or relating to this Contract shall be deemed to prejudice or constitute a waiver of

any other rights or remedies of the UNDP.
The UNDP shall not be liable for any consequences of, or claim based upon, any act or
omission on the part of the Government.
71 SETTLEMENT OF DISPUTES
In the case of any claim, controversy or dispute arising out of, or in connection with this Contract
or any breach thereof, the following procedure for resolution of such claim, controversy or
dispute shall apply.
1 Notification
The aggrieved party shall immediately notify the other party in writing of the nature of the
alleged claim, controversy or dispute, not later than seven (7) days from awareness of the
existence thereof.
2 Consultation
On receipt of the notification provided above, the representatives of the Parties shall start
consultations with a view to reaching an amicable resolution of the claim, controversy or
dispute without causing interruption of the Works.
3 Conciliation
Where the representatives of the Parties are unable to reach such an amicable settlement,
either party may request the submission of the matter to conciliation in accordance with the
UNCITRAL Rules of Conciliation then obtaining.
4 Arbitration
Any claim, controversy or dispute which is not settled as provided under clauses 71.1
through 3 above shall be referred to arbitration in accordance with the UNCITRAL
Arbitration Rules then obtaining. The Parties shall be bound by the arbitration award
Rev Nov 2021 41

INT: ___
rendered in accordance with such arbitration as the final adjudication of any such controversy
or claim.
72 PRIVILEGES AND IMMUNITIES
Nothing in or relating to this Contract shall be deemed a waiver of any of the privileges and
immunities of the United Nations of which the UNDP is an integral part.
73 SECURITY
The Contractor shall:

(a) put in place an appropriate security plan and maintain the security plan, taking into
account the security situation in the country where the services are being provided;
(b) assume all risks and liabilities related to the Contractor’s security, and the full
implementation of the security plan.
UNDP reserves the right to verify whether such a plan is in place, and to suggest modifications
to the plan when necessary. Failure to maintain and implement an appropriate security plan as
required hereunder shall be deemed a breach of this contract. Notwithstanding the foregoing,
the Contractor shall remain solely responsible for the security of its personnel and for UNDP’s
property in its custody as set forth in paragraph 4.1 above.
74 AUDIT AND INVESTIGATIONS
Each invoice paid by UNDP shall be subject to a post-payment audit by auditors, whether
internal or external, of UNDP or the authorized agents of the UNDP at any time during the
term of the Contract and for a period of three (3) years following the expiration or prior
termination of the Contract. The UNDP shall be entitled to a refund from the Contractor for
any amounts shown by such audits to have been paid by the UNDP other than in accordance
with the terms and conditions of the Contract. Should the audit determine that any funds paid
by UNDP have not been used as per contract clauses, the company shall reimburse such
funds forthwith. Where the company fails to reimburse such funds, UNDP reserves the right
to seek recovery and/or to take any other action as it deems necessary.
The Contractor acknowledges and agrees that, at anytime, UNDP may conduct
investigations relating to any aspect of the Contract, the obligations performed under the
Contract, and the operations of the Contractor generally. The right of UNDP to conduct an
investigation and the Contractor’s obligation to comply with such an investigation shall not
lapse upon expiration or prior termination of the Contract. The Contractor shall provide its
full and timely cooperation with any such inspections, post-payment audits or investigations.
Such cooperation shall include, but shall not be limited to, the Contractor’s obligation to
make available its personnel and any documentation for such purposes and to grant to UNDP
Rev Nov 2021 42

INT: ___
access to the Contractor’s premises. The Contractor shall require its agents, including, but
not limited to, the Contractor’s attorneys, accountants or other advisers, to reasonably
cooperate with any inspections, post-payment audits or investigations carried out by UNDP
hereunder.
75 ANTI-TERRORISM
The Contractor agrees to undertake all reasonable efforts to ensure that none of the UNDP
funds received under this Contract are used to provide support to individuals or entities
associated with terrorism and that the recipients of any amounts provided by UNDP
hereunder do not appear on the list maintained by the Security Council Committee
established pursuant to resolution 1267 (1999). The list can be accessed via
https://www.un.org/securitycouncil/content/un-sc-consolidated-list. This provision must be
included in all sub-contracts or sub-agreements entered into under this Contract.
APPENDIX I: FORMATS OF PERFORMANCE SECURITY
Rev Nov 2021 43

INT: ___
PERFORMACE BANK GUARANTEE
To: .................................................
[INSERT FULL NAME AND ADDRESS OF RR or BUREAU/DIVISION

DIRECTOR AT UNDP]
WHEREAS RIVIO CONSTRUCTION (hereinafter called "the Contractor") has undertaken, in

pursuance of Contract No UNDP/CW/TLS/2022/002, dated................, to execute UNDP Timor-
Leste and RIVIO CONSTRUCTION, UNIPESSOAL LDA for the Construction of
ACCESS TO JUSTICE CLINIC at PDO Office, Ermera, Timor-Leste, (hereinafter called
"the Contract");
AND WHEREAS it has been stipulated by you in the said Contract that the Contractor shall
furnish you with a Bank Guarantee by a recognized Bank for the sum specified therein as
security for compliance with his obligations in accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee;
NOW THEREFORE we hereby irrevocably affirm that we are the Guarantor and responsible to
you, on behalf of the Contractor, up to a total of US $6,445.00 (10% of total amount of
contract, such sum being payable in the types and proportions of currencies in which the
Contract Price is payable, and we undertake to pay you, upon your first written demand and
without cavil or argument, any sum or sums within the limits of US $6,445.00 (10% of total
amount of contract) as aforesaid without your needing to prove or to show grounds or reasons
for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Contractor before
presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the Contract
or of the Works to be performed thereunder or of any of the Contract Documents which may be
made between you and the Contractor shall in any way release us from any liability under this
guarantee, and we hereby waive notice of any such change, addition or modification.
This guarantee shall be valid until twenty eight calendar days after issuance of the Certificate of
Final Completion.
SIGNATURE AND SEAL OF THE GUARANTOR

............................................................ ..................................................................
NAME OF BANK ..................................................................

ADDRESS ..................................................................
DATE .................................................................
Rev Nov 2021 44

INT: ___
PERFORMANCE BOND
By this Bond ...................................................................................................[INSERT NAME

AND ADDRESS OF THE CONTRACTOR] as Principal (hereinafter called "the Contractor")
and ................................................[INSERT
NAME, LEGAL TITLE AND ADDRESS OF SURETY, BONDING COMPANY OR
INSURANCE COMPANY] as Surety (hereinafter called "the Surety") are held and firmly bound
unto .....................................................[INSERT NAME AND ADDRESS OF EMPLOYER] as
Obligee (hereinafter called "the Employer") in the amount of.
........................................................[INSERT AMOUNT OF BOND IN FIGURES AND IN
WORDS], for the payment of which sum well and truly to be made in the types and proportions
of currencies in which the Contract Price is payable, the Contractor and the Surety bind
themselves, their heirs, executors, administrators, successors and assigns, jointly and severally,
firmly by these presents.
WHEREAS the Contractor has entered into a contract with the Employer dated for
................................................... [INSERT TITLE OF CONTRACT AND BRIEF
DESCRIPTION OF THE WORKS] in accordance with the documents, plans, specifications and
amendments thereto, which to the extent herein provided for, are by reference made part hereof
and are hereinafter referred to as the Contract.
NOW, THEREFORE, the Condition of this Obligation is such that, if the Contractor shall
promptly and faithfully perform the said Contract (including any amendments thereto) then this
obligation shall be null and void; otherwise it shall remain in full force and effect. Whenever the
Contractor shall be , and declared by the Employer to be, in default under the Contract, the
Employer having performed the Employer's obligations thereunder, the Surety may promptly
remedy the default, or shall promptly:
(1) complete the Contract in accordance with its terms and conditions; or
(2) obtain a bid or bids from qualified Bidders for submission to the Employer for completing the
Contract in accordance with its terms and conditions, and upon determination by the Employer
and the Surety of the lowest responsible Bidder, arrange for a Contract between such Bidder and
Employer and make available as work progresses (even though there should be a default or a
succession of defaults under the Contract or Contracts of completion arranged under this
paragraph) sufficient funds to pay the cost of completion less the Balance of the Contract Price;
but not exceeding, including other costs and damages for which the Surety may be liable
hereunder, the amount set forth in the first paragraph hereof. The term " Balance of the Contract
Rev Oct 20001
Price", as used in this paragraph, shall mean the total amount payable by Employer to Contractor
under the Contract, less the amount properly paid by Employer to Contractor; or
(3) pay the Employer the amount required by Employer to complete the Contract in accordance
with its terms and conditions up to a total not exceeding the amount of this Bond.
The Surety shall not be liable for a greater sum than the specified penalty of this Bond.
No right of action shall accrue on this Bond to or for the use of any person or corporation other
than the Employer named herein or the heirs, executors, administrators, successors and assigns of
the Employer.
In testimony whereof, the Contractor has hereunto set his hand and affixed his seal, and the
Surety has caused these presents to be sealed with his corporate seal duly attested by the
signature of his legal representative, this.........day of..................2000
SIGNED ON: SIGNED ON:
ON BEHALF OF: ON BEHALF OF:
NAME &TITLE: NAME &TITLE:
Rev Oct 20002

Contract UNDPTLS2622022 - Central Hill - For Countersignature

Uploaded by

Copyright:

Available Formats

Contract UNDPTLS2622022 - Central Hill - For Countersignature

Uploaded by

Document Information

Original Description:

Copyright

Available Formats

Share this document

Share or Embed Document

Sharing Options

Did you find this document useful?

Is this content inappropriate?

Copyright:

Available Formats

Contract UNDPTLS2622022 - Central Hill - For Countersignature

Uploaded by

Copyright:

Available Formats

DocuSign Envelope ID: 650EC340-1BD1-40A6-B45E-4658A696D21B

Contract for Civil Works

Contract Ref. no: UNDP/TLS/RFQ/2022/003

Rev Nov 2021 1

CONTRACT FOR CIVIL WORKS

Date: 19 August 2022

Contract no.: UNDP/TLS/CW/2022/026

The United Nations Development Programme (hereinafter referred to as "UNDP"), wishes to

Rev Nov 2021 2

2. Obligations of the Contractor

3. Price and Payment

No. % of Target % Amount

Rev Nov 2021 3

 Painting of masonry work completed

Rev Nov 2021 4

6. Time and manner of payment

NAME OF THE BANK: BANK MANDIRI DILI

ACCOUNT NUMBER: 601-00-0047364-8

BANK ADDRESS: Dili, Timor-Leste

For the UNDP:

Name: Tito De Jesus Filipe Da Costa

Telephone number: +670 7726 9279

Ref. UNDP/ TLS/CW/2022/026

Rev Nov 2021 5

For the Contractor:

Name: Aderito da Costa Correia

Telephone number: +670 77256112

Name: Reinaldo Soares Da Costa

Telephone number: +670 77407070

For: Central Hill Unipessoal Lda

Agreed and Accepted:

Name Aderito da Costa Correia

Rev Nov 2021 6

TECHNICAL SPECIFICATIONS AND DRAWINGS (Attached separately)

Rev Nov 2021 7

UNDP GENERAL CONDITIONS

General Conditions of Contract for Civil Works

Rev Nov 2021 8

30. Extraordinary Traffic and Special Loads

Appendix I: Formats of Performance Security

Rev Nov 2021 9

a) "Employer" means the United Nations Development Programme (UNDP).

2. SINGULAR AND PLURAL

Rev Nov 2021 10

5. GENERAL DUTIES/POWERS OF ENGINEER

a) The Engineer shall provide administration of Contract as provided in the Contract

Rev Nov 2021 11

f) Based on the Engineer's observations and an evaluation of the documentation submitted by

Rev Nov 2021 12

6. CONTRACTOR'S GENERAL OBLIGATIONS/RESPONSIBILITIES

6.1.Obligation to Perform in Accordance with Contract

6.2 Responsibility for Site Operations

6.3.Responsibility for Employees

6.5.Officials Not to Benefit

Rev Nov 2021 13

6.6.Use of Name, Emblem or Official Seal of UNDP or the United Nations

6.7.Confidential Nature of Documents

All maps, drawings, photographs, mosaics, plans, reports, recommendations, estimates,

7. ASSIGNMENT AND SUBCONTRACTING