RFP Mizoram
RFP Mizoram
RFP Mizoram
FOR
[Online mode]
January, 2020
CONTENT
Sr. Page
Particulars
No. Nos.
1 SECTION 1: Information to Consultants 3-8
2 SECTION 2: Letter of Invitation 9-19
Datasheet 20-24
Appendix-EC 25-38
3 SECTION 3: Format for Submission of Firms Credentials. 39-42
4 SECTION 4: Format for Submission of Technical Proposal. 43
Project Length
S r. Project Assignment
Consultancy Package NH No. State (Km)/ Estimated
No. Stretch period (months)
Cost(Cr.)
1 Consultancy services as Authority’s
Engineer for Supervision of
“Rehabilitation and Up-gradation to
2 lane with paved shoulders of 24 months
Seling-Dulte section (Economic Seling- Dulte during
Mizoram
Construction
Corridor) of NH-6 from Existing NH-6 62.20 km /
Period and 60
chainage Km 0+000 to Km 69+015 755.59 Cr.
months during
(Design Chainage Km 0+000 to Km Maintenance
62+200) in the State of Mizoram Period
under Bharatmala Pariyojna on EPC
mode.
3. All the bidders registered on Infracon shall form a Team on Infracon and which
would be assigned unique Infracon Team ID. Bidders while submitting the
proposal shall quote the Infracon Team ID.
6. The proposal shall be submitted in English Language and all correspondence would be
in the same language.
Page 3 of 229
7. National Highways & Infrastructure Development Corporation Limited (NHIDCL)
intends to appoint a Consultant to act as Authority’s Engineer for implementation of the
following EPC project. As per the Terms and Conditions of the EPC Agreement(s), the
Authority’s Engineer shall perform all the duties as per TOR given in this RFP along
with any amendment thereof. The selection of Authority’s Engineer shall follow the
laid down procedures given in the Contract Agreement signed between Employer and
Contractor. The Civil work of subject project is to be executed in the following 04
packages:
9. Unqualified bidders would be informed regarding their non qualification, without any
explanation.
10. The proposal should be submitted by consultancy firms in two parts. The two parts of
Page 4 of 229
the proposal are Part1: Technical Proposal and Part2: Financial Proposal. For this
bid, Stage -1 of the Evaluation shall consider the evaluation of the Technical Proposal
(i.e. Part 1). The firms scoring the qualifying marks (minimum 75%) as mentioned in
RFP shall only be considered for further evaluation. Under stage 2, the financial
proposal of such firms as selected above shall be opened and evaluated. Proposals will
finally be ranked according to their combined technical and financial scores as
specified in clause 5 of section 2.
11. The total time period for the assignment as Authority’s Engineer will be for
Construction Period of 24 months +Maintenance Period of 60 Months with reduced
man power.
12. Consultants may apply either as a sole firm or forming Joint Venture with other
consultants. In case of Joint Venture, the maximum number of Joint Venture partners
is limited to 2 (i.e. one lead + 1 JV partners). Formulation of more than one
JV/association with different partners for the same work is not allowed and all such
proposal involving the firms shall be treated as non-responsive. If the Consultant
submits bids as sole applicant and also in JV/Association with another consultant,
both bids shall be summarily rejected. No Consultant shall submit more than one bid.
13. (A) The Applicant whether a sole applicant or lead member with joint venture may
include One Associate to provide technology in assignment (refer para 10(iii) of data
sheet). The Associate firm can provide equipment based road inspection services for
any of the 4 equipment viz., (i) Network Survey Vehicle including all modules required
as per technical specifications, (ii) Falling Weight Deflectometer, (iii) Mobile Bridge
Inspection Unit and (iv) Retro Reflectometer. However, the Associate(s) cannot be
common for 2 or more bidders. If any Associate is common with 2 or more bidders, all
those bids shall be declared non-responsive. Hence, the bidder may ensure on his own
that the associate proposed by him is not proposed by any other bidder participating
in the same assignment and the bidder is solely responsible in this regard.
(B) In addition, the applicant whether a sole applicant or lead member with joint
venture may also include an Associate for providing key personnel. In such case, the
applicant should submit an MOU with associate regarding role and responsibility of
Associate Company. However the maximum no. of key personnel from Associate firm
during RFP proposal and implementation of contract should be limited to two (2).
14. The Applicant, by submitting its Application pursuant to this RFP, shall be deemed to
have acknowledged that without prejudice to the NHIDCL any other right or remedy
hereunder or in law or otherwise, the Applicant shall be debarred from participating in
the future projects of the NHIDCL in the following situations
(a) If an Applicant withdraws its Proposal during the period of its validity as
specified in this RFP and as extended by the Applicant from time to time.
(b) In the case of a Selected Applicant, if the Applicant fails to sign the Agreement.
15. Consulting firms meeting the following criteria are only eligible for applying for this
assignment. Firms not meeting these criteria, need not apply.
** Similar project means 2/4/6 lane as applicable for the project for which RFP is invited.
For 2-lane projects experience of 4/6 lane also to be considered with a multiplication
factor of 1.5. Experience of 4/6 lane shall be considered interchangeably for 4/6 laning
projects. For 4/6 laning projects, experience of 2 lane will be considered with a
multiplication factor of 0.4, but only for those 2 lane projects whose cost of consultancy
services was more than Rs.3.0 crores.
B) Eligibility Criteria for partners in case of JV (not more than 1 JV partners shall
be allowed) shall be as under:
The lead partner must fulfill atleast 50% of requirements at 1(a) of table in para (A)
above and other JV partner should fulfill atleast 30% of eligibility criteria as indicated
at 1(a) of table in para (A) above. Also the lead partner and JV partner jointly should
meet the eligibility criteria as mentioned at 1(a) of table in para (A) above. Lead
partner should meet the criteria 1 (b) of table in para (A) above.
Note: The weightage given for experience of a firm would depend on the role of the
firm in the respective assignments. The firm’s experience would get full credit if it was
the sole firm in the respective assignment. If the applicant firm has completed projects
as JV with some other firms, weightage shall be given as per the JV share***. However
if the applicant firm has executed the project as associate with some other firms, 25%
weightage shall be given to the applicant firm for the projects completed under such
association.
Page 6 of 229
certificate from the client along with JV agreement shall be submitted. In absence of
clear demarcation of JV share in client certificate & in JV agreement, the weightage
will be treated as 60 % for lead partner and 40% for minor partner. Annual turnover
duly certified by Chartered Accountant shall be accepted. In case of non-availability of
such documents no weightage of turnover/experience will be considered.
16. In case the financial figures and values of services provided are in foreign currency
current market exchange rate (State Bank of India BC Selling rate as on last date of
submission of the bid) will be applied for the purpose of conversion of amount in foreign
currency into Indian Rupees.
17. The Bidder including individual or any of its Joint Venture Member should, in the last 2
years, have neither failed to perform for the consultancy services pertaining to
Expressways, National Highways, ISC (Inter State Connectivity) & EI (Economic
Importance) works, as evidenced by imposition of a penalty by an arbitral or judicial
authority or a judicial pronouncement or arbitration award against the Bidder including
individual or any of its Joint Venture Member, as the case may be, nor has been expelled
or terminated by Ministry of Road Transport & Highways or its implementing agencies
for breach by such Bidder including individual or any of its Joint Venture Member.
Consultants (sole firm or lead firm and any of the JV partners) who do not fulfill the
aforesaid condition as on last date of submission of proposal, need not apply as their
RFP proposal will not be entertained.
18. Employer will not be responsible for any delay, loss or non-receipt of RFP document
sent by post/courier. Further, Employer shall not be responsible for any delay in
receiving the proposal and reserves the right to accept/reject any or all applications
without assigning any reason thereof.
19. The two parts of the Proposal (Technical proposal and Financial proposal) must be
submitted on-line only with all pages numbered serially, along with an index of
submission as per procedure under e-tendering. Physical submission of the proposal
shall not be accepted. In the event, any of the instructions mentioned herein have not
been adhered to, the Employer may reject the Proposal.
20. Employer will be at liberty to keep the credentials submitted by the Consultants at
bidding stage, in public domain and the same may be uploaded by Employer on
Employer’s web-site. Consultants should have no objection if Employer uploads the
information pertaining to their credentials as well as of their key personnel.
21. The individual key personnel proposed in the bid by the consultants or any replacement
thereof should undertake that they shall have no objection in uploading/hoisting of their
credentials by Employer in public domain.
22. RFP submission must be received not later than 1100 hrs on 28.02.2020 in the
manner specified in the RFP document at the address given below.
Address of Employer:
Page 8 of 229
SECTION 2: LETTER OF INVITATION TO CONSULTANTS
1 INTRODUCTION
1.1 Bids are invited from consulting firms either as a sole firm/ joint venture with other
Consultant willing to act as AE to submit a proposal for providing consulting services
required for the assignment “Consultancy services as Authority’s Engineer for
Supervision of “Rehabilitation and Up-gradation to 2 lane with paved shoulders
of Seling-Dulte section (Economic Corridor) of NH-6 from Existing chainage Km
0+000 to Km 69+015 (Design Chainage Km 0+000 to Km 62+200) in the State
of Mizoram under Bharatmala Pariyojna on EPC mode.”
1.2 A brief description of the assignment and its objectives are given in the Terms of
Reference (TOR).
1.3 The assignment shall be implemented in Construction Period (24 Months) and
Maintenance Period (60 Months).
1.4 This RFP is neither an agreement nor an offer by the Authority to the prospective
Applicants or any other person. The purpose of this RFP is to provide interested
parties with information that may be useful to them in the formulation of their
Proposals pursuant to this RFP. This RFP includes statements and assumptions, which
reflect various assessments arrived at by the Authority in relation to the Consultancy.
Such assessments and statements do not purport to contain all the information that
each Applicant may require. The information contained in this RFP, may not be
complete, accurate, adequate or correct. Each Applicant should, therefore, conduct its
own investigations about the assignment and the local conditions before submitting
the proposal by paying a visit to the Client and the project site, sending written queries
to the client, before the date and time specified in the Data Sheet.
1.5 Please note that (i) the costs of preparing the proposal and negotiating for the
contract, including a visit to site, are not reimbursable as a direct cost of assignment
and (ii) Employer is not bound to accept any of the proposals received by it and
reserves the right to annul the selection process at any time prior to contract award,
without thereby incurring any liability to the Consultants.
1.6 Consultant have an obligation to disclose any situation of actual or potential conflict
that impacts their capacity to serve the best interest of their Client, or than may
reasonably be perceived as having this effect. Failure to disclose said situations may
lead to the disqualification of the Consultant
Or the termination of its Contract and/or any other action as deemed fit by the Authority
at any stage.
1.7 It is the NHIDCL policy that the consultants observe the highest standard of ethics
during the selection and execution of such contracts. In pursuance of this policy, the
NHIDCL:
(a) Defines, for the purpose of this paragraph, the terms set forth below as follows:
Page 9 of 229
(i) “corrupt practice” means the offering, giving, receiving, or soliciting,
directly or indirectly, of anything of value to influence the action of a
public official in the selection process or in contract execution;
(ii) “fraudulent practice” means a misrepresentation or omission of facts in
order to influence a selection process or the execution of a contract;
(iii) “collusive practices” means a scheme or arrangement between two or more
consultants with or without the knowledge of the Client, designed to
establish prices at artificial, non-competitive levels;
(iv) “coercive practices” means harming or threatening to harm, directly or
indirectly, persons or their property to influence their participation in a
procurement process, or affect the execution of a contract.
(b) will reject a proposal for award if it determines that the Consultant
recommended for award has, directly or through an agent, engaged in corrupt,
fraudulent, collusive or coercive practices in competing for the contract in
question;
(c) will declare a firm ineligible, either indefinitely or for a stated period of time,
to be awarded a contract if it at any time determines that the firm has engaged
in corrupt or fraudulent practices in competing for, or in executing, a contract;
and
(d) will have the right to require that a provision be included requiring consultants
to permit the Employer to inspect their accounts and records relating to
the performance of the contract and to have them audited by authorized
representatives of Employer.
1.8 Consultants, their JV partner, their Sub-Consultants, and their associates shall not be
under a declaration of ineligibility for corrupt and fraudulent practices. Furthermore,
the Consultants shall be aware of the provisions on fraud and corruption stated in the
specific clauses in the General Conditions of Contract.
1.9 Consultants shall furnish information on commissions and gratuities, if any, paid or to
be paid to agents relating to this proposal and during execution of the assignment if the
Consultant is awarded the Contract, in the Financial Proposal.
1.10 The Data Sheet indicates how long Consultants’ Proposals must remain valid after the
submission date. During this period, Consultants shall maintain the availability of
Page 10 of 229
Professional staff nominated in the Proposal. The Client will make its best effort to
complete the process within this period. Should the need arise, however, the Client may
request Consultants to extend the validity period of their proposals. Consultants who
agree to such extension shall confirm that they maintain the availability of the
Professional staff nominated in the Proposal, or in their confirmation of extension of
validity of the Proposal, consultants could seek replacement upto a maximum of 50%
key personnel .If any Consultant seeks any replacement(s), while extending the bid
validity, then the same shall be evaluated for ascertaining suitability of replacement as
per the provisions of the RFP and remuneration shall not be reduced for any such
replacement(s). However, the technical evaluation shall take into account of the
originally submitted CV(s) only irrespective of replacement sought.
2. CLARIFICATIONS AND AMENDMENT OF RFP DOCUMENTS
2.1 The Consultants may request a clarification of any of the RFP documents up to the
number of days indicated in the Data Sheet before the Proposal submission date. Any
request for clarification must be sent in writing by paper mail, facsimile, or electronic
mail to the Client’s address indicated in the Data Sheet. The Client will respond by cable,
facsimile, or electronic mail to such requests and will send copies of the response
(including an explanation of the query but without identifying the source of inquiry) to
all consultants who have purchased the RFP document. Clarification/amendment will
also be hosted on NHIDCL e-portal.
2.2 At any time before the submission of Proposals, the Client may for any reason, whether
at its own initiative or in response to a clarification requested by a Consulting firm,
modify the RFP documents by amendment. Any amendment shall be issued in writing
through addendum. Addendum may be sent by mail, cable, telex, facsimile or electronic
mail to consultants or/and will be hosted on Employer’s website which will be binding
on them. The Client may at its discretion extend the deadline for the submission of
Proposals.
3. PREPARATION OF PROPOSAL
3.1 You are requested to submit your proposal in Two Parts strictly using the formats
enclosed herewith (refer section 3,4and 5). The two parts shall be:
The proposal shall be written in the English language as specified in the Data Sheet. All
pages of the Proposal shall be signed by an authorized representative. The
representative’s authorization shall be confirmed by written Power of Attorney duly
notarized to be submitted with the proposal. In case of JV or inclusion of Associate
company, a MoU indicating the specific Projects, input and role of each Partner etc. shall
be submitted with the proposal.
3.2 You are expected to examine all terms and conditions included in the documents.
Failure to act or to provide all requested information will be at your own risk and may
Page 11 of 229
result in rejection of your proposal.
3.3 During preparation of the Technical proposal you may give particular attention to the
following
i. The man-months for the assignment shall be that stated in the Terms of
Reference. The same shall be considered for the purpose of evaluation as well
as award. In case the man months of TOR are amended in view of Client’s own
initiative or in response to clarification sought by any Consulting firm, the man
months so amended and published shall be considered for the purpose of
evaluation as well as award.
ii. The Consultants should prefer to field as many of their permanent staff as
possible. The permanent staff would be considered those already employed
with the firm prior to one year from the month during which this Tender Notice
is issued. Applicant shall submit the details of the period of employment of the
proposed personnel with the firm.
iii. A good working knowledge of the language specified in the data sheet is
essential for key professional staff on this assignment. Reports must be in the
language (s) specified in the data sheet
3.4 Your Technical Proposal must provide the following information, using but not limited
to the formats attached in the Section 3 & 4.
Page 12 of 229
Surface defects detection and roughness measurement using Network
Survey Vehicle
Pavement strength measurement using FWD
Bridge inspection using Mobile Bridge Inspection Unit
Road signs inspection using Retro Reflectometer
vii. Proposed Quality Audit Methodology including Quality Assurance Plan
viii. In case the Consultant envisages outsourcing any or all of the above services to
the expert agencies, the details of the same indicating the arrangement made
with the agencies need to be furnished. These agencies would however, be
subject to approval of the client to ensure quality input by such agencies before
award of the work. For out-sourced services, proposed firms/consultants
should have such experience on similar projects.
ix. The composition of the proposed staff team, the tasks which shall be assigned
to each and their timing;
x. Requirement for submission of CVs.
a. The CVs of following [six key personnel in the format as per Appendix- B-6 is
to be furnished on INFRACON portal.
[Team leader cum Senior Highway Engineer, Resident cum Highway Engineer,
Bridge/Structural Engineer, Senior Pavement Specialist, Senior Quality cum
Material Expert and Road Safety Expert in case of Normal Highway Project]
It may please be ensured that the format is strictly followed and the
information furnished therein is true and correct. The CV must indicate the
work in hand and the duration till which the person will be required to be
engaged in that assignment. The Firm shall ensure that details furnished in
the CV by the personnel are correct. If any information is found incorrect, at
any stage, action including termination and debarment from future NHIDCL
projects for a minimum period of 2 years may be taken by NHIDCL on the
personnel and the Firm.
b. Key information should include years with the firm and degree of
responsibility held in various assignments. In CV format, at summary, the
individual shall declare his qualification & total experience (in years) against
the requirements specified in TOR for the position (Ref. Enclosure-B of TOR).
If any information is found incorrect, at any stage, action including termination
and debarment from future NHIDCL projects upto 2 years may be taken by
NHIDCL on the personnel and the firm.
c. CVs of Key Personnel having intermittent inputs will be considered only if the
assignments on hand as on 7 days before due date of proposal including those
for which LOA has been received from the Client or for which Consultant has
been declared as H1 are such that the key personnel is able to proportionately
devote the given man months for this project.
d. All the CVs which are to be evaluated should be complete in all respects
including signing and certification by the individual and the firm.
xi. Deployment Schedule for each key personnel should be formulated and
incorporated in the Technical Proposal which will be reviewed on quarterly
basis.
xii. Estimates of the total time effort (person x months) to be provided for the
services, supported by bar chart diagrams showing the time proposed (person
x months) for each professional staff and sub professional staff.
xiii. Any additional information.
3.5 The technical proposal must NOT include any financial information.
3.6 Your Financial Proposal must be strictly using the formats attached in Section 5. No
additional items/quantities other than that specified in the formats should be proposed
by the Consultants since the same shall not be considered for the evaluation/award.
Consultants shall be paid billing rates for services as per financial proposal submitted
by them basis. Beginning 13th months from the last date of submission of bid, billing
rates shall be increased to cover all items of the contract i.e. remuneration, vehicle hire,
office rent, consumables, furniture etc. @ 5% every 12 months. However, for evaluation
and award of the Bid proposals, the quoted initial rate (as applicable for first 12 months
from last date of submission of bid) shall be multiplied by the total time input for each
position on this contract, i.e. without considering the increase in the billing rates. All
payments shall be made in Indian Rupees and shall be subjected to applicable Indian
Page 14 of 229
laws withholding taxes if any.
3.7 The Financial Proposal should clearly identify as a separate amount, the local taxes
(including social security), duties, fees, levies and other charges imposed under the
applicable law, on the consultants, the sub-consultants, and their personnel (other than
nationals or permanent residents of the government’s country); unless the Data Sheet
specifies otherwise. This cost, however, will not be considered in evaluation.
3.8 Consultants may express the price of their services in the Indian Rupees only.
3.9 Goods & Service tax as applicable shall be paid to the Consultant while making payment
for services rendered. The consultants shall then deposit the same with the tax
authorities and provide a proof of having done so within next 90 days in line with policy
circulars issued by Employer. Employer shall pay only the Goods & service tax.
A. Detailed RFP may be downloaded from E-tendering portal of Employer and the
Application may be submitted online following the instructions appearing on the
screen.
B. The following shall be the form of various documents in the Application:
(III) Online Payment Receipt towards cost of RFP of Rs. 5,000/- (Rupees Five
thousand only) in favour of NHIDCL.
(IV) Bidders have to comply with the OM No. 13030/09/2008-vig dated 28th
January, 2013(copy enclosed) regarding Integrity pact.
C. The successful bidder shall submit the original documents specified above in point
no.4.1 B (I) (a), (b), (c)& (d) above together with their respective enclosures to the
Authority before signing of the Agreement.
i.) The Applicant shall upload scanned copies of the Technical Proposal and Financial
Proposal as specified in point nos. 4.1 (B) (I) ,(II), (III) & (IV) above on the E-
tendering portal of Employer before 11:00 hours Indian Standard Time on the Bid
due date i.e. on 28.02.2020. Financial Proposal is to be submitted online only and
Page 15 of 229
no hard submission is to be made.
(i) The Bidder may modify, substitute or withdraw its e- bid, prior to the Bid Due Date. No
Bid shall be modified, substituted or withdrawn by the Bidder on or after the Bid Due
Date.
(ii) Any alteration/ modification in the Bid or additional information supplied subsequent
to the Bid Due Date, unless the same has been expressly sought for by the Employer,
shall be disregarded.
(iii) For modification of e-bid, bidder has to detach its old bid from e-tendering portal and
upload / resubmit digitally signed modified bid.
(iv) For withdrawal of bid, bidder has to click on withdrawal icon at e-tendering portal and
can withdraw its e-bid.
(v) Before withdrawal of a bid, it may specifically be noted that after withdrawal of a bid
for any reason, bidder cannot re-submit e-bid again.
(i) Opening of Proposals will be done through online for both Financial Proposal and
Technical Proposal.
(ii) For participating in the tender, the authorized signatory holding Power of Attorney
shall be the Digital Signatory. In case the authorized signatory holding Power of
Attorney and Digital Signatory are not the same, the bid shall be considered non-
responsive.
The Employer will open the Technical Proposal at 11:30 hours Indian Standard Time
on 02.03.2020 in the presence of the Applicants who choose to attend and evaluate
the Applications in accordance with the provisions set out in the RFP.
(iii) The Financial Proposal will be opened of the short listed applicants who qualify for
financial opening as per RFP. The date of opening of Financial Proposal will be notified
later on.
Page 16 of 229
5 PROPOSAL EVALUATION
5.1 A two -stage procedure shall be adopted for evaluating the proposals.
5.2 Deleted
Technical Proposal
5.3 The Evaluation Committee appointed by the Employer shall carry out its evaluation
applying the evaluation criteria and point system specified in the data sheet. Each
responsive proposal shall be attributed a technical score (ST.) Only those Applicants
whose Technical proposal score 75 marks or more out of 100 shall qualify for further
consideration. However, if the number of such pre-qualified applications is less than
two, the Employer may, in its sole discretion, pre-qualify the applicant(s) whose
technical score is less than 75 marks.
Financial Proposal
5.4 After the evaluation of Technical Proposals is completed and the shortlist of firms is
finalized, the Employer may notify those consultants whose proposals were not
considered as per conditions of RFP. The Employer shall simultaneously notify the
shortlisted firms indicating the date and time set for opening of the Financial Proposals.
5.5 The Financial Proposals shall be opened publicly in the presence of the consultants’
representatives who choose to attend. The name of the consultant, the technical scores,
and the proposed prices shall be read aloud and recorded when the Financial Proposals
are opened. The Client shall prepare minutes of the public opening.
5.6 The Evaluation Committee will determine whether the submitted Financial Proposals
are complete (i.e. whether they have included cost of all items of the corresponding
proposals; if not, then the cost towards such missing items will be considered as NIL,
but the Consultant shall, however, be required to carry out such obligations without
any additional compensation.) and without computational error. In case under such
circumstances, if Client feels that the work cannot be carried out within the overall cost
as per the submitted financial proposal, such proposals shall be considered non
responsive.
5.7 The lowest financial proposal (FM) will be given a financial score (SF) of 100 points.
The financial scores of other proposals will be computed as follows:
5.8 Proposals will finally be ranked according to their combined technical (ST) and
financial (SF) scores as follows:
S= ST x Tw+SF x Fw
Where S is the combined score, and Tw and Fw are weights assigned to Technical
Proposal and Financial Proposal that shall be 0.70 and 0.30 respectively.
Page 17 of 229
5.9 The selected Authority’s Engineer shall be the first Ranked Applicant (H-1, having the
highest combined score). In the event the proposals of two or more consultants have
the same scores in the final ranking, the proposal with the highest technical score
should be ranked first.
6 AWARD OF CONTRACT
6.1 The Client shall issue letter of award to selected Consultant and ask the Consultant to
provide Performance Security as in Para 7 below. If the selected Consultant fail to
provide performance security within the prescribed time or the Consultant fail to
sign the Contract Agreement within prescribed time, the Client may invite the 2 nd
highest ranking bidder Consultant and follow the procedure outlined in Para 6 and
8 of this Letter of Invitation.
7 PERFORMANCE SECURITY
7.1 The successful consulting firm shall have to submit a Bank Guarantee (BG) for an
amount of 10% of the Contract Value within 15 days of issue of LOA. The BG shall be
valid for a period of [84+2] i.e. upto 2 months beyond the expiry of the Contract
period of [84 months]. The BG shall be in the format specified in Appendix H of draft
contract form and furnished from a Nationalised Bank, IDBI or ICICI/ICICI
Bank/Foreign Bank/EXIM Bank / Any Scheduled Commercial Bank approved by RBI
having a net worth of not less than 1000 crore as per latest Annual Report of the
Bank. In the case of a Foreign Bank (issued by a Branch in India) the net worth in
respect of Indian operations shall only be taken into account. In case of Foreign Bank,
the BG issued by Foreign Bank should be counter guaranteed by any Nationalised
Bank in India. In case of JV, the BG shall be furnished on behalf of the JV and not
individually by the members.
Further, in case where the bid of the successful consulting firm is less than 85% of the
average of all bids received, the successful consulting firm shall have to submit an
Additional Performance Security (APS) in the form of a Bank Guarantee for 30% of
the differential value between the successful bid and average of all the bids received.
The BG shall be valid for a period of [84+2] months i.e. upto 2 months beyond the
expiry of the Contract of [84] months. The other requirements of APS are same as
those of Performance Security.
7.2 In the event the Consultant fails to provide the security within 15 days of date of LOA,
it may seek extension of time for a period of 15 (Fifteen) days on payment of damages
for such extended period in a sum of calculated at the rate of 0.1% (Zero Point One
Percent) of the contract price for each day until the performance security is provided.
For the avoidance of doubt the agreement shall be deemed to be terminated on expiry
of additional 15 days time period.
7.3 Notwithstanding anything to the contrary contained in this Agreement, the Parties
agree that in the event of failure of the Consultant to provide the Performance
Security in accordance with the provisions of Clause 7.1 within the time specified
Page 18 of 229
therein or such extended period as may be provided by the Authority, in accordance
with the provisions of Clause 7.2 and thereupon all rights, privileges, claims and
entitlements of the Consultant under or arising out of this Agreement shall be deemed
to have been waived by, and to have ceased with the concurrence of the Consultant,
and LoA shall be deemed to have been withdrawn by mutual agreement of the Parties.
Authority may take action debar such firm for future projects for a period of 1-2 years.
After having received the performance security and verified it, the Client shall invite
the selected bidder for signing of Contract Agreement on a date and time convenient
to both parties within 15 days of receipt of valid Performance Security.
Page 19 of 229
DATASHEET
2 The proposal shall be valid for 120 days after the last date of submission.
3 Clarification may be requested 7 days prior to Pre Proposal Conference. The address
for requesting clarification is:
Address of Employer:
5 All the personnel shall have working knowledge of English and all the reports etc shall
be written in English.
6 NHIDCL shall reimburse only Goods and service tax. Authority’s Engineer has to
assess all other taxes and should inbuilt them in their financial proposal. These taxes
(other than Goods and service tax) should not be provided separately. Consultants are
requested to consult Tax Consultants for details.
7. The Consultants to ensure that their firms and key personnel should register their
credentials / modules on www.infracon.nic.in as stipulated in MoRT&H Circular No.
RW-NH-35075/1/2010-S&R® dt. 28.10.2015.
Page 20 of 229
i. Sub criteria for Relevant Experience of the firm for the assignment
Average Annual Turnover (last 3 years) from consultancy business (Min 5 crore) 2
Nos of Highway Professionals with the firm * The professionals who possess degree in Civil 10
Engineering/Transport Planning/Transport Economics/Traffic Management / Geology/
Environment Science or Engineering and 8 years experience in highway/bridge/tunnel with
employment in the firm for more than one year. The current Employment Certificate shall be
uploaded by Key Personnel on INFRACON.
Experience as Independent Engineer/Authority Engineer/Construction Supervision in Number of 10
Highway Projects of length equal to 40% of project length of similar category for which RFP invited
of 2/ 4/6**-laning or more in last 7 years*
Experience in DPR preparation for Number of Highway Projects (of length 40% of project length 5
of similar category for which RFP invited of 2/4/6**-laning or more) in last 7 years *
In hand DPRs for Authority (Ministry /NHAI/NHIDCL-As applicable) Projects (presently under 10
progress)
Experience in Construction Supervision/DPR /Design Review of Major structures having length 3
of more than 500 meter in last 7 years.
* Consultants should give details of the experience of the firm considering the
completed and the on-going highway assignments, separately for PPP and non-PPP
Projects along with experience certificates from clients. This list of the completed
works should also include those assignments which are substantially (90% of
Contract value) completed. No Qualification/Experience etc. shall be considered
without proof of experience.
** Similar projects means 2/4/6 lane as applicable for the project for which RFP is
invited. For 2-lane projects, experience of 4/6 lane also to be considered with a
multiplication factor of 1.5. Experience of 4/6 lane shall be considered
interchangeably for 4/6 laning projects. For 4/6 laning projects, experience of 2 lane
will be considered with a multiplication factor of 0.4, but only for those 2 lane projects
whose cost of consultancy services was more than Rs.3.0 crores.
In case of JV the turnover and experience details of Lead and JV Employer’s certificate
should be submitted substantiating the experience claimed by the firm.
Page 21 of 229
ii. Sub criteria for Experience in use of technology for road inspection
Sr. Maximum
Description Sub-Points
No. Points
Experience in Network Survey Vehicle (NSV) or better
1 7
technology for pavement inspection
1.1 Equipment 4
(a) Equipment on MOU with Associate or on hiring basis 2
(b) Own Equipment 4
1.2 Experience 3
(a) 1-2 projects 1
(b) 3-5 projects 2
(c) >5projects 3
Experience in Falling Weight Deflectometer (FWD) or better
2 4
technology for pavement strength measurement
2.1 Equipment 2
(a) Equipment on MOU with Associate or on hiring basis 1
(b) ) Own Equipment 2
2.2 Experience 2
(a) 1-3 projects 1
(b) > 3 projects 2
Experience in Mobile Bridge Inspection Unit or better
3 5
technology for bridge inspection
3.1 Equipment 2
(a) Equipment on MOU with Associate or on hiring basis 1
(b) Own Equipment 2
3.2 Experience 3
(a) 1-2 projects 1
(b) 3-5 projects 2
(c) 5 projects 3
4 Experience in Retro reflectometer technology 4
4.1 Equipment 2
a) Equipment on MOU with Associate or on hiring basis 1
(b)Own Equipment 2
4.2 Experience 2
(a)1-3 projects 1
(b)> 3 projects 2
Total 20
Note: A. The Authority’s Engineer owning the equipments shall be required to submit
proof of ownership.
B. The experience of the associate firms in use of technology shall also be counted in
the evaluation. The experience of firm or associate firm in NSV or equivalent
technology, FWD or equivalent technology, MBIU or equivalent technology and Retro
reflectometer or equivalent technology shall be supported by experience certificate.
The experience of a firm/associate firm for a private concessionaire/contractor shall
not be considered.
Page 22 of 229
Qualification and competence of following professional/sub-professional staff
for the assignment shall be evaluated. The weightage for various key staff are as under:-
General qualifications 25
Total 100
The technical proposal should score at least 75 points to be considered responsive for
financial evaluation.
v) Detailed evaluation criteria which is to be used for evaluation of technical bids is as
indicated below as Appendix-EC.
vi) The Authority’s Engineer should carryout self-evaluation based on the evaluation criteria
at Appendix-EC. While submitting the self-evaluation along with bid, Authority’s
Engineer shall make references to the documents which has been relied upon in his self-
evaluation.
vii) Result of technical evaluation shall be made available on the website giving opportunity to
the bidders to respond within 7 days in case they have any objection.
viii) The single currency for price conversion is INR. For evaluation of bid proposals, the
foreign currency conversation rate of 1US Dollar = Rs. And 1 Euro = Rs. shall be used.
(This will be the exchange rates as per Reserve Bank of India rounded off to nearest
Ruppe applicable at the time of RFP invitation).
11 Commencement of Assignment: The firm shall begin carrying out the services within one
month of signing of the Consultancy Agreement.
12 The NHIDCL’s Bank Account detail is as given below: (REF. PARA 8 of NIT)
Page 23 of 229
Sl
Particulars Details
No
National Highways & Infrastructure
1. Name of Beneficiary
Development Corporation Limited
2. Beneficiary Bank Account No. 90621010002659
Syndicate Bank, Transport Bhawan,
Beneficiary Bank Branch Name and
3. 1st Parliament Street, New
Address
Delhi110001
4. Beneficiary Bank Branch IFSC SYNB0009062
5. SWIFT Code (For Foreign Bidders) SYNBINBB126
Page 24 of 229
Appendix-EC
Page 25 of 229
Reference/Details of Marks self-
Max.
S. No. Description projects Claimed for assessed by
Marks
self-assessment the bidder
5.3 >5 10
6 Experience in Construction Supervision/DPR/Design 3
Review of Major structures having length of more
than 500 meter in last 7 years.
1 project – 2.0 marks Add 0. 5 (Zero point five) marks
extra for each additional project subject to maximum
1.0 marks
Note 1: In case of JV, the turnover and experience details of Lead and JV partners to be added.
Note 2: Employer’s certificate/ certificate from Statutory Auditor should be submitted
substantiating the experience/turnover claimed by the firm.
Note 3: ** For 4/6 laning projects, experience of 2 lane will be considered with a
multiplication factor of 0.4, but only for those 2 lane projects whose cost of consultancy
services was more than Rs.3.0 crores.
Evaluation sheet for assessment of experience in use of technology for road inspection
Reference/Details Marks self-
S. Maximum of projects assessed
Description
No Points Claimed for self- by the
assessment bidder
Experience in Network Survey Vehicle (NSV) or
1 7
better technology for pavement inspection
1.1 Equipment 4
(a) Equipment on MOU with Associate or on hiring
basis- 2 marks
(b) Own Equipment – 4 marks
1.2 Experience 3
(i) 1-2 projects 1
(ii) 3-5 projects 2
(iii) > 5 projects 3
Experience in Falling Weight Deflectometer (FWD) or
2 better technology for pavement strength 4
measurement
2.1 Equipment 2
Page 26 of 229
Evaluation sheet for assessment of experience in use of technology for road inspection
Reference/Details Marks self-
S. Maximum of projects assessed
Description
No Points Claimed for self- by the
Assessment bidder
(a) Equipment on MOU with Associate or on hiring
basis- 1 mark
(b) Own Equipment – 2 marks
2.2 Experience 2
(i) 1-3 Projects 1
(ii) >3 Projects 2
Experience in Mobile Bridge Inspection Unit or better
3 5
technology for bridge inspection
3.1 Equipment 2
(a) Equipment on MOU with Associate or on hiring
basis- 1 mark
(b) Own Equipment – 2 marks
3.2 Experience 3
(i) 1-2 Projects 1
(ii) 3-5 Projects 2
(iii) > 5 Projects 3
4 Experience in Retro reflectometer technology 4
4.1 Equipment 2
(a) Equipment on MOU with Associate or on hiring
basis- 1 mark
(b) Own Equipment – 2 marks
Execution with owned/hired Equipment/through
4.2 2
Associate
(i) 1-3 Projects 1
(ii) >3 Projects 2
Total 20
Notes:
(i) The Consultants owning the equipment shall be required to submit proof of ownership.
(ii) The experience of the associate firms in use of technology shall also be counted in the evaluation.
The experience of firm or associate firm in NSV or equivalent technology, FWD or equivalent
technology, MBIU or equivalent technology and Retro reflectometer or equivalent technology
shall be supported by experience certificate. The experience of a firm/ associate firm for a
private concessionaire/ contractor (client) shall be considered on self-certification along with
the client certificate. Any false certification shall attract provisions of Clause 1.8, Section -2
(letter of Invitation) read with Clause 2.9.1(g) of GCC
Page 27 of 229
3 Evaluation Criteria for assessment of score of Key Staff for adequacy of the
Assignment.
Page 28 of 229
Reference/Details of Marks self-
Max.
S. No. Description projects Claimed for assessed by
Points
self-assessment the bidder
2 Projects -11 marks
Add 2 marks for each additional project subject to
maximum 4 marks.
Total : 100
Note:
(2) Only those projects will be considered for evaluation at S. No. 2(b) where the input of the
personnel is not < 9 months.
(3) Only those projects will be considered for evaluation at S. No. 2I, (d) where the input of the
personnel is not < 12 months.
Page 29 of 229
(4) In case of experience on behalf of Authority’s Engineer or Contractor, the experience shall be
duly endorsed by the respective Government agency. In case of non-availability of endorsement
from Govt. Agency, the experience uploaded on INFRACON Portal will be taken into
consideration. However, the key personnel/ bidder will be solely responsible for any fake
information/ CV, which may result in debarment.
Page 30 of 229
Reference/Details of Marks self-
Max.
S. No. Description projects Claimed for assessed by
Points
self-assessment the bidder
(of length 40% of project length or more of similar
configuration (2/4/6 laning**) and above)
1 Project- 4 marks
Add 1 (one) mark extra for each additional project
subject to maximum 1 (one) mark
3 Employment with the Firm 5
< 1 year -0
1 year – 3 marks
Add 0.5 marks for each subsequent year subject to
maximum 2 marks
Total : 100
Note:
(2) Only those projects (in numbers) will be considered for evaluation above, where the input of
the personnel is not < 12 months
(3) In case of experience on behalf of Authority’s Engineer or Contractor, the experience shall be
duly endorsed by the respective Government agency. In case of non-availability of endorsement
from Govt. Agency, the experience uploaded on INFRACON Portal will be taken into
consideration. However, the key personnel/ bidder will be solely responsible for any fake
information/ CV, which may result in debarment.
(1)
Page 31 of 229
Professional Experience
i) Total Professional Experience in handling 15
Highway/Bridge projects
< 10 years -0
10 years -11
Add one mark extra for each additional year of
experience subject to maximum 4 (four) marks.
ii) Experience in similar capacity in 25
Construction/Construction Supervision of major
Highway Projects ((similar configuration (2/4/6
laning**) and above))
< 5 years -0; 5 years -19
Add 2.0 (two) marks extra for each additional year of
experience subject to maximum 6 (Six) marks.
iii) Experience in similar capacity in handling Similar 30
Highway projects (of length 40% of project length or
more of similar configuration (2/4/6 laning**) and
above)
< 2 nos. -0
2 nos. - 25
Add 2.5 marks extra for each additional project
subject to maximum 5 (five) marks.
3 Employment with the Firm 5
< 1 year – 0
1 year – 3
Note:
(2) Only those projects (in numbers) will be considered for evaluation above, where the input of
the personnel is not < 12 months
(3) In case of experience on behalf of Authority’s Engineer or Contractor, the experience shall be
duly endorsed by the respective Government agency. In case of non-availability of endorsement
from Govt. Agency, the experience uploaded on Infracon Portal will be taken into consideration.
However, the key personnel/ bidder will be solely responsible for any fake information/ CV,
which may result in debarment.
(1)
Page 32 of 229
3.6 Senior Quantity Surveyor
Reference/ Marks
Details of self-
projects assess
Sr. Max.
No.
Description
Points
Claimed for ed by
self- the
assessme bidder
nt
1 General Qualification 25
I) Graduate in Civil Engineering 20
Post Graduate in Construction Management/ Post Graduate in
Construction Engineering/ Certificate Course in Management/
II) Certificate Course in Construction Management/ Certificate 5
Course in Contract Management or equivalent
i) Experience in India 10
Minimum 2 Years 7.5
Additional 1.25 marks for each additional year 2.5
ii) Experience in North East Region 5
Minimum 1 Years 3.75
Additional 1.25 marks for additional year 1.25
Total: 100
Page 33 of 229
i) Total Professional Experience in handling Highway/Bridge 15
projects
< 10 years -0
10 years -11 marks
Add one mark extra for each additional year of experience
subject to maximum 4 (four) marks.
ii) Experience in similar capacity in Road Safety works on 15
Major Highway Project (similar configuration (2/4/6 laning**)
and above).
< 5 years -0
5 years -11 marks
Add one mark extra for each additional year of experience
subject to maximum 4 (four) marks.
iii) Experience in similar capacity in Road Safety Audits of 2/4/6- 20
laning** Highway projects at different stages including at
least one at design stage
< 2 nos. -0
2 nos. -15 marks
Add 2.5 marks extra for each additional project subject to
maximum 5 marks.
iv) Experience in similar capacity in identification and 10
improvement of black spots on Major Highway Project
(similar configuration (2/4/6 laning**) and above)
< 2 nos. -0
2 nos. -8 marks
Add 2 marks extra for each additional improvement of black
spots subject to maximum 2 marks.
v) Experience in similar capacity of preparing Road Safety 5
Management Plans for Inter Urban Highway
1 project -4 marks
2 or more -5 marks
vi) Experience in similar capacity in field of Road Safety 5
Management Plan
1 project -4 marks
2 or more -5 marks
3 Employment with the Firm 5
<1 year- 0
1 year – 3 marks
Add 0.5 marks for each subsequent year subject to
maximum 2 marks
Total : 100
Note:
(1) Similar Capacity includes the following positions
Page 34 of 229
i) On behalf of Consultant/Contractor: Road Safety Expert
ii) In Government Organizations: Executive Engineer (or equivalent) and above
(2) Only those projects (in numbers) will be considered for evaluation above, where the input of
the personnel is not < 6 months
Page 35 of 229
SECTION 3: FORMATS FOR SUBMISSION OF FIRMS CREDENTIALS
The proposal should contain the following information in enclosed format attached at
Appendix A.
Year of Establishment of Firm
Average annual turnover (last three years)
Note: The Firm shall submit Certificate of Incorporation and audited balance sheet for the
last three years [FY 2016-2017, FY 2017-2018 and FY 2018-2019]. For claiming
experience of Highway projects, completion certificate from employer should be
enclosed. The proposal should also contain the details of the key personnel viz. their
name, qualification, expertise area, experience and years of association with the firm.
Page 36 of 229
Appendix A
The following information related to the firm should be provided in the proposal.
i. Name of the package applied for:-
ii. Year of establishment of firm*
Consultant Year of Countr Type of Organization
Establish y Individual Partnership Corporation Other
ment
Individual / Lead Partner
(of JV)/ Minor Partner of
JV/Associate
NOTE:- Year of Establishment of Lead Partner of JV shall be considered.
*Copy of Certificate of incorporation shall be submitted.
iii. Office/ Business Address/Telephone nos. /Cable Address.
iv. Narrative description of firm (Not more than 2 sheets)
v. Name of two (2) principals who may be contacted with title and telephone
number/fax number/e-mail.
vi. Financial Statement of the last three years. **
Sl. No. Particular <2016-17> < 2017-18> <2018-19>
i. Annual turnover from Consulting business
ii. Total Assets
iii. Current Assets
Balance Sheet/ Auditor Certificate of last 3years <2016-17, 2017-18 and 2018-19> shall be
submitted as evidence of Annual Turnover.
** a) The amount shall be stated in INR. (Consider 1US Dollar = Rs. And 1 Euro =
Rs.) (This will be the exchange rates as per Reserve Bank of India rounded off to
nearest Rupee applicable at the time of RFP invitation).
b) The currency conversion rate for the respective years shall be mentioned for
other International currencies.
vii. Experience as Authority Engineer/Independent Consultant/Construction
supervision of Highway projects, separately for PPP and non-PPP Projects during
the last 7 years. ***
S Projects Type of Description Client (with Total Fee Fee received %age of Approx. Period
No Name / Year Services of Highway complete for the by Applicant (in total fee Cost of
Sole rendered Project/ address, Consultancy case of received Highway
Consultant/ Length contact Assignment JV/Association) by the Project
Prime (kms) person, (INR) firm
Consultant of Telephone
JV / minor Nos. and
Authority’s Fax Nos.)
Engineer of
JV/ /as
associate
consultant
1 2 3 4 5 6 7 8 9 10
A. Completed / Substantially completed projects:
Page 37 of 229
S Projects Type of Description Client (with Total Fee Fee received %age of Approx. Period
No Name / Year Services of Highway complete for the by Applicant (in total fee Cost of
Sole rendered Project/ address, Consultancy case of received Highway
Consultant/ Length contact Assignment JV/Association) by the Project
Prime (kms) person, (INR) firm
Consultant of Telephone
JV / minor Nos. and
Authority’s Fax Nos.)
Engineer of
JV/ /as
associate
consultant
1.
2.
3.
B. Projects in progress:
1.
2.
3.
viii. Experience in DPR/ Feasibility Study cum Preliminary Design Report preparation of
2/4/6 laning / Bridge Highway Projects separately for the PPP and non-PPP projects
during the last 7 years. ***
S No Projects Name / Type Length Client Total Fee Fee received by %age of Period
Year of (with for the Applicant total fee
Sole of Project Complete Consultancy (in case of received
Consultant/ Services (kms) address, Assignment JV/Association) by the firm
Prime Rendered contact (INR) ca
Consultant of JV / person, se of JV)
minor Authority’s telephone
Engineer of JV/ /as Nos. and
associate Fax Nos.)
consultant
1 2 3 4 5 6 7 8 9
***a) 2/4/6 lane/Bridge work as applicable for the project for which RFP is invited. For 2-
lane projects experience of 4/6 lane also to be considered with a multiplication factor
of 1.5. Experience of 4/6 lane shall be considered interchangeably for 4/6 laning
projects. For 4/6 lane projects, experience of 2 lane will be considered with a
multiplication factor of 0.4, but only for those 2-lane projects whose cost of consultancy
services was more than Rs.3.0 crores. For standalone bridge projects, experience in
bridge work (either standalone project or as a part of road project) only be considered.
b) Only those projects, to be included in the table which are Highways Projects and for
which clients certificates from the concerned Government agencies are enclosed with
the proposal.
c) The details of bridges having length more than 200m (500m in case the project consist
of bridges of length more than 500m) in the listed projects is to be specifically
mentioned.
d) The weightage given for experience of a firm would depend on the role of the firm in
the respective assignments. The firm’s experience would get full credit if it was the
sole firm in the respective assignment. If the applicant firm has completed projects as
Page 38 of 229
JV with some other firms, weightage shall be given as per the JV share***. However if
the applicant firm has executed the project as associate with some other firms, 25%
weightage shall be given to the applicant firm for the projects completed under such
association
e) For weightage of experience in any past Consultancy assignment, experience
certificate from the client shall be submitted. In absence of clear demarcation of JV
share in client certificate, the weightage will be treated as 60 % for lead partner and
40% for minor partner. Annual turnover duly certified by Chartered Accountant shall
be accepted. In case of non-availability of such documents no weightage of
turnover/experience will be considered.
(ix)Assignments on hand including those for which the Letter of Acceptance from the
clients received as on 7 days prior to due date for submission of proposals: The
details shall be given in the following format.
S. Name of Client Role of the firm Date of Date of Present Team Members provided
No Assignment letter of Agreement status of by the firm
Sole, Lead/ Acceptance if signed Assignment
Other in JV or
sub-consultant
Name DOB Position
(1) (2) (3) (4) (5) (6) (7) (8) (9) (10)
Page 39 of 229
SECTION 4: FORMAT FOR SUBMISSION OF TECHNICAL PROPOSAL
Page 40 of 229
APPENDIX B-1-Technical proposal submission form.
Ladies/Gentlemen:
Subject: Submission of Technical and Financial Proposal for engagement as Authority
Engineer for the EPC work of Consultancy Services as Authority’s Engineer for
Supervision of “Rehabilitation and Up-gradation to 2 lane with paved shoulders of
Seling-Dulte section (Economic Corridor) of NH-6 from Existing chainage Km 0+000 to
Km 69+015 (Design Chainage Km 0+000 to Km 62+200) in the state of Mizoram under
Bharatmala Pariyojna on EPC mode.”
We, the undersigned, offer to provide the consulting services for the above in accordance with
your Request for Proposal dated (Date), and our Proposal. We are hereby submitting our
Proposal, which includes this Technical Proposal and a Financial Proposal sealed under a
separate envelope for the above mentioned work.
My/Our registration No. on Infracon is ……. And my/our Infracon Team ID is …………….
Our Proposal is binding upon us. We understand you are not bound to accept any Proposal you
receive
We remain,
Yours sincerely,
Page 41 of 229
APPENDIX B-2: SITE APPRECIATION
Shall give details of site as per actual site visit and data provided in RFP and collected from site
supported by photographs to demonstrate that responsible personnel of the Authority’s
Engineer have actually visited the site and familiarized with the salient details/ complexities
and scope of services.
Page 42 of 229
APPENDIX B-3: APPROACH PAPER ON METHODOLOGY FOR PERFORMING THE
ASSIGNMENT
The approach and methodology will be detailed precisely under the following topics.
1) Methodology for services, surveying, road condition data collection and analysis [not
more than 2 pages]
2) Key challenges foreseen and proposed solutions in carrying out the assignment [not
more than 1page]
3) Quality Audit methodology including Quality Assurance Plan [not more than 6 pages]
Page 43 of 229
APPENDIX B-4 : FACILITY FOR FIELD INVESTIGATION AND TESTING
1. State whether applicant has in-house (created in house at site)/ outsourced/ not
available facility for
Surface defects detection and roughness measurement using Network Survey
Vehicle
Pavement strength measurement using FWD
Bridge inspection using Mobile Bridge Inspection Unit
Road signs inspection using Retro Reflectometer
2. In-case answer to 1 is available (created in house at site) a list of field investigation and
testing equipment is to be attached
4. For experience in NSV, FWD, MBIU and reflectometer, references need to be provided
in the following format:
REFERENCES
The following information should be provided in the format below for each reference
assignment for which your firm, either individually as a corporate entity or as one of the major
companies within a consortium, was legally contracted by the client:
Page 44 of 229
APPENDIX B-5: COMPOSITION OF THE TEAM PERSONNEL, AND TASK(S) OF
EACH TEAM MEMBER
2. Technical/Managerial Staff
Sl. No. Name Position Task
1
i. Support Staff
Page 45 of 229
APPENDIX B-6 : FORMATOF CURRICULUM VITAE (CV) FOR PROPOSED
PROFESSIONALSTAFF
Name of Firm:........................................................................................
Name of Staff :........................................................................................
Profession :..............................................................................................
Date of Birth :
Years with Firm/Entity: ...........................................Nationality:.............................. Membership of
Professional Societies :.........................................................................
Detailed Task Assigned : Please attach printout of CV along with all the relevant details
uploaded on infracon portal.
I, the undersigned,(Name and Address) undertake that this CV correctly describes myself, my
qualifications and my experience and Employer would be at liberty to debar me if any
information given in the CV, in particular the Summary of Qualification & Experience vis-à-vis
the requirements as per TOR is found incorrect. I further undertake that I have neither been
debarred by NHIDCL or any other central/stage government organization nor left any
assignment with the consultants engaged by Employer / contracting firm (firm to be
supervised now) for any continuing work of Employer without completing my assignment. I
will be available for the entire duration of the current project (named… ). If I leave this
assignment in the middle of the work, Employer would be at liberty to debar me
from taking any assignment in any of the Employer works for an appropriate period
of time to be decided by the Employer. I have no objection if my services are extended by
the Employer for this work in future.
I further undertake that my CV is being proposed for this project by --------- (the applicant firm)
and I have not given consent to any other consultant(s) to propose my CV for any position for
this project.
I further undertake that if due to my inability to work on this project due to unavoidable
circumstances, due to which consultant’s firm is forced to seek replacement. In such
unavoidable circumstances, I shall not undertake any employment in Employer projects during
the period of assignment of this project and Employer shall consider my CV invalid till such
time.
Page 46 of 229
For Key Personnel having intermittent inputs, add the following:
I further certify that I am associated with the following assignments as on date (as on 7 days
prior to due date for submission of proposal) including those for which LOA has been received
by the firm and the inputs in these assignments shall not effect the work of the current
assignment.
Name of Assignment Client Date of Likely start Likely end Total input of the
LOA (Month / Year) (Month / Year) person (man-
months)
………………………………………………………….. Date
(Signature of Key Personnel)
(Day/Month/Year)
The Authority’s Engineer should carryout self-evaluation based on the evaluation criteria at
Appendix-EC and furnish the same here. While submitting the self-evaluation along with bid,
Authority’s Engineer shall make references to the documents which have been relied upon in
his self-evaluation.
The undersigned on behalf of ----------( name of consulting firm) certify that Shri-------- (name
of proposed personnel) to the best of our knowledge has neither been debarred by NHIDCL or
any other Central/State Government organization nor left his assignment with any other
consulting firm engaged by the Employer /Contracting firm(firm to be supervised now) for the
ongoing projects. We understand that if the information about leaving the past assignment is
known to the Employer, Employer would be at liberty to remove the personnel from the
present assignment and debar him for an appropriate period to be decided by the Employer.
a) Deleted.
b) Deleted.
c) Deleted.
d) Deleted.
e) Deleted.
f) Deleted
Page 47 of 229
APPENDIXB-7: TIME SCHEDULE FOR PROFESSIONAL PERSONNEL
A. Activity Schedule
Page 48 of 229
APPENDIXB-8 : ACTIVITY(WORKS)SCHEDULE
B. Activity Schedule
1 Monthly reports
(Design and Construction)
2 Quarterly Reports
Page 49 of 229
APPENDIX B-9: AFFIDAVIT FOR CORRECTNESS OF CV OF KEY PERSONNEL AND
EXPERIENCE CLAIMED BY THE FIRMS
Page 50 of 229
APPENDIX B-10: INTEGRITY PACT
(To be executed on plain paper and submitted along with Technical Bid/Tender documents for
tenders having a value between Rs.5 Cr and 100 Cr. To be signed by the bidder and same
signatory competent/ authorized to sign the relevant contract on behalf of the NHIDCL)
Tender No.
Between
NHIDCL, hereinafter referred to as “The Principal”, which expression shall unless repugnant to
the meaning or contract thereof include its successors and permitted assigns.
And
Preamble
Whereas, the Principal intends to award, under laid down organizational procedures,
contract/s Consultancy services for Authority’s Engineer for Supervision of
“Rehabilitation and Up-gradation to 2 lane with paved shoulders of Seling-Dulte
section (Economic Corridor) of NH-6 from Existing chainage Km 0+000 to Km 69+015
(Design Chainage Km 0+000 to Km 62+200) in the state of Mizoram under Bharatmala
Pariyojna on EPC mode.” The Principal values full compliance with all relevant laws of the
land, rules of land, regulations, economic use of resources and of fairness/ transparency in its
relations with its Bidder(s) and/ or Contractor(s)/Concessionaire(s)/ Consultant(s).
And whereas to meet the purpose aforesaid, both the parties have agreed to enter into this
Integrity Pact (hereafter referred to as Integrity Pact) the terms and conditions of which shall
also be read as integral part and parcel of the Tender documents and contract between the
parties. Now, therefore, in consideration of mutual covenants stipulated in this pact, the parties
hereby agree as follows and this pact witnesses as under:-
1. The Principal commits itself to take all measures necessary to prevent corruption and
to observe the following principles:-
b. The Principal will, during the tender process treat all Bidder(s) with equity and
reason. The Principal will in particular, before and during the tender process, provide
Page 51 of 229
to all Bidder(s) the same information and will not provide to any Bidder(s)
confidential/ additional information through which the Bidder(s) could obtain an
advantage in relation to the tender process or the contract execution.
c. The Principal will exclude all known prejudiced persons from the process, whose
conduct in the past has been of biased nature.
2. If the Principal obtains information on the conduct of any of its employees which is a
criminal offence under the IPC/PC Act or any other Statutory Acts or if there be a
substantive suspicion in this regard, the Principal will inform the Chief Vigilance Officer
and in addition can initiate disciplinary actions as per its internal laid down
Rules/Regulations.
Page 52 of 229
with the award of the contract. He shall also disclose the details of services
agreed upon for such payments.
(f) The Bidder(s)/ Contractor(s)/ Concessionaire(s)/ Consultant(s) will not
instigate third persons to commit offences outlined above or be an accessory to
such offences.
(g) The Bidder(s)/ Contractor(s)/ Concessionaire(s)/ Consultant(s) will not bring
any outside influence through any Govt. bodies/quarters directly or indirectly
on the bidding process in furtherance of his bid.
4. The Bidder/ Contractor/ Concessionaire/ Authority’s Engineer with its free consent
and without any influence agrees and undertakes to respect and uphold the Principal’s
absolute rights to resort to and impose such exclusion and further accepts and
undertakes not to challenge or question such exclusion on any ground, including the
lack of any hearing before the decision to resort to such exclusion is taken. This
undertaking is given freely and after obtaining independent legal advice.
5. The decision of the Principal to the effect that a breach of the provisions of this Integrity
Pact has been committed by the Bidder/ Contractor/ Concessionaire/ Authority’s
Engineer shall be final and binding on the Bidder/ Contractor/ Concessionaire/
Consultant.
Page 53 of 229
6. On occurrence of any sanctions/ disqualification etc arising out from violation of
integrity pact, the Bidder/ Contractor/ Concessionaire/ Authority’s Engineer shall not
be entitled for any compensation on this account.
7. Subject to full satisfaction of the Principal, the exclusion of the Bidder/ Contractor/
Concessionaire/ Authority’s Engineer could be revoked by the Principal if the Bidder/
Contractor/ Concessionaire/ Authority’s Engineer can prove that he has restored/
recouped the damage caused by him and has installed a suitable corruption prevention
system in his organization.
1. If the Principal has disqualified the Bidder(s) from the tender process prior to the
award according to Arcticle-3, the Principal shall be entitled to forfeit the Earnest
Money Deposit/ Bid Security or demand and recover the damages equivalent to
Earnest Money Deposit/ Bid Security (equivalent to 1% of Contract Price) apart from
any other legal right that may have accrued to the Principal.
2. In addition to 1 above, the Principal shall be entitled to take recourse to the relevant
provisions of the contract related to Termination of Contract due to Contractor/
Concessionaire/Consultant’s Default. In such case, the Principal shall be entitled to
forfeit the Performance Bank Guarantee of the Contractor/ Concessionaire/
Authority’s Engineer and/ or demand and recover liquidated and all damages as per
the provisions of the contract/concession agreement against Termination.
1. The Bidder declares that no previous transgressions occurred in the last 3 years
immediately before signing of this Integrity Pact with any other Company in any
country conforming to the anti corruption/ Transparency International (TI) approach
or with any other Public Sector Enterprise/ Undertaking in India or any Government
Department in India that could justify his exclusion from the tender process.
2. If the Bidder makes incorrect statement on this subject, he can be disqualified from the
tender process or action for his exclusion can be taken as mentioned under Article-3
above for transgressions of Article-2 and shall be liable for compensation for damages
as per Article-4 above.
2. The Principal will enter into agreements with identical conditions as this one with all
Bidders/ Contractors/ Concessionaires/ Consultants and Subcontractors.
Page 54 of 229
3. The Principal will disqualify from the tender process all Bidders who do not sign this
Pact or violate its provisions.
This Pact begins when both parties have legally signed it. (In case of EPC i.e. for projects funded
by Principal and consultancy services). It expires for the Contractor/ Authority’s Engineer 12
months after his Defect Liability period is over or 12 months after his last payment under the
contract whichever is later and for all other unsuccessful Bidders 6 months after this Contract
has been awarded. (In case of BOT Projects) It expires for the concessionaire 24 months after
his concession period is over and for all other unsuccessful Bidders 6 months after this
Contract has been awarded.
If any claim is made/ lodged during this time, the same shall be binding and continue to be
valid despite the lapse of this pact as specified above, unless it is discharged/ determined by
NHIDCL.
1. This pact is subject to Indian Law. Place of performance and jurisdiction is the
Registered Office of the Principal, i.e. ........
4. Should one or several provisions of this agreement turn out to be invalid, the
remainder of this agreement remains valid. In this case, the parties will strive to come
to an agreement to their original intentions.
5. Any disputes/ differences arising between the parties with regard to term of this pact,
any action taken by the Principal in accordance with this Pact or interpretation thereof
shall not be subject to any Arbitration.
6. The actions stipulated in this Integrity Pact are without prejudice to any other legal
action that may follow in accordance with the provisions of the extant law in force
relating to any civil or criminal proceedings.
Page 55 of 229
In witness whereof the parties have signed and executed this Pact at the place and date first
done mentioned in the presence of following witness:-
(For & On behalf of the Principal) (For & On behalf of the Bidder/
Contractor/ Concessionaire/ Authority’s
Engineer)
(Office Seal )
Place
Date
Witness 1 :
(Name & Address):
Witness 2 :
(Name & Address):
Page 56 of 229
Appendix B-11: Details of Ongoing and Awarded works in NHIDCL
Details of Ongoing & Awarded (for which LOA has been issued) works in NHIDCL (Ref Clause 2.1.15 of Section-2 of
RFP)
Sl. No. Name of the Contract Price Appointed Original Progress as Likely date of Remarks,
work (Rs. Cr.) Date Scheduled on Date Completion if any
completion date
1.
2.
3.
…….
I/We certify that all the information furnished above is true in all respects.
Page 57 of 229
SECTION 5: FORMAT FOR SUBMISSION OF FINANCIAL PROPOSAL.
Page 58 of 229
APPENDIX C-1: FINANCIALPROPOSALSUBMISSIONFORM
We, the undersigned, offer to provide the consulting services for the above in accordance with
your Request for Proposal dated [Date], and our proposal. Our attached financial proposal is
for the sum of [Amount in words and figures]. This amount is exclusive of the local taxes which
we have estimated at (Amount in Words and Figures).
Our financial proposal shall be binding upon us upto the expiration of the validity period of
the proposal, i.e., [Date].
We undertake that, in competing for (and, if the award is made to us, in executing) the above
contract, we will strictly observe the laws against fraud and corruption in force in India
namely “Prevention of Corruption Act 1988”.
Commission and gratuities, if any, paid or to be paid by us to agents relating to this proposal
and contract execution, if we are awarded the contract, are listed below:
We understand you are not bound to accept any proposal you receive.
We remain,
Yours
sincerely,
Page 59 of 229
Managing Director/Head of the firm/
Authorised Representative of the firm*
Name of the firm
Address
*Lead Member in case of JV
Page 60 of 229
APPENDIX C-2: SUMMARY OF COSTS
Page 61 of 229
APPENDIX C-3: BREAKDOWN OF LOCAL CURRENCY COSTS
Construction Maintenance
period period
Professional Staff
1 Team Leader Cum Senior
PavementEngineer 24 06
Sub-Professional
1 Survey Engineer (02 Nos.), one for TBN
package 1&2 and one for package 24x2=48 10x2=20
3&4
2 Assistant Highway Engineer (04 TBN
24x4=96 60x4=240
Nos.), one for each package
3 Assistant Bridge Engineer TBN 24 03
4 Assistant Quality cum material TBN
Engineer (04 Nos.), one for each 24x4=96 0
package
5 Quantity Surveyor (02 Nos.), one for TBN
package 1&2 and one for package 24x2=48 08x2=16
3&4
Sub Total 312 279
Total 438 300
Note : Billing rates as indicated above shall be increased in accordance of clause 6.2(a) Special
Conditions of Contract for the personnel of all categories namely (i) key Personnel; (ii) sub-
Professional personnel and (iii) Support staff. The increase as above shall be payable only on
the remuneration part of Key Personnel, Sub-Professional Personnel and support staff.
However, for evaluation of Bid proposals, the quoted initial rate shall be multiplied by the total
time input for each position on this contract, i.e. without considering the increase in the billing
rates
The vehicles provided by the Consultants shall include the cost for rental, drivers, operation,
maintenance, repairs, insurance, etc. for all complete approx. 3000km/month run
V. Office Rent (Fixed Costs)– Minimum 200 sqm area of office shall be rented
during construction and 50 sqm during maintenance period. The rent cost includes
electricity and water charges, maintenance, Cleaning, repairs, etc. complete.
Page 63 of 229
Nos. of Months Rate/month Amount
24+60
The cost shall include rental charges towards all such furniture and equipment as required
for proper functioning of office. Office furniture shall include executive tables, chairs, visitor
chairs, steel almirahs, computer furniture, conference table etc. Office equipment shall
include as a minimum of telephone (2 external & 10 internal lines), photocopier (15ppm,
12000 copies per month with A3 & A4 input), fax machine, PCs(5 No., Intel Core 2 Duo
E8300, 19’’ colour TFT, Cache-6MB, RAM-2 GB, HDD-250 GB, DVD Writer, Key board,
optical scroll mouse, MS- Windows Vista Business, pre-loaded anti-virus etc.), laser
printers (2 no., 14 ppm, 266 MHZ, 5000 pages per month, 600x600 dpi or better etc.,
Engineering Plan printer (1 no.), binding machine (1 no.), plotter A0 size, overhead
projector, AC (4 no., 1.5 Ton), Water Coolers (as required)etc.
Nos. of Months Rate/month Amount
24+60
VIII. Reports and Document Printing
Total
The cost shall include carrying out survey using equipment, manpower, software and report
processing.
X. Contingencies
A fixed amount of Indian Rupees 10 (ten) Lakh shall be included in the Financial Proposal. The
provisions of Contingency shall be operated with the specific approval from the Competent
Authority in NHIDCL.
Page 65 of 229
SECTION 6: TERMS OF REFERENCE FOR AUTHORITY’S ENGINEER
[Note: The term “Agreement” and clauses thereof refer to the EPC Agreement dated-----
- entered between Authority and --------(the Contractors) for the work of Consultancy
Services as Authority’s Engineer for Supervision of “Rehabilitation and Up-gradation to 2
lane with paved shoulders of Seling-Dulte section (Economic Corridor) of NH-6 from Existing
chainage Km 0+000 to Km 69+015 (Design Chainage Km 0+000 to Km 62+200) in the state of
Mizoram under Bharatmala Pariyojna on EPC mode.”
1. Scope
These Terms of Reference (the “TOR”) for the Authority’s Engineer are being specified
pursuant to the EPC Agreement dated........... (the “Agreement”), which has been entered into
between the Authority and (the “Contractors”) for Consultancy Services as Authority’s
Engineer for Supervision of “Rehabilitation and Up-gradation to 2 lane with paved
shoulders of Seling-Dulte section (Economic Corridor) of NH-6 from Existing chainage Km
0+000 to Km 69+015 (Design Chainage Km 0+000 to Km 62+200) in the state of Mizoram
under Bharatmala Pariyojna on EPC mode.” on Engineering, Procurement, Construction
(EPC) basis, and a copy of which is annexed hereto and marked as Annex-A to form part of
this TOR.
1.1 The TOR shall apply to construction and maintenance of the Project Highway.
2.1 The words and expressions beginning with or in capital letters and not defined herein
but defined in the Agreement shall have, unless repugnant to the context, the meaning
respectively assigned to them in the Agreement.
2.2 References to Articles, Clauses and Schedules in this TOR shall, except where the
context otherwise requires, be deemed to be reference to the Articles, Clauses and
Schedules of the Agreement, and references to Paragraphs shall be deemed to be
references to Paragraphs of this TOR.
2.3 The rules of interpretation stated in Clauses 1.2, 1.3 and 1.4 of the Agreement shall
apply, mutatis mutandis, to this TOR.
3 General
3.1 The Authority’s Engineer shall discharge its duties in a fair, impartial and efficient
manner, consistent with the highest standards of professional integrity and Good
Industry Practice.
3.2 The Authority’s Engineer shall perform the duties and exercise the authority in
accordance with the provisions of this Agreement, but subject to obtaining prior
written approval of the Authority before determining.
Page 66 of 229
(d) Any other matter which is not specified in (a), (b) or (c) above and which creates
an obligation or liability on either Party for a sum exceeding Rs. 5,000,000 (Rs. Fifty
lakh.)
3.3 The Authority’s Engineer shall submit regular periodic reports, once every month, to
the Authority in respect of its duties and functions under this Agreement. Such reports
shall be submitted by the Authority’s Engineer within 10 (ten) days of the beginning of
every month.
3.4 The Authority’s Engineer shall inform the Contractor of any delegation of its duties and
responsibilities to its suitably qualified and experienced personnel; provided, however,
that it shall not delegate the authority to refer any matter for the Authority’s prior
approval in accordance with the provisions of Clause 18.2 EPC Agreement.
3.5 The Authority’s Engineer shall aid and advise the Authority on any proposal for Change
of Scope under Article 13.
3.6 In the event of any disagreement between the Parties regarding the meaning, scope and
nature of Good Industry Practice, as set forth in any provision of the Agreement, the
Authority’s Engineer shall specify such meaning, scope and nature by issuing a
reasoned written statement relying on good industry practice and authentic literature.
The officer in-charge of the Authority (e.g. PD/ RO/ CGM/ Member in the case of NHAI;
RO/CE/ADG in the case of MoRTH projects executed through the State PWDs; and
PD/ED/Director in the case of NHIDCL) is responsible for the overall supervision and
monitoring of the execution of project as the representative of the owner of the project.
The Authority's Engineer is appointed to assist the Authority for carrying out the
functions as detailed under clause 18.2 of the EPC Agreement. As such, an officer of the
Authority is vested with all such powers and responsibilities as are enjoined upon the
Authority's Engineer and is fully competent to issue any instructions for proper
monitoring and supervision of the project, either by himself or through the Authority's
Engineer. Instructions issued by the concerned officer of the Authority shall have the
same effect as that of the Authority's Engineer in terms of this Agreement. Wherever
such concerned officer issues any instructions or notice to the Contractor, he shall
endorse a copy thereof to the Authority's Engineer.
5 Construction Period
5.1 During the Construction Period, the Authority’s Engineer shall review and approve the
Drawings furnished by the Contractor along with supporting data, including the geo-
technical and hydrological investigations, characteristics of materials from borrow
areas and quarry sites, topographical surveys, and the recommendations of the Safety
Consultant in accordance with the provisions of Clause 10.1.6 of EPC Agreement. The
Authority’s Engineer shall complete such review and approve and send its observations
to the Authority and the Contractor within 15 (fifteen) days of receipt of such Drawings;
provided, however that in case of a Major Bridge or Structure, the aforesaid period of
15 (fifteen) days may be extended upto 30 (thirty) days. In particular, such comments
shall specify the conformity or otherwise of such Drawings with the Scope of the Project
and Specifications and Standards.
Page 67 of 229
5.2 The Authority’s Engineer shall review and approve any revised Drawings sent to it by
the Contractor and furnish its comments within 10 (ten) days of receiving such
Drawings. The review/approval of drawing should be authenticated by Authority’s
Engineer.
5.3 Quality Assurance Manual and Plan forms the basis of quality of the work. It is therefore
essential that the Quality Assurance Manual and Plan prepared by the Concessionaire
be checked and approved. Thus, the Authority’s Engineer shall check contents of
Quality Assurance Plan and Manual of Concessionaire as per requirements of Quality
Management System (as per ISO 9001), IRC: SP: 47-1998 and IRC: SP: 57-2000 for road
bridges and roads respectively. The Authority’s Engineer Authority’s Engineer shall
also offer their comments for modifying/ improving the document. After receiving the
corrected document, the Authority’s Engineer shall review and formally approve the
QAM and Quality Plan and send one copy to the Authority. The Authority’s Engineer
shall complete the review of the methodology proposed to be adopted by the
Contractor for executing the Works, and convey its comments to the Contractor within
a period of 10 (ten) days from the date of receipt of the proposed methodology from
the Contractor.
5.4 The Authority’s Engineer shall grant written approval to the Contractor, where
necessary, for interruption and diversion of the flow of traffic in the existing lane(s) of
the Project Highway for purposes of maintenance during the Construction Period in
accordance with the provisions of Clause 10.4 EPC Agreement.
5.5 The Authority’s Engineer shall review the monthly progress report furnished by the
Contractor and send its comments thereon to the Authority and the contractor within
7 (seven) days of receipt of such report.
5.6 On a daily basis, the concerned key personnel of Authority Engineer shall inspect the
Construction Works. Following activities need to be undertaken during the visits.
5.7 On a monthly basis, the Authority Engineer shall prepare a Monthly Inspection
Page 68 of 229
Report in accordance with the format prescribed in Annexure V setting forth an
overview of the status, progress, quality and safety of construction, including the work
methodology adopted, the materials used and their sources, and conformity of
Construction Works with the Scope of the Project and the Specifications and Standards.
In a separate section of the Inspection Report, the Authority Engineer shall describe in
reasonable detail the lapses, defects or deficiencies observed by it in the construction
of the Project Highway. The Authority Engineer shall send a copy of its Inspection
Report to the Authority and the Concessionaire latest by 7th of every month. Key
sections of the Monthly Progress Report are as follows.
Page 69 of 229
5.8 If at any time during the Construction Period, the Authority Engineer determines that
the Concessionaire has not made adequate arrangements for the safety of workers and
Users in the zone of construction or that any work is being carried out in a manner that
threatens the safety of the workers and the Users, it shall make a recommendation to
the Authority forthwith, identifying the whole or part of the Construction Works that
should be suspended for ensuring safety in respect thereof.
5.9 The Authority’s Engineer shall conduct the pre-construction review of manufacturer’s
reports and standard samples of manufactured Materials, and such other Materials as
the Authority’s Engineer may require.
5.10 For determining that the Works conform to Specifications and Standards, the
Authority’s Engineer shall require the Contractor to carry out, or cause to be carried
out, tests at such time and frequency and in such manner as specified in the Agreement
and in accordance with Good Industry Practice for quality assurance. For purposes of
this, the tests specified in the IRC Special Publication-11 (Handbook of Quality Control
for Construction of Roads and Runways) and the Specifications for Road and Bridge
Works issued by MORT&H (the “Quality Control Manuals”) or any
modifications/substitution thereof shall be deemed to be tests conforming to Good
Industry Practice for quality assurance.
5.11 The Authority’s Engineer shall test check at least 60(sixty) percent of the quantity or
number of tests prescribed for each category or type of test for quality control by the
Contractor.
5.12 The timing of tests referred to in Paragraph 5.10, and the criteria for
acceptance/rejection of their results shall be determined by the Authority’s Engineer
in accordance with the Quality Control Manuals. The tests shall be undertaken on a
random sample basis and shall be in addition to, and independent of, the tests that may
be carried out by the Contractor for its own quality assurance in accordance with Good
Industry Practice.
5.13 In the event that results of any tests conducted under Clause 11.10 establish any
Defects or deficiencies in the Works, the Authority’s Engineer shall require the
Contractor to carry out remedial measures.
5.14 The Authority’s Engineer may instruct the Contractor to execute any work which is
urgently required for the safety of the Project Highway, whether because of an accident,
unforeseeable event or otherwise; provided that in case of any work required on
account of a Force Majeure Event, the provisions of Clause 21.6 of EPC Agreement shall
apply.
5.15 In the event that the Contractor fails to achieve any of the Project Milestones, the
Authority’s Engineer shall undertake a review of the progress of construction and
identify potential delays, if any. If the Authority’s Engineer shall determine that
completion of the Project Highway is not feasible within the time specified in the
Agreement, it shall require the Contractor to indicate within 15 (fifteen) days the
steps proposed to be take to expedite progress, and the period within which the
Project Completion Date shall be achieved. Upon receipt of a report from the
Contractor, the Authority’s Engineer shall review the same and send its comments to
Page 70 of 229
the Authority and the Contractor forthwith.
5.16 The Authority’s Engineer shall obtain from the Contractor a copy of all the Contractor’s
quality control records and documents before the Completion Certificate is issued
pursuant to Clause 12.2 of EPC Agreement.
5.17 Authority’s Engineer may recommend to the Authority suspension of the whole or part
of the Works if the work threatens the safety of the Users and pedestrians. After the
Contractor has carried out remedial measure, the Authority’s Engineer shall inspect
such remedial measures forthwith and make a report to the Authority recommending
whether or not the suspension hereunder may be revoked.
5.18 In the event that the Contractor carries out any remedial measures to secure the safety
of suspended works and users, and requires the Authority’s Engineer to inspect such
works, the Authority’s Engineer shall inspect the suspended works within 3 (three)
days of receiving such notice, and make a report to the Authority forthwith,
recommending whether or not such suspension may be revoked by the Authority.
5.19 The Authority’s Engineer shall carry out, or cause to be carried out, all the Tests
specified in Schedule-K and issue a Completion Certificate or Provisional Certificate as
the case may be. For carrying out is functions under this Paragraph 4.18 and all matters
incidental thereto, the Authority’s Engineer shall act under and in accordance with the
provisions of Article 12 and Schedule-K. The Authority’s Engineer shall use following
equipment in carrying out the tests.
6 Maintenance Period
6.1 The Authority’s Engineer shall aid and advise the Contractor in the preparation of its
monthly Maintenance Programme and for this purpose carry out a joint monthly
inspection with Contractor.
6.2 The Authority’s Engineer shall undertake regular inspections, at least once every
month to evaluate compliance with the Maintenance Requirements and submit a
Maintenance Inspection Report to the Authority and the Contractor.
6.3.1 The Authority Engineer shall carry out visual inspection of entire highway stretch as
per the frequency defined in the following table
Page 71 of 229
Frequency
Nature of defect or deficiency of
inspection
ROADS
(a) Carriageway and paved shoulders
(i) Breach or blockade Daily
(ii) Pot holes Daily
(iii) Cracking Weekly
(iv) Rutting Weekly
(v) Bleeding/skidding Weekly
(vi) Ravelling/Stripping of bitumen surface Weekly
(vii) Damage to pavement edges Weekly
(viii
Removal of debris Daily
)
(b) Hard/earth shoulders, side slopes, drains and culverts
(i) Variation by more than 2% in the prescribed slope of camber/cross fall Weekly
(ii) Edge drop at shoulders Weekly
(iii) Variation by more than 15% in the prescribed side (embankment) slopes Weekly
(iv) Rain cuts/gullies in slope Weekly
Damage to or silting of culverts and side drains during and immediately
(v) Weekly
preceding the rainy season
(vi) Desilting of drains in urban/semi-urban areas Daily
(c) Road side furniture including road signs and pavement marking
Damage to shape or position;
(i) Daily
poor visibility or loss of retro-reflectivity
(d) Street lighting and telecom (ATMS)
(i) Any major failure of the system Daily
(ii) Faults and minor failures Daily
(iii) Streetlight with Lux Meter Weekly
(e) Trees and plantation
Obstruction in a minimum head-room of 5 m above carriageway or
(i) Daily
obstruction in visibility of road signs
(ii) Deterioration in health of trees and bushes Weekly
(iii) Replacement of trees and bushes Weekly
(iv) Removal of vegetation affecting sight line and road structures Weekly
(f ) Rest areas/Wayside amenities
(i) Cleaning of toilets Daily
(ii) Defects in electrical, water and sanitary installations Daily
(g) Toll plaza[s]
(i) Failure of toll collection equipment including ETC or lighting Daily
(ii) Damage to toll plaza Weekly
(h) Other Project Facilities and Approach roads
Damage or deterioration in Approach Roads, -[pedestrian facilities,
(i) truck lay-bys, bus-bays, bus- shelters, cattle crossings, Traffic Aid Posts, Daily
Medical Aid Posts and other works]
(j) Incident Management
Page 72 of 229
Frequency
Nature of defect or deficiency of
inspection
Instances of Incident Management as reported including time of call,
(i) Daily
response time, services rendered and time of clearing of the Highway.
(ii) List of the Incident Management Services rendered. Weekly
BRIDGES
(a) Superstructure of bridges
(i) Cracks Weekly
(ii) Spalling/scaling Weekly
(b) Foundations of bridges
(i) Scouring and/or cavitation Weekly
(c) Piers, abutments, return walls and wing walls of bridges
(i) Cracks and damages including settlement and tilting Weekly
(d) Bearings (metallic) of bridges
(i) Deformation Weekly
(e) Joints in bridges
(i) Loosening and malfunctioning of joints Weekly
(f) Other items relating to bridges
(i) Deforming of pads in elastomeric bearings Weekly
Gathering of dirt in bearings and joints; or clogging of spouts, weep holes
(ii) Weekly
and vent-holes
(iii) Damage or deterioration in parapets and handrails Weekly
(iv) Rain-cuts or erosion of banks of the side slopes of approaches Weekly
(v) Damage to wearing coat Weekly
Damage or deterioration in approach slabs, pitching, apron, toes, floor or
(vi) Weekly
guide bunds
(vii) Growth of vegetation affecting the structure or obstructing the waterway Weekly
6.3.2 All elements which have daily inspection frequency shall be inspected weekly as well.
Similarly, all elements which have weekly inspection frequency shall be inspected
monthly as well.
6.3.3 Daily inspection report format and weekly inspection report format has been provided
in Annexure II and III of this document respectively. Manpower which needs to conduct
visual inspection and mode of reporting is defined in the following table
6.3.4 High resolution photographs and video of the highway stretches having defects and/or
deficiencies shall be submitted along with Weekly Inspection Report and Monthly
Status Report. Summary of key observations around defects and deficiencies in
highway stretch shall be reported in Monthly Progress Report and detailed inspection
report shall be provided as Annexure to Monthly Progress Report.
6.3.5 The Authority’s Engineer shall also be responsible for inspection and monitoring of
Wayside Amenities. ETC (Electronic Toll Collection) and ATMS (Advanced Traffic
Page 73 of 229
Management System) and incident management.
6.4.1 The carrying out of condition surveys will be one of the most important and crucial field
tasks under the project. The Authority Engineer shall carry out condition surveys using
equipment and following a frequency as defined under.
Frequency of condition
S No Key metrics of Asset Equipment to be used
survey
Surface defects of At least twice a year (As per
Network Survey Vehicle survey months defined for
pavement (NSV)
1 the state basis rainy
season)
At least twice a year (As per
Roughness of pavement Laser Profilometer survey months defined for
2 the state basis rainy
season)
Falling Weight Reflectometer
3 Strength of pavement At least once a year
(FWD)
At least twice a year (As per
Mobile Bridge Inspection Unit
Bridges survey months defined for
4 (MBIU)
the
state basis rainy season)
At least twice a year (As per
Road signs Retro-reflectometer survey months defined for
5 the
state basis rainy season)
The first equipment based inspection shall be conducted at the time of completion testing. The
other inspections shall be conducted before and after the rainy seasons as per the schedule
defined in Annexure IV, except for FWD testing which shall be conducted once a year.
Page 74 of 229
Surface defect Dimensions to be
reported
%
Area
Depth
Rutting
Width
Concrete Joint/ Faulting Length
Roughness IRI in both wheel paths
ii. The following criteria shall be met by the process of defects detection
Measurement of 3D road profile using such technologies as laser scanning or
other proven technologies.
Ability to operate (collect data) at different speeds with a minimum speed of
30km/hr and upto at least 75 km/ hr.
Profile depth accuracy of 0.5mm
Capability for lane tracking to control driver wander’ and ensure high
repeatability of data between surveys.
Measure at least 3.5m width of highway lane.
Transverse Profile including rut depth measurement of pavement surface
widths of both carriageway and shoulders. The rut depth data must be
convertible to different straightedge lengths (1.8m to 3.5m) and meet industry
standards (ASTM E1703 / E1703M).
Pavement images with capability to automatically identify and rate distresses
Roughness measurement with outputs of both raw longitudinal profiles and
International Roughness Index (IRI) calculation shall be reported at least 100m
referenced to the preceding Location Reference Post (LRP). The roughness
must meet ASTM-E950 (equivalent to Class I road profiler). The IRI shall be
determined in both wheel paths.
Ability to record images at user-defined intervals (e.g. every 5, 10m, etc.)
Minimum images resolution of 1600x1200
Outputs must include Standard JPEG image or similar industry standard
Distance resolution of <1mm,
Capable of achieving distance accuracy of 0.1% (i.e. within 1m over 1km
distance)
All data outputs should be in a non-proprietary format (e.g. .CSV, .MDB, Excel)
and not require specialist software in order to view or format data
Data should also be capable of being easily formatted into data compatible
with HDM-4
iii. The following are the set of deliverables which should be submitted after
completion of survey as part of Monthly Progress Report
Raw data generated from the equipment which are part of Network Survey
covering the parameters mentioned in above table. It should also include
o Survey ID, Description, Date, Lane
o GPS referenced data for GIS mapping
Video logging
o Pavement imagery (AVI/JPEG)
o 360 degree imagery (JPEG)
Interpretation report covering summary of entire survey and analysis of defects
Page 75 of 229
and deficiencies
(i) The Authority Engineer shall carry out structural strength surveys for existing
pavements using Falling Weight Deflectometer technique in accordance with the
procedure given in IRC:115-2014 (Guidelines for Structural Evaluation and
Strengthening of Flexible Road Pavements Using Falling Weight Deflectometer (FWD)
Technique) and IRC: 117-2015 (Guidelines for the Structural Evaluation of Rigid
Pavement by Falling Weight Deflectometer)
(ii) The interval at which deflection measurements are to be taken up are as per IRC:115-
2014 / IRC:117-2015. For flexible pavements, the sample size and the interval of the data
to be collected depends on the length of the uniform section calculated and condition of
the pavement section i.e. ‘good’, ‘fair’ and ‘poor’ for each lane, established on the
pavement condition data based on the criterion given in IRC:115-2014. For rigid
pavements, the deflection data may be collected at interiors, corners, transverse joints
and longitudinal joints in the outer lanes at intervals as specified in IRC:117-2015.
(iii) The following are the set of deliverables which should be submitted after completion of
inspection test as part of Monthly Progress Report
6.4.4 The Authority Engineer shall carry out the condition and structural assessment survey
of the bridges in accordance with IRC-SP; 35 with the use of Mobile Bridge Inspection
unit (MBIU) or better technology.
(i) The following criteria shall be met by the process of bridge condition assessment
(ii) Detailed bridge inspection report shall be submitted as per the Inspection Proforma
provided in IRC-SP 35
6.4.5 Measurement of retro reflection of road signs
(i) The Authority Engineer shall measure Coefficient of retro reflected luminance RA (night
Page 76 of 229
time retro reflection) of road traffic signs using a portable retro reflectometer.
(ii) The following criteria shall be met by the process of road signs retro reflection
measurement
(iii) The following are the set of deliverables which should be submitted after completion
of survey as part of Monthly Progress Report
(i) Infrastructure:
Availability of civil infrastructure at toll plazas required for installation of ETC systems
Adequacy of hardware, software and other related items as per IHMCL/ NHIDCL
technical specifications and requirements
(ii) Operations:
Page 77 of 229
6.6 The Authority Engineer shall prepare a Monthly Status Report in O&M phase of project
in respect of its duties and functions under this Agreement and in accordance with the
format prescribed in Annexure VI. 1st deliverable of the report which is an executive
summary to the main report (Section 1) shall be submitted to the Authority and
updated on the PMIS and project specific website by 4th of every month. Main report
(Section 2 onwards) shall be submitted to the Authority and updated on the PMIS and
project specific website by 7th of every month. Key sections of the Monthly Status
Report are as follows;
6.9 The Authority’s Engineer shall examine the request of the Contractor for closure of any
lane (s) of the Project Highway for undertakings maintenance/repair thereof, and shall
grant permission with such modifications, as it may deem necessary, within 5 (five)
days of receiving a request from the Contractor. Upon expiry of the permitted period
of closure, the Authority’s Engineer shall monitor the reopening of such lane (s), and in
case of delay, determine the Damages payable by the Contractor to the Authority under
Clause 14.5 of EPC Agreement
7.1 The Authority’s Engineer shall determine the costs, and/or their reasonableness, that
are required to be determined by it under the Agreement.
7.2 The Authority’s Engineer shall determine the period of Time Extension that is required
to be determined by it under the Agreement.
7.3 The Authority’s Engineer shall consult each Party in every case of determination in
accordance with the provisions of Clause 18.5 of EPC Agreement.
8 Payments
8.1 The Authority’s Engineer shall withhold payments for the affected works for which the
Contractor fails to revise and resubmit the Drawings to the Authority’s Engineer in
accordance with the provision of Clause 10.2.4 (d) of EPC Agreement.
Page 79 of 229
8.3 The Authority’s Engineer shall, within 15 (fifteen) days of receipt of the First stage
Maintenance Payment Statement from the Contractor pursuant to Clause 19.6 of EPC
Agreement, verify the Contractor’s statement and certify the amount to be paid to the
Contractor in accordance with the provisions of the Agreement.
8.4 The Authority’s Engineer shall certify final payment with 30 (thirty) days of the
receipt of the final payment statement of Maintenance in accordance with the
provisions of Clause 19.16 of EPC Agreement.
The Authority’s Engineer shall perform all other duties and functions as specified in the
Agreement.
10 Miscellaneous
10.1 All key personnel and sub professional staff of the Authority Engineer shall use the
fingerprint based (biometric) attendance system for marking their daily attendance.
Attendance shall be marked at least once a day and anytime during the day. 1 Biometric
Attendance System shall be installed by the Authority Engineer at its own cost at the
site office in order to facilitate the attendance marking. More systems can be installed
near the project highway upto a maximum of 1 system per 50 km in order to encourage
frequent visits of project highway by key personnel and sub professional staff. A copy
of monthly attendance records shall be attached with Monthly Status Report. Proper
justification shall be provided for cases of absence of key personnel/ sub professional
staff which do not have prior approval from Project Director of concerned stretch
10.3 The Authority’s Engineer shall retain at least one copy each of all Drawings and
Documents received by it, including ‘as – built’ Drawings and keep them in its safe
custody.
10.4 Within 90 (ninety) days of the Project Completion Date, the Authority’s Engineer shall
obtain a complete set of as built Drawings in 2 (two) hard copies and in micro film form
or in such other medium as may be acceptable to the Authority, reflecting the Project
Highway as actually designed, engineered and constructed, including an as-built survey
illustrating the layout of the Project Highway and setback lines, if any, of the buildings
and structures forming part of project Facilities; and shall hand them over to the
Authority against receipt thereof.
10.5 The Authority’s Engineer, if called upon by the Authority or the Contractor or both,
shall mediate and assist the Parties in arriving at an amicable settlement of any Dispute
between the Parties.
10.6 The Authority’s Engineer shall inform the Authority and the Contractor of any event of
Contractor’s Default within one week of its occurrence.
Page 80 of 229
11. PERFORMANCE CLAUSE
Authority’s Engineers shall be expected to fully comply with all the provisions of the
`Terms of Reference’, and shall be fully responsible for supervising the Designs,
Construction and maintenance and operation of the facility takes place in accordance
with the provisions of the EPC Agreement and other schedules. Any failure of the
Authority Engineer in notifying to Employer and the Contractor on non-compliance of
the provisions of the EPC Contract Agreement and other schedules by the EPC
Contractor, non-adherence to the provision of ToR and non-adherence to the time
schedule prescribed under ToR shall amount to non-performance.
The Authority Engineer shall appoint its authorized representative, who shall issue on
behalf of the AE, Completion Certificate along with the Team Leader and shall carry out
any such task as may be decided by Employer. The AE shall take prior approval of
Employer before issuing Completion Certificate. The proposal submitted shall also
include the name of the authorized representative along with the authorization letter
and power of attorney.
12.2 Broad job-description and minimum qualification for key personnel mentioned above
is enclosed as Enclosure–B. However, higher marks shall be accorded to the Candidate
with higher relevant qualification and experience. All the CV’s of the personals
mentioned in Para5.3 (iii) of Data Sheet shall be evaluated at the time of evaluation of
technical proposal. The age of the Key Personnel should not be more than 60 years
on the date of submission of proposal. Consultants are advised in their own interest
to frame the technical proposal in an objective manner as far as possible so that these
could be properly assessed in respect of points to be given as part of evaluation criteria.
The bio-data of the key personnel should be signed on every sheet by the personnel
concerned and the last sheet of each bio-data should also be signed by the authorised
signatory for the Consultant. The key personnel shall also certify at the end of their bio-
data proforma that they have not left any of the Employer works without completing
of their assignment and have not accepted any other offer at the time of signing of the
bio-data and as such shall be available to work with the Authority Engineer, if the
Project is awarded. In case the key personnel leaves the assignment without approval
of Employer, Employer would beat liberty to take any appropriate action against that
key personnel including debarment. The CV submitted by selected firm/JV shall be
hoisted on official website of Employer.
Page 81 of 229
12.3 In addition to above, consultants are required to propose other key personnel, sub-
professional staff and other field engineers as detailed in Enclosure-A and the
minimum qualification requirements for the same is enclosed in Enclosure–B.
13. PERIOD OF SERVICES
The proposed manpower deployment for this period shall be matching the activities to
be performed during the said period. The time frame for services during the
deployment of key personnel during this period shall be as shown in Enclosure A.
Extension of Time for providing services of the Authority’s Engineer may be extended
concurrently with the Extension of Time granted, if any, to the EPC Contractor for the
project, subject to satisfactory performance of the Authority’s Engineer.
The Firm shall appoint a personnel from its head office to act as Project Coordinator for
the assignment. He will be authorised to communicate with the Authority in respect of
all matters pertaining to the project. The cost of the Project Coordinator shall be
incidental to the Consultancy Assignment.
Page 82 of 229
Enclosure-A
Page 84 of 229
Enclosure-B
1. Essential Qualifications.
a) Graduate in Civil Engineering from recognized university.
b) Total Professional Experience of at least 12 years in handling Highway Projects.
c) At least 5 years experience as Team Leader/Project Manager or similar capacity in
Highway Development Project.
d) He should have handled as Team Leader/Project Manager or similar capacity of at
least two projects in Construction Supervision / IC (of length 40% of project length
or more of similar configuration (2/4/6 laning**)
e) He should have handled as Team Leader or similar capacity of at least two Projects
of project Preparation of major highway Project (of length 40% of project length or
more of similar configuration (2/4/6 laning**).
f) Experience as Team Leader/Project Manager or similar capacity in Operation and
Maintenance of Major Highway Projects(of length 40% of project length or more of
similar configuration (2/4/6 laning**).
2. Preferential Qualifications.
a) Post Graduate Degree in Construction Management/Transportation/Highway
Engineering//Structural Engineering/ any specialised stream of Civil Engineering.
b) Highway Development Projects (of length 40% of project length or more of similar
configuration (2/4/6 laning**) taken up under EPC.
c) Degree/Diploma/Certificate in Project Management
Note: (1) Similar Capacity includes the following positions
i. On behalf of Consultant: Team Leader / Resident Engineer (Construction
Supervision/IE/AE).
Page 85 of 229
ii. On behalf of Contractor : Project Manager (Construction/ Construction
Supervision)
iii. In Government Organizations : Superintending Engineer (or equivalent) and
above
(2) Only those projects will be considered for evaluation at Sl. No. 1(d), 1(e) & 1(f)
above, where the input of the personnel is 12 months, 9 months and 12 months respectively.
RESIDENT CUM HIGHWAY ENGINEER
The Resident cum Highway Engineer shall be responsible for supervising the works of
highway to be constructed by the Concessionaire for this project. He shall also inspect the
pavement rehabilitation and repair works to be undertaken by the Concessionaire.
He should have the following qualification / experience.
1. Essential Qualifications.
a) Graduate in Civil Engineering from a recognized University.
b) Professional Experience of at least 12 years in Highway Projects.
c) At least 5 years experience in similar capacity in Highway Development Project.
d) Should have handled at least 2 major projects(of length 40% of project length or
more of similar configuration (2/4/6 laning**) and above).
2. Preferential Qualifications.
a) Post Graduate Degree in Transportation/Highway Engineering/Structural
Engineering/Geotechnical Engineering/any specialised stream of Civil Engineering.
b) Experience of Highway Project (of length 40% of project length or more of similar
configuration (2/4/6 laning**) and above) of Construction / Construction
Supervision / IC of Highway projects
Page 86 of 229
SENIOR QUALITY/MATERIAL EXPERT
The Quality/Material Expert shall review the test results of bore holes, quarry and borrow
area material to find out their strength characteristics and suitability for using them in
construction. He shall inspect the Concessionaire’s field laboratories to ensure that they are
adequately equipped and capable of performing all the specified testing requirements of
the contract. He shall look into the quality assurance aspect of the construction works and
supervise the setting-up of the various Concessionaire’s rock crushers and bituminous
mixing plants to ensure that the specified requirements for such equipment are fully met.
Experience in latest Quality Management techniques in highway projects shall have added
advantage.
He should have the following qualification / experience.
1. Essential Qualifications.
a) Graduate in Civil Engineering from a recognized University.
b) Professional Experience of at least 10 years in handling Highway projects.
c) Experience of at least 5 years as Senior Quality/ Material Expert or in similar
capacity in Construction / Construction Supervision /major highway projects
d) Experience as Senior Quality/ Material Expert or in similar capacity in handling of
at least 2 similar highway projects.(of length 40% of project length or more of
similar configuration (2/4/6 laning**) and above)
2. Preferential Qualifications.
Page 87 of 229
SENIOR QUANTITY SURVEYOR
He will be reporting to the Team Leader and give input as and when required during the
work. He will provide necessary guidance to the Quantity Surveyor, and shall issue
directions/procedures/formats of reporting to the Quantity Surveyor. He will act as a
contract specialist also for the construction package, even though the thrust of his
responsibilities will be in the areas of quantity surveying/ processing of the invoices etc.
He will be responsible for taking all measures required to control the project cost and time
over-runs. He will examine the claims of the contractor, variation orders, if any, and will
approve the progress reports as per the project requirements. He will approve the
measurement of all items of works executed in different stages for payment purpose
prepared by Quantity Surveyor.
a)
Page 88 of 229
ROAD SAFETY EXPERT
Shall be responsible for the overall Road Safety Aspect of the Project. He shall ensure that
safety provisions as per relevant codes are strictly followed at site during Construction of
Road and also during the Maintenance Period
1. Essential Qualifications.
a) Graduate in Civil Engineering from a recognized University.
b) Professional Experience of at least 10 years in handling Highway projects.
c) Minimum 5 years experience in Road Safety works of Major Highway Projects (4 / 6
laning projects)
d) Experience in similar capacity in Road Safety Audit of at least 2 nos. 2/4/6 lane**
highway / expressway project including 1 nos. at design stage
e) Experience in similar capacity in the field of Road Safety Management Plan.
2. Preferential Qualifications
a) Post Graduate Degree in Traffic Transportation/Safety Engineering.
b) Experience in similar capacity in identification and improvement of black spots on
Major Highway Project.
c) Experience in similar capacity in Preparation of Road Safety Management Plan for
inter urban Highways.
Page 89 of 229
Annexure I- Daily Inspection Report in construction period
Results of lab
Description of Name of key
tests conducted
inspection personnel
Component Item Description (Test
work carried inspecting the
conducted,
out work
Pass/Fail)
1. Road works
Embankment/ Sub
including
Grade/ GSB/ WMM/
culverts, and
DBM/ BC
minor bridges
2. Major Bridge
Foundation/ Sub
works, Flyovers,
structure/ Super
ROB, RUB, VUP,
structure
PUP
3. Approach to
Foundation/ Sub
ROB/RUB/ Major
structure/ Super
Bridges/ Viaduct /
structure
RE wall
4. Other Works
Page 90 of 229
Annexure II- Daily Inspection Report in O&M period
Page 91 of 229
Annexure III- Weekly Inspection Report in O&M period
ROADS
(vi) Bleeding/skidding
Ravelling/Stripping of bitumen
(vii)
surface exceeding 10 sq m
Page 92 of 229
Defect If defect Compliance of AE Remarks
found found, previous defect
Nature of defect or deficiency
(Yes/No) Chainage & (Yes/No/NA)
side
Page 93 of 229
Defect If defect Compliance of AE Remarks
found found, previous defect
Nature of defect or deficiency
(Yes/No) Chainage & (Yes/No/NA)
side
Damage or deterioration in
Approach Roads, -[pedestrian
facilities, truck lay-bys, bus-bays,
(i)
bus- shelters, cattle crossings,
Traffic Aid Posts, Medical Aid Posts
and other works]
BRIDGES
(i) Cracks
(ii) Spalling/scaling
(b) Foundations of bridges
(i) Deformation
Joints in
(e) bridges
Loosening and malfunctioning of
(i)
joints
Damage or deterioration in
(iii)
parapets and handrails
Page 94 of 229
Defect If defect Compliance of AE Remarks
found found, previous defect
Nature of defect or deficiency
(Yes/No) Chainage & (Yes/No/NA)
side
Damage or deterioration in
(vi) approach slabs, pitching, apron,
toes, floor or guide bunds
Page 95 of 229
Annexure IV- Month of survey for equipment based road condition assessment
Equipment based road inspection shall be done by the Authority’s Engineer twice a year as per
the month of the year defined in the following table.
However, since the first survey shall be conducted at the time of completion testing, the
following modification to the schedule shall be adopted. For example, if majority of highway
length (>50%) passes through a state, where defined survey months are May and November,
if completion testing is conducted in April, then the first equipment based survey shall be
conducted in the month of April. This shall be considered as the equipment based survey to be
conducted in the month of May. The 2nd equipment based survey shall be conducted in the
month of November, the 3rd survey shall be conducted in the month of May and so on. As
regards FWD, the first test/survey shall be conducted at the time of completion in April. The
2nd test/survey shall be conducted in April of next year and so on.
Page 96 of 229
Region State Survey before rains Survey after rains
Page 97 of 229
Annexure V- Monthly Progress Report in Construction Phase
Authority Engineer
[NAME OF CONSULTING FIRM]
Page 98 of 229
Table of content
Contents
Page Nos.
% Total % %
Lengt Pendin Lengt Total Lengt Total
h (km) g h (km) Lengt h (km) Lengt
Length h h
Total Length Total Total
Length Length
Total Total Total
Workfront Length Length
Unavailable Complete Complete
d (Till d
DBM) (Till DBM)
Pending Land BC BC
Acq. DBM DBM
Pending WMM WMM
Clearances GSB GSB
Encumbrance Sub- Sub-
s Grade Grade
C&G C&G
2 Project Overview
Project Name
NH No. (New/ Old)
Scheme/ Phase
Mode of the Execution (BOT Toll/ BOT Annuity/ EPC/
HAM/ Item Rate/ Others)
No. of Lanes/ Configuration
Length of the Project (in Km)
Total Project Cost (in Cr)
No. of Bypasses (Name of Town, Length)
No. of Major Bridges (Number and Location)
No. of Toll Plazas (Number and Location)
No. of Fly Overs (Number and Location)
DPR Authority’s Engineer Name
Lead & Consortium Members of Banks
Concessionaire Name (SPV & Parent Company)
Date of Award (LOA Date)
Appointed Date
Concession Period
Construction Period (in Days)
O&M Period (in Days)
Scheduled Date of Completion
Authority Engineer
IE / AE Agreement Date
IE / AE Mobilization Date
Milesto
ne II
Milesto
ne II
Schedule
d
Completio
n
[Above image is illustrative only. Please include chainage and name below the axis and
list of features above the axis]
Ongoin Expected
Chainage( Action(s)
g/ New Length Action(s) date/ Actual
S.N Issue Concerned s) affected suggested
Type Issue/ affecte taken till Date for
o Description Authority due to the by
Resolve d (km) now resolving
issue the AE
d issue
4 Physical Progress
Physical
Physical Progress
%
Compone Progress(Durin (Cumulativ
Weightag
nt g Current e, Upto
e
Month) Current
Month)
Road Works
Major Bridge works and ROB / RUB
Structures
Other Works
Physical
Progress
1. Road works
including
culverts, minor
bridges,
underpasses,
overpasses,
approaches to
ROB/RUB/ Major
Bridges/
Structures (but
excluding service
roads)
2. Major Bridge
works and
ROB/RUB
3. Structures
(elevated
sections,
reinforced earth)
4. Other Works
GRAND TOTAL
5.1 LA Summary
CALA 1]
[CALA2
]
[CALA
3]
Grand
Total
CALA 1
Total Amount Pendin
3H 3G Amount Amount
Land left 3H 3G 3D 3D 3A 3A Disburse g
Pend Pend Awarde Deposite
Village to be Done Done Pendin Done Pendin Done d by Amoun
-ing -ing d (Crore d (Crore
Acquire (ha) (ha) g (ha) (ha) g (Ha) (ha) CALA t (Rs
(ha) (ha) Rs.) Rs.)
d (Ha) (Rs Cr) Cr)
[Village 1]
[Village 2]
[Village 3]
Grand
Total
[CALA 1]
[CALA 1]
[CALA 2]
[CALA 2]
Grand Total
Environment
Length
Proposal Description Status Current Stage Issues/ Comments
Impacted
Forest Land
Length
Proposal Description Status Current Stage Issues/ Comments
Impacted
Tree Cutting
Length
Proposal Description Status Current Stage Issues/ Comments
Impacted
Railway (ROBs/RUBs)
Length
Proposal Description Status Current Stage Issues/ Comments
Impacted
Water
Electric
ity
Others
6 Change of Scope
Date of first
COS ed/ Actual Date of
S No. Proposal Details submission to Current Status Amount Approval
AE
Cumulative inflow
Cumulative outflow Inflow to Escrow Outflow from
to Escrow till
TPC (Cr) from Escrow till during the month Escrow during the
previous month
previous month(Cr) (Cr) month(Cr)
(Cr)
Are the Escrow withdrawals in accordance with the order of withdrawal as specified
in the Concession Agreement?
Tick as applicable
Total test up to
Frequenc Total test in This Cumulative No. of
Previous
y of tests Month tests
Descriptio Uni Month Remark
n t s
No. Conducte Pas Fai Conducte Pas Fai Conducte Pas Fai
Qty.
s d s l d s l d s l
Sub grade
Wet Mix
Macadam
Filter
material
Concrete
Cement
Water
Prime
Coat
Tack coat
Dense
Bituminou
s
Macadam
Bituminou
s Concrete
Bitumen
test
DLC
Steel
<Quality inspection test results to be reported in a table similar to the table provided in
previous section>
resolving issue
Action(s) taken
affected due to
Length affected
Ongoing/New
Chainage(s)
Action(s)
Concerned
Authority
the issue
till now
Issue
(km)
SNo
1 Drying up
of plants
on median
2 Large
potholes
(c ) Bridges
1
2
3
4
Total
11 Safety features
Date
Chainage no
Time of accident
Sex (M/F)
Accident location
A
Nature of accident
B
Classification of
C
Causes
D
Load conditions of
E
Road condition
F
Intersection type of
G
Weather condition
H
Age of victim
I
Type of victim
J
Type of vehicle
K
Fatal
persons
affected
No of
Major
Minor
Help provided by
A 1. Urban 2. Rural
1. Overturned 2. Head On Collision 3. Hit from Back 4. Hit to Fix Object 5. Right turn Collision
B
6. Left turn Collision 7. Veered Out off The Road 8. Hit Pedestrian 9. Unknown/Hit & Ran Away
C 1. Fatal 2. Major injury 3. Minor injury
1. Drunken 2. Over Speeding 3. Vehicle out of Control 4. Driven on wrong side 5. Mechanical
D
Problem 6. Drowsiness/Not Applicable 7. Fault of Driver
E 1. Normally Loaded 2. Overloaded/Handing 3. Empty 4. Unknown
F 1. Straight road 2. Slight Curve 3. Sharp Curve 4. Hump 5. Dip
1. T-Junction 2. Y-Junction 3. Four arm Junction 4. Staggered Junction 5. Junction with more
G
than 6. Round about
1. Fine/Clear 2.Mist/Fog 3. Cloudy 4. Light Rain 5. Heavy Rain 6. Strong Wind 7. Dust Storm 8.
H
Cold 9. Hot
I 1. 0-18 Years 2. 18-25 Years 3. 25-40 Years 4.40-60 Years 5. 60-80 Years
J 1. Driver 2. Passenger 3. Pedestrian 4. Cyclist 5. Others
1. Two Wheeler 2. Auto Rickshaw 3. Car/Jeep 4. Bus 5. Light Truck 6. Heavy Truck 7. Tractor
K
8. Bicycle 9. Cycle Rickshaw 10. Hand Drawn Cart 11. Animal Drawn Cart
* The above list is illustrative and may require modification as per the actual scope
of the work
IE / AE should include comments, status update, data points and reports in following
annexures which have not been included elsewhere in the main report. Such reports
may include but not limited to:
Review status of drawings/ design reports
Review status of other documents
Minutes of review meeting
Detailed Inspection report of project highway
Correspondence details
Weather report
Organizational chart of Concessionaire / Contractor and IE / AE
List of lab equipment
Details of user complaints
Project photographs
Authority Engineer
[NAME OF CONSULTING FIRM]
9.1 Monthly Toll Collection Report (Applicable only if project highway is tolled)
173
9.2 Accident Report 174
1 Executive Summary
Overlay on the entire stretch of project length of 252 km and service roads has not
been taken up by Concessionaire yet since the date of completion of overlay is due in
next 25 days
Over all progress is very slow regarding repair of potholes and rutting on Main
Carriageway which is causing inconvenience to highway users and is also a concern
from road safety point of view.
Street lighting in
Anantapur bypass completed on main carriageway and is energized but for
service roads street lighting is pending on both sides
Kurnool bypass erection of poles only completed in main carriageway not yet
energized till to date, but for service roads not started
Main report
2 Project Overview
Project Name
NH no (New/Old)
Mode of the Project
No. of Lanes
Length of the Project
Total Project Cost
Concessionaire/ Contractor
Date of Award (LOA date)
Appointed Date
Commercial Operation Date (COD)
Concession Period
O&M Period
Authority Engineer
AE Agreement Date
AE Mobilization Date
AE Scheduled Completion Date
AE EOT (Extension Of Time)
20 m
18 m
16 m 16 16 16 16 16 16 16
14 m
12 m
10 m
8m 8.2 8.2 8.2 8.2 8.2
6m
4m 4.7 4.7 4.7 4.7 4.7
2m 1.8 1.8
Chainage
2m
RHS- Width of RoW available
4m
6m 6.2 6.2 6.2 6.2 6.2 6.2
8m
10 m 10 10
12 m
14 m
16 m
18 m 17.5 17.5 17.5 17.5 17.5 17.5 17.5 17.5
20 m
>20 m 25 25 25
resolving issue
Action(s) taken
affected due to
Length affected
Ongoing/New
Chainage(s)
Action(s)
Concerned
Authority
the issue
till now
Issue
(km)
SNo
Drying up Replacemen
of plants Concession 325+200 to Irregular t of plants
1 Ongoing 2.6 NA
on aire 327+800 watering and daily
median watering
Large Concession 387+300 Filling of <DD/M
2 New 0.1 None
potholes aire LHS potholes M>
4 Inspection Report
Bleeding (cm)
Raveling (cm)
Bituminous E1
Lane number
Texture depth
Rutting depth
Cracks (cm)
SubGrade E3
(International
Roughness
Resistance
Modulus
Chainage
Chainage
Modulus
Ending
Starting
Modulus
Elastic
Elastic
Elastic
)
Index)
(mm)
(mm)
Skid
IRI
m
(
m
1.000 1.500 L1
Video footage of all cameras installed on Network Survey Vehicle- ROW cameras and
pavement camera
Network Survey Vehicle report capturing dimensions of following key metrics of
pavement
Cracks
For Corresponding
TYPE OF VEHICLE month of previous For Previous Month For Current Month
year
No of Fee No of Fee Fee per No of Fee
vehicles Collected vehicles Collected vehicle vehicles Collected
A Car Total 3845 384500 4659 465,900.00 100 4289 428,900.00
B LCV Total 1521 243360 1312 209,920.00 160 1399 223,840.00
C Bus Total 2404 793386 2284 765,207.00 201 2349 786,915.00
D Truck Total 1603 528924 1523 510,138.00 134 1566 524,610.00
E 3 Axle Total 18990 6836400 16310 5,953,150.00 365 15127 5,521,355.00
F MAV Total 16119 8381880 21111 11,188,830.00 530 18790 9,958,700.00
Over
G Total 1 630 27 17,280.00 640 36 23,040.00
Size
Total for the
49844 18,050,618 52963 19,898,834 49016 18,265,661
Month
Average Average
Average
queue queue Average Average Average Average
transction
Lane length length Transaction transaction transaction transaction
time
during peak during non time (cash) time (RFID) time (cards) time (wallet)
(others)
time peak time
UPI – 20
Lane 1 10 vehicles 5 vehicles 15 seconds 10 seconds 20 seconds 25 seconds
seconds
Lane 2
Lane 3
No of days as
Cost o repair
as estimated
Damages as
Damages at
higher side
No of days
inspection
damages
Nature of
Damages
Damages
amount
Quantity
Date of
per CA
per CA
defect
Total
S No
from
Rate
Unit
Total 6,02,64,000
9 Reports
9.1 Monthly Toll Collection Report (Applicable only if project highway is tolled)
For Corresponding
TYPE OF VEHICLE month of previous For Previous Month For Current Month
year
Fee
No of Fee No of Fee No of Fee
per
vehicles Collected vehicles Collected vehicles Collected
vehicle
Single 3845 384500 4659 465,900.00 100 4289 428,900.00
A Car Return 1506 218370 1972 295,800.00 150 1758 263,700.00
Local 769 38450 979 48,950.00 50 1029 51,450.00
Single 1521 243360 1312 209,920.00 160 1399 223,840.00
B LCV Return 134 31490 162 38,880.00 240 132 31,680.00
Local 1683 134640 1838 147,040.00 80 1461 116,880.00
Single 2404 793386 2284 765,207.00 201 2349 786,915.00
C Bus Return 359 177903 173 87,567.00 303 203 102,717.00
Local 277 45738 205 34,782.00 102 318 54,060.00
Single 1603 528924 1523 510,138.00 134 1566 524,610.00
D Truck Return 240 118602 116 58,378.00 202 136 68,478.00
Local 185 30492 136 23,188.00 68 212 36,040.00
Single 18990 6836400 16310 5,953,150.00 365 15127 5,521,355.00
E 3 Axle Return 131 70740 34 18,700.00 550 37 20,350.00
Local 69 12420 84 15,540.00 185 131 24,235.00
Single 16119 8381880 21111 11,188,830.00 530 18790 9,958,700.00
F MAV Return 2 1550 20 15,800.00 790 35 27,650.00
Local 6 1560 18 4,770.00 265 8 2,120.00
Single 1 630 27 17,280.00 640 36 23,040.00
Over
G Return 0 0 - 965 -
Size
Local 0 0 - 320 -
Total for the
49844 18,050,618 52963 19,898,834 49016 18,265,661
Month
1
1/1/17
Date
382/050 05:25
RHS
Chainage no
pm
Time of accident
Sex (M/F)
M
Accident location
A
2
Nature of accident
B
2
Classification of accident
C
3
Causes
D
4
Load conditions of vehicle
E
1
F
1
Intersection type of control
G
-
Weather condition
H
1
Age of victim
I
3
Type of victim
J
1
Type of vehicle
K
3
Fatal
persons
affected
No of
Major
1
Minor
1
Ambu
Help provided by
A 1. Urban 2. Rural
B 1. Overturned 2. Head On Collision 3. Hit from Back 4. Hit to Fix Object 5. Right turn Collision
6. Left turn Collision 7. Veered Out off The Road 8. Hit Pedestrian 9. Unknown/Hit & Ran Away
C 1. Fatal 2. Major injury 3. Minor injury
D 1. Drunken 2. Over Speeding 3. Vehicle out of Control 4. Driven on wrong side 5. Mechanical
Problem 6. Drowsiness/Not Applicable 7. Fault of Driver
E 1. Normally Loaded 2. Overloaded/Handing 3. Empty 4. Unknown
G 1. T-Junction 2. Y-Junction 3. Four arm Junction 4. Staggered Junction 5. Junction with more
than 6. Round about Junction
H 1. Fine/Clear 2.Mist/Fog 3. Cloudy 4. Light Rain 5. Heavy Rain 6. Strong Wind 7. Dust Storm 8.
Cold 9. Hot
I 1. 0-18 Years 2. 18-25 Years 3. 25-40 Years 4.40-60 Years 5. 60-80 Years
K 1. Two Wheeler 2. Auto Rickshaw 3. Car/Jeep 4. Bus 5. Light Truck 6. Heavy Truck 7. Tractor
8. Bicycle 9. Cycle Rickshaw 10. Hand Drawn Cart 11. Animal Drawn Cart
Contact
Toll Complaint Name of the Details of Compliance by the
SNo Date details of
plaza No person complaint concessionaire
person
Mr. Shailendra Mr. Shailendra
Gurjar, LIG- Complaints
44,RSS regarding Pot holes Pot holes are
1 81 8/9/2016
mohalla, on the Highway repaired
Shivaji Nagar, may cause
Bhopal (M.P.) accidents.
Dr. Diwakar
Animals are
Dr. Anil complaints that
continuously driven
Diwakar, HIG presence of
out from the Road
Swarganga Animals and also
2 82 10/9/2016 by the Highway
Complex Bus Pot holes on road
Patrolling team and
Stand Seoni are obstructing the
Pot holes are
(M.P.) driving which may
repaired.
cause accidents.
The Exemption
under Indian Toll
(Army and Air
Maj. Sidharth while force) Act 1901, to
travelling in army personnel
Maj. Sidharth, personal car wants travelling in private
3 83 11/9/2016 238 Fd wksp Exemption from vehicle may be
C/o- 56 APO Toll Fee on given if on Govt.
production of I.D. duty with requisite
Card pass as specified
in the Indian Toll
(Army and Air
Force Rules, 1942)
Name of Encroacher
Encroachment width and
Encroachment type
(Temporary/ Permanent)
Side (LHS/RHS)
District/
length
Village
Tehsil
SNo
etc)
212+50 Temporar Tea Vijay Kumar
1 LHS Kurnool Kurnool New 7 5mX3.5m
0 y stall Reddy
213+20 Dinnedevara Permanen Godow 10.5m X
2 RHS Kurnool Existing 5 Buddana
0 Padu t n 4m
S.No Date Chainage (Km) Side Time of Closure Reasons for Lane Remarks
Closure & Approval
From To Details
9/9/201 215+30 215+35
1 6 0 0 RHS 1pm-4pm Patch work
Description of
SNo NCP/ SNo Date of issue Chainage Side AE Remarks
defect
1 311 15.08.2016 Potholes 311+200 LHS To be repaired
To be filled
2 312 15.08.2016 Cracking 311+500 RHS
immediately
3
4
Annexure 2 onwards:
AE should include comments, status update, data points and reports in following
annexures which have not been included elsewhere in the main report. Such reports
may include but not limited to:
Minutes of review meeting
Correspondence details
Weather report
Organizational chart of Concessionaire and AE
Project photographs
Authority Engineer
[NAME OF CONSULTING FIRM]
Worksheets under Section 1 (‘Road inventory data’) shall be updated from surveys conducted
only once at the time of completion testing. Worksheets under Section 2 (‘Road condition data’)
shall be updated from surveys carried out annually for FWD attributes and biannually for the
remaining attributes.
The fields to be updated in each of the worksheets are described below. Each description is
followed by an example of data for a sample project.
Road inventory data consists of parameters which provide basic information about roads such
as pavement type, number of lanes, topography, etc. These parameters are largely static in
nature, and therefore a survey to update this dataset shall be conducted only once at the time
of completion testing. The road inventory data shall be used to update specific worksheets
listed below.
The following table lists the fields which need to be populated for the ‘LRP Master’ attribute.
The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Carriageway Type’
attribute. The descriptions of the fields are given below.
Field Description Example
NH Number New National Highway number NH0065
HYD-VIJ
Section Code Code indicating starting and ending locations of section (Hyderabad-
Vijayawada)
Start Chainage Chainage of the start point (in km) 0.500
End Chainage Chainage of the end point (in km) 1.500
Type of carriageway, classified into one of the below Divided
categories:
Carriageway Type
Divided
Undivided
Survey Date Date of survey in the format <DD-MM-YY> 06-05-17
Latitude Latitude of survey point 9.98897
Longitude Longitude of survey point 78.02671
The following table lists the fields which need to be populated for the ‘Road Type’ attribute.
The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Pavement Type’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Pavement Width’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Shoulder Type’
attribute. The descriptions of the fields are given below.
Field Description Example
NH Number New National Highway number NH0065
Code indicating starting and ending locations of HYD-VIJ (Hyderabad-
Section Code section Vijayawada)
Start Chainage Chainage of the start point (in km) 0.500
Section End
NH Number Start Chainage Direction ShoulderType Survey Date Latitude Longitude
Code Chainage
NH00xx ABC-DEF 0.000 0.763 Increasing No Shoulder 09-01-16 9.98897 78.02671
NH00xx ABC-DEF 0.763 0.834 Increasing Gravel 09-01-16 9.98444 78.02934
The following table lists the fields for the ‘Shoulder Width’ attribute, which need to be
populated. The descriptions of the fields are given below.
Shoulder
Section Start End Shoulder Survey
NH Number Direction Width Latitude Longitude
Code Chainage Chainage Width Date
Value
No
NH0xxx ABC-DEF 0.000 0.785 Increasing Shoulder 0.0 03-01-16 9.98897 78.02671
No
NH0xxx ABC-DEF 0.785 2.612 Increasing 0.0 03-01-16 9.98444 78.02934
Shoulder
NH0xxx ABC-DEF 2.612 3.170 Increasing 1-2m 2.0 03-01-16 9.98341 78.03004
NH0xxx ABC-DEF 3.170 5.194 Increasing 1-2m 2.0 03-01-16 9.98107 78.03078
NH0xxx ABC-DEF 5.194 6.793 Increasing 1-2m 2.0 03-01-16 9.96328 78.04160
NH0xxx ABC-DEF 6.793 11.404 Increasing 1-2m 2.0 03-01-16 9.95385 78.05255
The following table lists the fields which need to be populated for the ‘Topography’ attribute.
The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Cross Section’ attribute.
The descriptions of the fields are given below.
Field Description Example
NH Number New National Highway number NH0065
Code indicating starting and ending locations of HYD-VIJ (Hyderabad-
Section Code section Vijayawada)
Start Chainage Chainage of the start point (in km) 0.500
The following table lists the fields which need to be populated for the ‘Drain Type’ attribute.
The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Median Opening’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Right of Way’ attribute.
The descriptions of the fields are given below.
Remarks
Survey Date Date of survey in the format <DD-MM-YY> 06-05-17
Bitumino
Bituminou Bituminou BSC Bitumino BBC Granular
Sec- Start End us Base Granul
NH Direc- Paveme s Surface s Surface Constru us Base Constru Base
tion Chai Chai Course ar Base
No. tion nt Type Course Course c-tion Course c-tion Thickne
Code nage nage Thicknes Type
Type Thickness Year Type Year ss
s
NH00x ABC- Both
x DEF 0.0 5.0 side Asphalt BC 40.0 2015 DBM 100 2015 WMM 250
NH00x ABC- Both
5.0 11.0 Asphalt BC 40.0 2015 DBM 80 2015 WMM 250
x DEF side
NH00x ABC- Both
x DEF 11.0 20.0 side Asphalt SDBC 25.0 2015 BM 115 2015 WMM 250
NH00x ABC- Both
20.0 22.0 Asphalt BC 40.0 2015 DBM 100 2015 WMM 250
x DEF side
NH00x ABC- Both
22.0 30.0 Asphalt SDBC 25.0 2015 BM 115 2015 WMM 250
x DEF side
NH00x ABC- Both
30.0 31.0 Asphalt BC 40.0 2015 DBM 100 2015 WMM 250
x DEF side
(table continued…)
Paveme
Dry
Paveme nt Granula
GB PQC Lean Dry DLC Granul GSB
nt Quality r Desig
Constr Constr Concret Lean Constr ar Constru Survey Latit Longit
Quality Concret SubBase n
uction uction e Concret uction SubBas ction Date ude ude
Concret e Thickne CBR
Year Year Thickn e Type Year e Type Year
e Type Thickne ss
ess
ss
05-05-
2015 NA NA NA NA NA NA GSB 300 2015 5% 9.99 78.03
15
05-05-
2015 NA NA NA NA NA NA GSB 300 2015 5% 15 9.98 78.03
05-05-
2015 NA NA NA NA NA NA GSB 300 2015 5% 9.98 78.03
15
05-05-
2015 NA NA NA NA NA NA GSB 300 2015 5% 9.98 78.03
15
05-05-
2015 NA NA NA NA NA NA GSB 300 2015 5% 15 9.96 78.04
05-05-
2015 NA NA NA NA NA NA GSB 300 2015 5% 15 9.95 78.05
The following table lists the fields which need to be populated for the ‘Carriageway Furniture’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Wayside Amenities’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Land Use’ attribute.
The descriptions of the fields are given below.
Field Description Example
NH Number New National Highway number NH0065
Code indicating starting and ending locations of HYD-VIJ (Hyderabad-
Section Code
section Vijayawada)
Start Chainage Chainage of the start point (in km) 0.500
End Chainage Chainage of the end point (in km) 1.500
Direction of survey Increasing
Direction Increasing (chainage)
Decreasing (chainage)
Land use classified into one of the below categories: Commercial
Residential;
Commercial;
Land Use Industrial;
Agricultural;
Water bodies;
Mixed.
Survey Date Date of survey in the format <DD-MM-YY> 06-05-17
Latitude Latitude of survey point 9.98897
Road condition data consists of parameters which directly affect maintenance requirements of
the road. These parameters are dynamic in nature, and therefore a survey to update this
dataset shall be conducted annually for FWD testing and every six months as per Annexure IV
for network survey vehicle testing. The first survey shall be conducted at the time of
completion testing and the remaining surveys shall be conducted as per the defined frequency.
As an example, if majority of highway length (>50%) passes through a state, where defined
survey months are May and November, if completion testing is conducted in April, then the
first network survey shall be conducted in the month of April. This shall be considered as the
network survey to be conducted in the month of May. The 2nd survey shall be conducted in the
month of November, the 3rd survey shall be conducted in the month of May and so on. As
regards FWD, the first test/survey shall be conducted at the time of completion in April. The
2nd test/survey shall be conducted in April of next year and so on.
The road condition data shall be used to update specific worksheets, which are listed below.
2.1 Visual condition
The following table lists the fields which need to be populated for the ‘Visual Condition’
attribute. The descriptions of the fields are given below.
2.2 Roughness
The following table lists the fields which need to be populated for the ‘Roughness’ attribute.
The descriptions of the fields are given below.
2.3 Rutting
The following table lists the fields which need to be populated for the ‘Rutting’ attribute. The
descriptions of the fields are given below.
Field Description Example
NH Number New National Highway number NH0065
HYD-VIJ (Hyderabad-
Section Code Code indicating starting and ending locations of section
Vijayawada)
Start Chainage Chainage of the start point (in km) 0.500
The following table lists the fields which need to be populated for the ‘Texture Depth’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘Skid Resistance’
attribute. The descriptions of the fields are given below.
The following table lists the fields which need to be populated for the ‘FWD’ attribute. The
descriptions of the fields are given below.
Pea
NH Lane Air Surface
Sectio Chainag Directio k Deflection Deflection Locatio Deflection
Numbe Numbe Temperatur Temperatur
n Code e n Loa 0 1 n1 2
r r e e
d
ABC-
NH00xx DEF 0.500 RHS R2 32.6 43.7 45.7 333 188 300 243
ABC-
NH00xx DEF 1.000 LHS L1 29.9 32.6 45.4 317 163 300 217
ABC-
NH00xx 1.499 RHS R1 33.0 39.3 45.7 246 110 300 153
DEF
ABC-
NH00xx DEF 2.000 LHS L2 28.7 32.4 46.0 293 130 300 187
ABC-
NH00xx 2.500 RHS R2 33.7 45.8 45.3 429 232 300 316
DEF
ABC-
NH00xx 3.000 LHS L1 29.0 33.0 45.7 343 204 300 252
DEF
ABC-
NH00xx 3.500 RHS R1 33.5 45.4 44.5 373 194 300 268
DEF
ABC-
NH00xx 4.010 LHS L2 28.9 33.5 45.0 348 201 300 254
DEF
ABC-
NH00xx DEF 4.500 RHS R2 33.3 40.3 46.0 393 241 300 301
(table continued…)
(table continued…)
Sub
Loca ElasticMod ElasticMod ElasticMod CorrectedElastic CorrectedElasti CorrectedElasti Bitumi Bas GS gra
tion ulusBitumi ulusGranul ulusSubGra ModulusBitumin cModulusGran cModulusSubGr nousL eLa BLa de
8 nousE1 arE2 deE3 ousE1 ularE2 adeE3 ayer yer yer CB
R
2400 6213 185 100 6447 135 78 105 230 200 0.08
2400 5356 195 100 5295 143 78 105 230 200 0.08
2400 3359 396 90 3424 300 69 105 230 200 0.08
2400 4830 226 100 4770 169 78 105 230 200 0.08
2400 4570 137 97 4781 93 75 105 230 200 0.08
2400 8454 135 100 8374 91 78 105 230 200 0.08
2400 4394 165 100 4590 117 78 105 230 200 0.08
2400 7817 139 96 7762 95 74 105 230 200 0.08
2400 7666 123 95 7847 81 73 105 230 200 0.08
(table continued…)
Deflection1 Surface deflection at the test load center, measured in micron 140
Surface deflection at 300 mm from the test load center, measured
Deflection2 in micron 121
Surface deflection at 600 mm from the test load center, measured
Deflection3 in micron 108
Surface deflection at 900 mm from the test load center, measured
Deflection4 in micron 101
Concrete Slab Thickness of concrete slab, measured in mm
Thicknessh 300
Area of deflection basin, calculated from measured deflections, in
Area of Deflection
Basin cm2 761
Radius of Relative Radius of relative stiffness, calculated in mm
Stiffness 823
NormalizedDeflectiond Normalized deflection at location 1, in mm 3.1
1
NormalizedDeflectiond Normalized deflection at location 2, in mm 2.9
2
NormalizedDeflectiond Normalized deflection at location 3, in mm 2.4
3
NormalizedDeflectiond Normalized deflection at location 4, in mm 1.9
4
Modulus of Subgrade Modulus of subgrade reaction, measured in MPa/m 131
Reaction k
Elastic Modulus of Elastic modulus of concrete, calculated in MPa 26118
Concrete Ec
Cube Strength of Cube strength of concrete, calculated inMPa 27
Concrete fck
Flexural strength of Flexural strength of concrete, calculated in MPa 3.7
concrete fmr
Date Of Testing Date of testing in the format <DD-MM-YY> 06-05-17
Note: This draft Agreement is a generic document and shall be modified based on
particular of the Project.
Between
(Name of Client)
And
(Name of Consultant)
Dated:
Page No.
2.7.1 Definition…………………………………………..
2.7.2 No Breach of Contract ……………………………..
2.7.3 Measures to be taken
2.7.4 Extension of Time
2.7.5 Payments
2.7.6 Consultation
2.8 Suspension…………………………………………………
2.9 Termination ………………………………………..
2.9.1 By the Client ………………………………
2.9.2 By the Consultants ………………………..
2.9.3 Cessation of Rights and Obligations ………
2.9.4 Cessation of Services ………………………
2.9.5 Payment upon Termination ………………..
2.9.6 Disputes about Events of Termination …….
3. Obligations of the Consultants ……………………
3.1 General
3.1.1 Standard of Performance…………..
3.1.2 Law Governing Services …………..
V ANNEXURES..…………………………………………
This CONTRACT (hereinafter called the “Contract”) is made the day of the Month of
, 201 , between, on the one hand (hereinafter Called the
“Client) and, on the other hand hereinafter called the “Consultants”)
[Note*: If the Consultants consist of more than one entity, the above should be partially
amended to read as follows:
“…(hereinafter called the “Client”)and, on the other hand, a joint venture consisting of the
following entities, each of which will be jointly severally liable to the Client for all the Consultants’
obligations under this Contract, namely,
and
(hereinafter called“ Consultants”)]
WHEREAS
(a) the Client has requested the Consultants to provide certain consulting services as
defined in the General Conditions of Contract attached to this Contract
(hereinafter called the “Services”);
(b) the Consultants, having represented to the Client that they have the required
processional skills ,and personnel and technical resources ,have agreed to provide
the Services on the terms and conditions set forth in this Contract;
1. The following documents attached hereto shall be deemed to form an integral part of
this Contract:
(a) The General Conditions of Contract (hereinafter called “GC”)’
(b) The Special Conditions of Contract (hereinafter called “SC”);
(c) The following Appendices:
[Note: If any of these Appendices are not used, the words “Not Used” should be inserted
below next to the title of the Appendix on the sheet attached hereto carrying the title of that
Appendix ].
IN WITNESS WHEREOF, the Parties hereto have caused this Contract to be signed in their
respective names as of the day and year first above written.
By
(Authorized Representative)
By
(Authorized Representative)
[Note: If the Consultants consist of more than one entity, all of these entities should appear as
signatures, e.g. in the following manner ]
1. General Provisions
Unless the context otherwise requires, the following terms whenever used in this
Contract have the following meanings:
1.1 Definitions
Or any part thereof; “Foreign Personnel” means such persons who at the time
of being so hired had their domicile outside the Government’s Country, “Local
Personnel” means such persons who at the time of being so hired had their
domicile inside the Government’s Country; and ‘key personnel’ means the
personnel referred to in Clause GC 4.2 (a).
(l) "SC" means the Special Conditions of Contract by which these General
Conditions of Contract may be amended or supplemented;
(m) "Services" means the work to be performed by the Consultants pursuant to his
contract, as described in Appendix A hereto. The scope of work will be strictly
as given in various Clauses in TOR. The approach and methodology to be
adopted by the Consultant for carrying out the assignment as Authority
Page 189 of 229
Engineer may be modified depending on the site requirements and work
programme of the EPC Contract or after mutual discussions with Employer, the
EPC Contractor and the Authority Engineer. The work plan as indicated by the
Consultant may be modified accordingly to the site requirements.
(n) "Sub-Consultant and or Associates "means any entity to which the Consultants
subcontract any part of the Services in accordance with the provisions of Clause
GC 3.7; and
(o) "Third Party" means any person or entity other than the Government, the
Client, the Consultants or a Sub-consultant.
This Contract, its meaning and interpretation, and the relation between the Parties
shall be governed by the Applicable Law.
1.4 Language
This Contract has been executed in the language specified in the SC, which shall be the
binding and controlling language for all matters relating to the meaning or
interpretation of this Contract.
1.5 Headings
The headings shall not limit, alter or affect the meaning of this Contract.
1.6 Notices
1.6.1 Any notice, request or consent required or permitted to be given or made pursuant to
this Contract shall be in writing. Any such notice, request or consent shall be deemed
to have been given or made when delivered in person to an authorized representative
of the Party to whom the communication is addressed, or when sent by registered mail,
telegram or facsimile to such Party at the address specified in the SC.
1.6.3 A Party may change its address for notice hereunder by giving the other Party notice of
such change pursuant to the provisions listed in the SC with respect to Clause GC 1.6.2.
1.7 Location
The Services shall be performed at such locations as are specified in Appendix A hereto
and, where the location of a particular task is not so specified, at such locations whether
in Government's Country or elsewhere, as the Client may approve.
Page 190 of 229
1.8 Authority of Member in Charge
In case the Consultants consist of a joint venture of more than one entity, the Members
hereby authorize the entity specified in the SC to act on their behalf in exercising all the
Consultants' rights and obligations towards the Client under this Contract, including
without limitation the receiving of instructions and payments from the Client.
Any action required or permitted to be taken, and any document required or permitted
to be executed, under this Contract by the Client or the Consultants may be taken or
executed by the officials specified in the SC.
Unless otherwise specified in the SC, the Consultants, Sub-consultants and Personnel
shall pay such taxes, duties, fees and other impositions as may be levied under the
Applicable Law. Goods &Service tax as applicable shall be paid to the Authority’s
Engineer while making payment for services rendered. The consultants shall then
deposit the same with the tax authorities and provide a proof of having done so within
next 90 days in line with policy circulars issued by Employer.
This Contract shall come into force and effect on the date (the" Effective Date") of the
Client's notice to the Consultants instructing the Consultants to begin carrying out the
Services. This notice shall confirm that the effectiveness conditions, if any, listed in the
SC have been met.
If this Contract has not become effective within such time period after the date of the
Contract signed by the Parties as shall be specified in the SC, either Party may, by not
less than four (4) weeks' written notice to the other Party, declare this Contract to be
null and void, and in the event of such a declaration by either Party, neither Party shall
have any claim against the other Party with respect hereto.
The Consultants shall begin carrying out the Services at the end of such time period
after the Effective Date as shall be specified in the SC.
2.4 Expiration of Contract
Unless terminated earlier pursuant to Clause GC2.9 hereof, this Contract shall expire
when services have been completed and all payments have been made at the end of
such time period after the Effective Date as shall be specified in the SC.
2.6 Modification
Modification of the terms and conditions of this Contract, including any modification of
the scope of the Services, may only be made by written agreement between the Parties
as the case may be, has been obtained. Pursuant to Clause GC 7.2 hereof, however, each
Party shall give due consideration to any proposals for modification made by the other
Party.
2.7.1. Definition
(a) For the purposes of this Contract, "Force Majeure" means an event which is
beyond the reasonable control of a Party, and which makes a Party's
performance of its obligations hereunder impossible or so impractical as
reasonably to be considered impossible in the circumstances, and includes,
but is not limited to, war, riots, civil disorder, earthquake, fire, explosion,
storm, flood or other adverse weather conditions, strikes, lockouts or other
industrial action ( except where such strikes, lockouts or other industrial
action are within the power of the Party invoking Force Majeure to prevent),
confiscation or any other action by government agencies.
(b) Force Majeure shall not include (i) any event which is caused by the
negligenceorintentionalactionofapartyorsuchParty'sSub-consultantsor
agents or employees, nor (ii) any event which a diligent Party could
reasonably have been expected to both(A) take in to account at the time of
the conclusion of this Contract and(B) avoid or overcome in the carrying out
of its obligations hereunder .
(c) Force Majeure shall not include insufficiency of funds or failure to make any
payment required hereunder.
The failure of a Party to fulfill any of its obligations hereunder shall not be considered
to be a breach of, or default under, this Contract insofar as such inability arises from an
event of Force Majeure, provided that the Party affected by such an event has taken all
reasonable precautions, due care "and reasonable alternative measures, all with the
objective of carrying out the terms and conditions of this Contract.
(a) A Party affected by an event of Force Majeure shall take all reasonable
measures to remove such Party's inability to fulfill its obligations hereunder
with a minimum of delay.
Page 192 of 229
(b) A Party affected by an event of Force Majeure shall notify the other Party
of such event as soon as possible, and in any event not later than fourteen
(14) days following the occurrence of such event, providing evidence of
the nature and cause of such event, and shall similarly give notice of the
restoration of normal conditions as soon as possible.
(c) The Parties shall take all reasonable measures to minimize the consequences
of any event of Force Majeure.
Any period within which a Party shall, pursuant to this Contract, complete any action
or task, shall be extended for a period equal to the time during which such Party was
unable to perform such action as a result of Force Majeure.
Extension of Time for providing services of the Authority’s Engineer shall be extended
concurrently with the Extension of Time granted, if any, to the EPC Contractor for the
project, subject to satisfactory performance of the Authority’s Engineer.
2.7.5 Payments
During the period of their inability to perform the Services as a result of an event of
Force Majeure, the Consultants shall be entitled to be reimbursed for additional costs
reasonably and necessarily incurred by them during such period for the purposes of
the Services and in reactivating the Services after the end of such period.
2.7.6 Consultation
Not later than thirty (30) days after the Consultants, as the result of an event of Force
Majeure, have become unable to perform a material portion of the Services, the Parties
shall consult with each other with a view to agreeing on appropriate measures to be
taken in the circumstances.
2.8. Suspension
The Client may, by written notice of suspension to the Consultants, suspend all
payments to the Consultants hereunder if the Consultants fail to perform any of their
obligations under this Contract, including the carrying out of the Services, provided
that such notice of suspension (i) shall specify the nature of the failure, and (ii) shall
request the Consultants to remedy such failure within a period not exceeding thirty
(30) days after receipt by the Consultants of such notice of suspension.
2.9 Termination
The Client may, by not less than thirty (30)days' written notice of termination to the
Consultants (except in the event listed in paragraph (f) below, for which there shall be
a written notice of not less than sixty (60) days), such notice to be given after the
occurrence of any of the events specified in paragraphs(a)through(h)of this Clause GC
Page 193 of 229
2.9.1, terminate this Contract.
(a) if the Consultants fail to remedy a failure in the performance of their obligations
hereunder, as specified in a notice of suspension pursuant to Clause GC 2.8
herein above, within thirty (30) days of receipt of such notice of suspension or
within such further period as the Client may have subsequently approved in
writing;
(b) If the Consultants become (or, if the Consultants consist of more than one
entity, if any of their Members becomes) in solvent or bankrupt or enter into
any agreements with their creditors for relief of debt or take advantage of any
law for the benefit of debtors or go into liquidation or receivership whether
compulsory or voluntary;
(c) If the Consultants fail to comply with any final decision reached as a result of
arbitration proceedings pursuant to Clause GC 8 hereof;
(d) If the Consultants submit to the Client a statement which has a material effect
on the rights, obligations or interests of the Client and which the Consultants
know to be false;
(e) if, as the result of Force Majeure, the Consultants are unable to perform a
material portion of the Services for a period of not less than sixty (60) days; or
(f) if the Client, in its sole discretion and for any reason whatsoever, decides to
terminate this Contract.
(g) if the consultant, in the judgment of the Client has engaged in corrupt or
fraudulent practices in competing for or in executing the Contract. For the
purpose of this clause:
(h) if EPC Contractor represents to Employer that the Consultant is not discharging
his duties in a fair, efficient and diligent manner and if the dispute remains
unresolved, Employer may terminate this contract.
The Consultants may, by not less than thirty (30) days' written notice to the Client, such
notice to be given after the occurrence of any of the events specified in paragraphs (a)
through (d) of this Clause GC2.9.2, terminate this Contract:
Page 194 of 229
(a) if the Client fails to pay any money due to the Consultants pursuant to this
Contract and not subject to dispute pursuant to Clause 8 hereof within forty-
five (45) days after receiving written notice from the Consultants that such
payment is overdue;
(b) if the Client is in material breach of its obligations pursuant to this Contract and
has not remedied the same within forty-five (45) days (or such longer period
as the Consultants may have subsequently approved in writing) following the
receipt by the Client of the Consultants' notice specifying such breach;
(c) if, as the result of Force Majeure, the Consultants are unable to perform a
material portion of the Services for a period of not less than sixty (60) days; or
(d) if the Client fails to comply with any final decision reached as a result of
arbitration pursuant to Clause GC 8 hereof.
Upon termination of this Contract pursuant to Clauses GC 2.2 or GC 2.9 hereof, or upon
expiration of this Contract pursuant to Clause GC2.4 hereof, all rights and obligations
of the Parties hereunder shall cease, except:
(i) such rights and obligations as may have accrued on the date of termination or
expiration;
(iii) the Consultants' obligation to permit inspection, copying and auditing of their
accounts and records set forth in Clause GC 3.6 (ii) hereof; and
(iv) any right which a Party may have under the Applicable Law
Upon termination of this Contract by notice of either Party to the other pursuant to
Clauses GC2.9.1 or GC2.9.2 hereof, the Consultants shall, immediately upon dispatch or
receipt of such notice, take all necessary steps to bring the Services to a close in a
prompt and orderly manner and shall make every reasonable effort to keep
expenditures for this purpose to a minimum. With respect to documents prepared by
the Consultants and equipment and materials furnished by the Client, the Consultants
shall proceed as provided, respectively, by Clauses GC 3.9 or GC 3.10 hereof.
Upon termination of this Contract pursuant to Clauses GC 2.9.1 or GC 2.9.2 hereof, the
Client shall make the following payments to the Consultants (after offsetting against
these payments any amount that may be due from the Consultant to the Client}:
If either Party disputes whether an event specified in paragraphs (a) through (e) of
Clause GC 2.9.1or in Clause GC2.9.2 hereof has occurred, such Party may, within forty-
five (45) days after receipt of notice of termination from the other Party, refer the
matter to arbitration pursuant to Clause GC8 hereof, and this Contract shall not be
terminated on account of such event except in accordance with the terms of any
resulting arbitral award.
3.1 General
The Consultants shall perform the Services and carry out their obligations hereunder
with all due diligence, efficiency and economy, in accordance with generally accepted
professional techniques and practices, and shall observe sound management practices,
and employ appropriate advanced technology and safe and effective equipment,
machinery, materials and methods "The Consultants shall always" act, in respect of any
matter relating to this Contract or to the Services, as faithful advisers to the Client, and
shall at all times support and safeguard the Client's legitimate interests in any dealings
with Sub-consultants or Third Parties.
The Consultants shall perform the Services in accordance with the Applicable Law and
shall take all practicable steps to ensure that any Sub- consultants and or Associates, as
well as the Personnel of the Consultants and any Sub-consultants and or
Associates,comply with the Applicable Law. The Client shall advise the Consultants in
writing of relevant local customs and the Consultants shall, after such notifications,
respect such customs.
The Remuneration of the Consultants pursuant to Clause GC6 hereof shall constitute
the Consultants' sole remuneration in connection with this Contract or the Services
and, subject to ClauseGC3.2.2 hereof, the Consultants shall not accept for their own
benefit any trade commission, discount or similar payment in connection with
activities pursuant to this Contract or to the Services or in the discharge of their
obligations hereunder, and the Consultants shall use their best efforts to ensure that
Page 196 of 229
any Sub-consultants and or Associates, as well as the Personnel and agents of either of
them, similarly shall not receive any such additional remuneration.
3.2.2 If the Consultants, as part of the Services, have the responsibility of advising the Client
on the procurement of goods, works or services, the Consultants shall comply with any
applicable procurement guidelines of the Client (Employer)and or Associates Bank or
of the Association, as the case maybe, and other funding agencies and shall at all times
exercise such responsibility in the best interest of the Client. Any discounts or
commissions obtained by the Consultants in the exercise of such procurement
responsibility shall be for the account of the Client.
The Consultants agree that, during the term of this Contract and after its termination,
the Consultants and any entity affiliated with the Consultants, as well as any Sub-
Consultant and or Associates and any entity affiliated with such Sub Consultant and or
Associates, shall be disqualified from providing goods works or services (other than
the Services and any continuation thereof) for any project resulting from or closely
related to the Services. .
The Consultants shall not engage, and shall cause their Personnel as well as their Sub-
consultants and or Associates and their Personnel not to engage, either directly or
indirectly, in any of the following activities:
(a) during the term of this Contract, any business or professional activities in the
Government's country which would conflict with the activities assigned to
them under this Contract; and
(b) after the termination of this Contract, such other activities as may be
specified in the SC.
3.3 Confidentiality
The Consultants, their Sub-consultants and the Personnel of either of them shall not, either
during the term or within two (2) years after the expiration of this Contract, disclose any
proprietary or confidential information relating to the Project, the Services, this Contract or
the Client's business or operations without the prior written consent of the Client.
Subject to additional provisions, if any, set forth in the SC, the Consultants’ liability
under this Contract shall be as provided by the Applicable Law.
The Consultants (i) shall take out and maintain, and shall cause any Sub-consultants to
take out and maintain, at their (or the Sub-consultants', as the case may be) own cost
but on terms and conditions approved by the Client, insurance against the risks, and
for the coverages, as shall be specified in the SC, and (ii) at the Client's request, shall
provide evidence to the Client showing that such insurance has been taken out and
Page 197 of 229
maintained and that the current premiums therefore have been paid.
The Consultants(i)shall keep accurate and systematic accounts and records in respect
of the Services, hereunder, in accordance with internationally accepted accounting
principles and in such form and detail as will clearly identify all relevant time charges
and cost, and the bases thereof (including such bases as may be specifically referred to
in the SC) ; (ii) shall permit the Client or its designated representative periodically, and
upto one year from the expiration or termination of this Contract, to inspect the same
and make copies thereof as well as to have them audited by auditors appointed by the
Client; and (iii) shall permit the client to inspect the Consultant's accounts and records
relating to the performance of the Consultant and to have them audited by auditors
appointed by the client.
The Consultants shall obtain the Client's prior approval in writing before taking any of
the following actions:
(a) appointing such members of the Personnel as are listed in Appendix ‘C’
("Consultants' Sub-consultants' Key Personnel") merely by title but not by
name;
(b) entering into a subcontract for the performance of any part of the Services, it
being understood (i) that the selection of the Sub-Consultant and the terms and
conditions of the subcontract shall have been approved in writing by the Client
prior to the execution of the subcontract, and (ii) that the Consultants shall
remain fully liable for the performance of the Services by the Sub-Consultant
and its Personnel pursuant to this Contract; and
The Consultants shall submit to the Client the reports and documents specified in
Appendix B here to, in the form, in the numbers and within the time periods set forth
in the said Appendix.
All plans, drawings, specifications, designs, reports, other documents and software
prepared by the Consultants for the Client under this Contract shall become and remain
the property of the Client, and the Consultants shall, not later than upon termination or
expiration of this Contract, deliver all such documents to the Client, together with a
detailed inventory thereof. The Consultants may retain a copy of such documents and
software. Restrictions about the future use of these documents and software, if any,
shall be specified in the SC.
Equipment and materials made available to the Consultants by the Client, or purchased
Page 198 of 229
by the Consultants with funds provided by the Client, shall be the property Of the Client
and shall be marked accordingly. Upon termination or expiration of this Contract, the
Consultants shall make available to the Client an inventory of such equipment and
materials and shall dispose of- such equipment and materials in accordance with the
Client's instructions. While in possession of such equipment and materials, the
Consultants, unless otherwise instructed by the Client in writing, shall insure them at
the expense of the Client in an amount equal to their full replacement value.
4.1 General
The Consultants shall employ and provide such qualified and experienced Personnel
and Sub-consultants as are required to carry out the Services.
(a) The titles, agreed job descriptions, minimum qualification and estimated
periods of engagement in the carrying out of the Services of each of the
Consultants' Key Personnel are described in Appendix C. If any of the Key
Personnel has already been approved by the clients his/her name is listed as
well.
(b) If required to comply with the provisions of Clause GCC 3.1.1 hereof,
adjustments with respect to the estimated periods "of engagement of Key
Personnel set forth in Appendix C may be made by the Consultants by written
notice to the Client, provided (i) that such adjustments shall not alter the
originally estimated period of engagement of any individual by more than 10%
or one week, whichever is larger, and (ii) that the aggregate of such adjustments
shall not cause payments under this Contract to exceed the ceilings set forth in
Clause GC 6.1(b) of this Contract. Any other such adjustments shall only be
made with the Client's written approval.
(c) If additional work is required beyond the scope of the Services specified in
Appendix A, the estimated periods of engagement of Key Personnel set forth in
Appendix C may be increased by agreement in writing between the Client and
the Consultants, provided that any such increase shall not, except as otherwise
agreed, cause payments under this Contract to exceed the ceilings set for thin
Clause GC 6.1 (b) of this Contract.
The Key Personnel i.e. Professional Staff and Sub-consultants listed by title as well as
By name in Appendix C are hereby approved by the Client. In respect of other Key
Personnel which the Consultants propose, to use in the carrying out of the Services, the
Consultants shall submit to the client for review and approval a copy of their
biographical data and (in the case of Key personnel to be used within the country of
the Government) a copy of a satisfactory medical certificate in the form attached here
to as Appendix D. If the Client does not object in writing(stating the reasons for the
objection) within thirty (30) calendar days from the date of receipt of such biographical
(a) Working hours and holidays for Key Personnel are set forth in Appendix E
hereto. To account for travel time, foreign Personnel carrying out Services
inside the Government's country shall be deemed to have commenced (or
finished) work in respect of the Services such number of days before their
arrival in (or after their departure from) the Government's country as is
specified in Appendix E hereto.
(b) The Personnel of all types engaged by Consultant to provide Services on this
Contract shall not been titled to be paid for overtime nor to take paid sick leave
or vacation leave except as specified in Appendix E hereto, and except as
specified. In such Appendix, the Consultants' remuneration shall be deemed to
cover these items. All leave to be allowed to the Personnel is included in the
staff-months of service set for in Appendix C. Any taking of leave by Personnel
shall be subject to the prior approval by the Client and the Consultants shall
ensure that absence for leave purposes will not delay the progress and
adequate supervision of the Services.
4.5.1 In case notice to commence services pursuant to Clause 2.1 of this Contract is not
ordered by Client within 120 days of signing of contract the key personnel can excuse
themselves on valid grounds, e.g., selection on some other assignment, health problem
developed after signing of contract, etc. In such a case no penalty shall be levied on the
Firm or on the person concerned. The firm shall however be asked to give a
replacement by an equal or better scoring person, whenever mobilization is ordered.
4.5.2 In case notice to commence services is given within 120 days of signing of contract
the, the Authority expects all the Key Personnel specified in the Proposal to be
available during implementation of the Agreement. The Authority will not consider
any substitution of Key Personnel except under compelling circumstances beyond the
control of the Consultant and the concerned Key Personnel. Such substitution shall be
limited to not more than three Key Personnel subject to equally or better qualified and
experienced personnel being provided to the satisfaction of the Authority.
Replacement of the Team Leader will not normally be considered and may lead to
disqualification of the Applicant or termination of the Agreement. Replacement of one
Key Personnel shall be permitted subject to reduction of remuneration equal to 5 %
(five per cent) of the total remuneration specified for the Key Personnel who is
proposed to be replaced. In case of second replacement the reduction in remuneration
shall be equal to 10% (ten per cent) and for third and subsequent replacement, such
reduction shall be equal to 15% (fifteen per cent) If the consultant finds that any of
the personnel had made false representation regarding his qualification and
experience, he may request the Employer for replacement of the personnel. There
shall be no reduction in remuneration for such replacement. The replacement shall
Page 200 of 229
however be of equal or better score. The personnel so replaced shall be debarred from
future projects for 2 years.
4.5.5 If the Employer (i) finds that any of the Personnel has committed serious misconduct
or has been charged with having committed a criminal action or (ii) has reasonable
ground to be dissatisfied with the performance of any of the Personnel, then the
consultant shall, at the Employer’s written request specifying the grounds therefore,
forthwith provide a replacement with qualifications and experience acceptable to him.
For such replacement there will be no reduction in remuneration.
4.5.6 If any member of the approved team of a consultant engaged by NHIDCL leaves that
consultant before completion of the job, he shall be barred for a period of 6 months to
24 months from being engaged as a team member of any other consultant working (or
to be appointed) for any other NHIDCL / MoRTH projects.
The person designated as the Team Leader of the Consultant’s Personnel shall be
responsible for the coordinated, timely and efficient functioning of the Personnel. In
addition, the Consultant shall designate a suitable person from its Head Office as
Project Coordinator who shall be responsible for day to day performance of the
Services.
5. Obligations of the Client
Unless otherwise specified in the SC, the Client shall use its best efforts to ensure that
the Government shall:
(c) provide the Consultants, Sub-consultants and Personnel with work permits and
such other documents as shall be necessary to enable the Consultants, Sub-
consultants or Personnel to perform the Services;
(d) assist for the Personnel and, if appropriate, their eligible dependents to be
provided promptly with all necessary entry and exit visas, residence permits,
exchange permits and any other documents required for their stay in
Government's country;
(e) Facilitate prompt clearance through customs of any property required for the
Services and of the personal effects of the Personnel and their -eligible
dependents;
(f) Issue to officials, agents and representatives of the Government all such
instructions as may be necessary or appropriate for the prompt and effective
implementation of the Services;
(g) assist the Consultants and the Personnel and any Sub-consultants and or
The Client warrants that the Consultants shall have, free of charge, unimpeded access
to all land in the Government's country in respect of which access is required for the
performance of the Services. The Client will be responsible for any damage to such land
or any property thereon resulting from such access and will indemnify the Consultants
and each of the Personnel in respect of liability for any such damage, unless such
damage is caused by the default or negligence of the Consultants or any Sub-Consultant
or the Personnel of either of them.
5.3 Change in the Applicable Law
If, after the date of this Contract, there is any change in the Applicable Law with respect
to taxes and duties which increases or decreases the cost or reimbursable expenses
incurred by the Consultants in performing the Services, then the remuneration and
reimbursable expenses otherwise payable to the Consultants under this Contract shall
be increased or decreased accordingly by agreement between the Parties hereto, and
corresponding adjustments shall be made to the ceiling amounts specified in Clause GC
6.1(b).
The Client shall make available to the Consultants and the Personnel, for the purposes
of the services and free of any charge, the services, facilities and property described in
Appendix F at the times and in the manner specified in said Appendix F, provided that
if such services, facilities and property shall not be made available to the Consultants
as and when so specified, the Parties shall agree on (i) any time extension that it may
be appropriate to grant to the Consultants for the performance of the Services, (ii) the
manner in which the Consultants shall procure any such services, facilities and
property from other sources, and (iii) the additional payments, if any, to be made to the
Consultants as a result thereof pursuant to Clause GC 6.l(c) hereinafter.
5.5 Payment
In consideration of the Services performed by the Consultants under this Contract, the
Client shall make to the Consultants such payments and in such manner as is provided
by Clause GC 6 of this Contract.
Page 202 of 229
5.6 Counterpart Personnel
(a) If so provided in Appendix F hereto, the Client shall make available to the
Consultants, as and when provided in such Appendix F, and free of charge, such
counterpart personnel to be selected by the Client, with the Consultants' advice,
as shall be specified in such Appendix F. Counterpart personnel shall work
under the exclusive direction of the Consultants. If any member of the
counterpart personnel fails to perform adequately any work assigned to him by
the Consultants which is consistent with the position occupied by such-
member, the Consultants may request the replacement of such member, and
the Client shall not unreasonably refuse to act upon such request.
(b) If counterpart personnel are not provided by the Client to the Consultants as
and when specified in Appendix F, the Client and the Consultants shall agree on
(i) how the affected part of the Services shall be carried out, and (ii) the
additional payments, if any, to be made by the Client to the Consultants as a
result thereof pursuant to Clause GC 6.1(c) hereof.
6. Payments to the Consultants
(a) An estimate of the cost of the Services payable is set forth in Appendix G.
(b) Except as may be otherwise agreed under ClauseGC2.6 and subject to Clause GC
6.1(c), payments under this Contract shall not exceed the ceilings specified in
the SC. The Consultants shall notify the Client as soon as cumulative charges
incurred for the Services have reached 80% of these ceilings.
(c) Notwithstanding ClauseGC6.l (b) hereof, if pursuant to clauses GC5.3, 5.4 or 5.6
hereof, the Parties shall agree that additional payments shall be made to the
Consultants in order to cover any necessary additional expenditures not
envisaged in the cost estimates referred to in Clause GC6.1(a) above, the ceiling
or ceilings, as the case maybe, set forth in ClauseGC6.1(b) above shall be
increased by the amount or amounts, as the case may be, of any such additional
payments.
(a) Subject to the ceilings specified in Clause GC6.1(b)hereof, the Client shall pay to
the Consultants (i) remuneration asset for thin Clause GC6.2(b),and(ii)
reimbursable expenditures asset forth in Clause GC6.2(c).If specified in the SC,
said remuneration shall be subject to price adjustment as specified in the SC.
(b) Remuneration for the Personnel shall be determined on the basis of time
actually spent by such Personnel in the performance of the Services after the
date determined in accordance with Clause GC2.3 and Clause SC2.3 (or such
other date as the Parties shall agree in writing) (including time for necessary
travel via the most direct route) at the rates referred to, and subject to such
additional provisions as are set forth, in the SC.
(c) Reimbursable expenditures actually and reasonably incurred by the
Consultants in the performance of the Services, as specified in SC.
Page 203 of 229
(d) Notwithstanding anything to the contrary stated in the GCC and SCC, it shall be
mandatory to deploy the key personnel and sub-professional as per the Man-
Months Input specified in the Terms of Reference.
Inadequate deployment of key personnel and sub-professional shall lead to
deduction in the monthly payment as per following table. The key personnel
and sub- professional shall be considered to be inadequately deployed if
he/she is not present for atleast 90% of the time stipulated in the month, as
per the Man Months Input in the Terms of Reference and the Deployment
Schedule proposed by the firm.
Sr. Personnel % reduction in
No. monthly payment
Normal Highway Project
1 Team Leader cum Senior Highway Engineer 20%
2 Resident Engineer cum Highway Engineer 25%
3 Bridge/Structural Engineer 20%
4 Other Key Personnel 20%
5 Sub- Professional Staff 15%
For avoidance of doubt, in case the Team Leader cum Senior Highway Engineer
has not been made available for 90% of the stipulated time in the month, then
only 80% of the monthly payment shall be released. In the case of “Other Key
Personnel (Sr. No. 4)” and “Sub – Professional Staff (Sr. No. 5)”, the average
availability across the group shall be considered for calculation.
All payments shall be made in Indian Rupees and shall be subjected to applicable Indian
laws withholding taxes if any.
(a) The Client shall cause to be paid to the Consultants an interest bearing advance
payment as specified in the SC, and as otherwise set forth below. The advance
payment will be due after provision by the Consultants to the Client of a bank
guarantee by a bank acceptable to the Client in an amount (or amounts) and in
a currency (or currencies) specified in the SC, such bank guarantee (I) to remain
effective until the advance payment has been fully set off as provided in the SC,
and(ii)to be in the form set for thin Appendix I hereto or in such other form as
the Client shall have approved in writing.
(b) As soon as practicable and not later than fifteen (15days)after the end of each
calendar month during the period of the Services, the Consultants shall submit
to the Client, in duplicate, itemized statements, accompanied by copies of
receipted invoices, vouchers and other appropriate supporting materials, of the
amounts payable pursuant to Clauses GC6.3 and 6.4 for such month. Each
monthly statement shall distinguish that portion of the total eligible costs
which pertains to remuneration from that portion which pertains to
reimbursable expenditures.
Page 204 of 229
(c) 75% of bill raised by the Consultant shall be paid within 72 Hrs and remaining
bill may be paid after due scrutiny. The Client shall cause the payment of the
Consultants periodically as given in schedule of payment above within thirty
(30) days after the receipt by the Client of bills with supporting documents.
Only such portion of a monthly statement that is not satisfactorily supported
may be withheld from payment. Should any discrepancy be found to exist
between actual payment and costs authorized to be incurred by the
Consultants, the Client may add or subtract the difference from any subsequent
payments. Interest at the rate specified in the SC shall become payable as from
the above due date on any amount due by, but not paid on such due date.
(d) The final payment under this Clause shall be made only after the final report
and a final statement, identified as such, shall have been submitted by the
Consultants and approved as satisfactory by the Client. The Services shall be
deemed completed and finally accepted by the Client and the final report and
final statement shall be deemed approved by the Client as satisfactory ninety
(90) calendar days after receipt of the final report and final statement by the
Client unless the Client, within such ninety (90)-day period, gives written notice
to the Consultants specifying in detail deficiencies in the Services, the final
report or final statement. The Consultants shall there upon promptly make any
necessary corrections, and upon completion of such corrections, the
foregoing process shall be repeated. Any amount which the Client has paid or
caused to be paid in accordance with this Clause in excess of the amounts
actually payable in accordance with the provisions of this Contract shall be
reimbursed by the Consultants to the Client within thirty, (30) days after
receipt by the Consultants of notice thereof. Any such claim by the Client for
reimbursement must be made within twelve (12) calendar months after receipt
by the Client of a final report and a final statement approved by the Client in
accordance with the above.
(e) All payments under this Contract shall be made to the account of the
Consultants specified in the SC.
The Parties undertake to act in good faith with respect to each other's rights under this
Contract and to adopt all reasonable measures to ensure the realization of the
objectives of this Contract.
The Parties recognize that it is impractical in this Contract to provide for every
contingency which may arise during the life of the Contract, and the Parties hereby
agree that it is their intention that this Contract shall operate fairly as between them,
and without detriment to the interest of either of them, and that, if during the term of
this Contract either Party believes that this Contract is operating unfairly, the Parties
will use their best efforts to agree on such action as may be necessary to remove the
cause or causes of such unfairness, but no failure to agree on any action pursuant to
this Clause shall give rise to a dispute subject to arbitration in accordance with Clause
Page 205 of 229
GC 8 hereof.
8. Settlement of Disputes
The Parties shall use their best efforts to settle amicably all disputes arising out of or in
connection with this Contractor the interpretation thereof.
8.2.1 Any dispute, difference or controversy of whatever nature howsoever arising under or
out of or in relation to this Agreement (including its interpretation) between the
Parties, and so notified in writing by either Party to the other Party (the “Dispute”)
shall, in the first instance, be attempted to be resolved amicably in accordance with the
conciliation procedure set forth in Clause 8.3.
8.2.2 The Parties agree to use their best efforts for resolving all Disputes arising under or in
respect of this Agreement promptly, equitably and in good faith, and further agree to
provide each other with reasonable access during normal business hours to all non –
privileged records, information and data pertaining to any dispute.
8.3 Conciliation
In the event of any Dispute between the Parties, either Party may call upon
[Chairman of NHIDCL] and the Chairman of the Board of Directors of the
Consultant or a substitute thereof for amicable settlement, and upon such
reference, the said persons shall meet no later than 10(ten) days from the date
of reference to discuss and attempt to amicably resolve the Dispute. If such
meeting does not take place within the 10(ten) day period or the Dispute is not
amicably settled within 15(fifteen) days of the meeting or the Dispute is not
resolved as evidenced by the signing of written terms of settlement within 30
(thirty) days of the notice in writing referred to in Clause 8.2.1 or such longer
period as may be mutually agreed by the Parties, either Party may refer the
Dispute to arbitration in accordance with the Provisions of Clause 8.4.
8.4 Arbitration
8.4.1. Any Dispute which is not resolved amicably by conciliation, as provided in Clause
8.3, shall be finally decided by reference to arbitration by an Arbitral Tribunal
appointed in accordance with Clause 8.4.2. Such arbitration shall be held in
accordance with the Rules of Arbitration of the International Centre for
Alternative Dispute Resolution, New Delhi (the “Rules”), or such other rules as
may be mutually agreed by the Parties, and shall be subject to the provisions of
the Arbitration and Conciliation Act, 1996 as amended. The venue of such
arbitration shall be ***** and the language of arbitration proceedings shall be
English.
8.4.2 Each dispute submitted by a Party to arbitration shall be heard by a sole arbitrator to
be appointed as per the procedure below
(a) Parties may agree to appoint a sole arbitrator or, failing agreement on the
identity of such sole arbitrator within thirty(30) days after receipt by the other
If for any reason an arbitrator is unable to perform his function, a substitute shall be
appointed in the same manner as the original arbitrator.
The sole arbitrator selected pursuant to Clause 8.2.1 hereof shall be expert with
extensive experience in relation to the matter in dispute.
8.4.5 The Arbitrators shall make a reasoned award (the “Award”). Any Award made in any
arbitration held pursuant to this Clause 8 shall be final and biding on the Parties as
from the date it is made, and the Consultant and the Authority agree and undertake to
carry out such Award without delay.
8.4.6 The Consultant and the Authority agree that an Award may be enforced against the
Consultant and/or the Authority, as the case may be, and their respective assets
wherever situated.
8.4.7. This Agreement and the rights and obligations of the Parties shall remain in full force and
effect, pending the Award in any arbitration proceedings hereunder
8.4.8 Miscellaneous
(a) Proceedings shall, unless otherwise agreed by the parties be held in Delhi.
(b) The English language shall be the official language for all purposes;
(c) The decision of sole arbitrator shall be final and binding and shall be
enforceable in any court of competent jurisdiction, and the Parties hereby
waive any objections to or claims of immunity in respect of such enforcement;
and
(d) The schedule of Expenses and Fee payable to the Arbitrator shall be as under
Sr. Particulars of Fees and Maximum amount payable per case
No. Expenses
1 Fee (i) Rs. 25,000/- per day;
9. Fake CV
1.1(a) The words’’ in the Government’s country” are amended to read ‘in INDIA”
Attention:
Telex :
Facsimile :
Attention:
Cable address :
Telex :
Facsimile :
(Note: If the Consultants consist of a joint venture of more than one entity, the name of
the entity whose address is specified in SC1.6.1shouldbeinsertedhere. If the Consultants
consist of one entity, this Clause 1.8 should be deleted from the SC)
1.10 The Consultants, Sub-consultants and the Personnel shall pay the taxes, duties, fees,
Page 209 of 229
levies and other impositions levied under the existing, amended or enacted laws during life
of this contract and the client shall perform such duties in regard to the deduction of such
tax as may be lawfully imposed.
2.2 The time period shall be four months or such other time period as the parties may
agree in writing.
2.3 The time period shall be one month or such other time period as the Parties may
agree in writing.
2.4 The time period shall be 66 months (18 month for construction period and48 months
for Maintenance period)
(a) Except in case of gross negligence or willful misconduct on the part of the
Consultants or on the part of any person or firm acting on behalf of the
Consultants in carrying out the Services, the Consultants, with respect to
damage caused by the Consultants to the Client's property, shall not be liable
to the Client:
(i) for any indirect or consequential loss or damage; and
(iii) The policy should be issued only from an Insurance Company operating in
India.
(iv) The policy must clearly indicate the limit of indemnity in terms of“ Any One
Accident”(AOA) and “Aggregate limit on the policy period”(AOP) and in no case
should be for an amount less than stated in the contract.
(v) If the Consultant enters into an agreement with Employer in a joint venture or
‘in association’, the policy must be procured and provided to Employer by the
joint venture/in association entity and not by the individual partners of the
joint venture/association.
(vi) The contract may include a provision thereby the Consultant does not cancel
the policy midterm without the consent of the Employer. The insurance
company may provide an undertaking in this regard.
(b) This limitation of liability shall not affect the Consultants' liability, if any, for
damage to Third Parties caused by the Consultants or any person or firm acting
on behalf of the Consultants in carrying out the Services.
Page 210 of 229
(c) Professional Liability Insurance may be accepted for initially one year which
shall be extended annually for five years. PLI shall be uniformly taken for a
period of five years.
(a) Third Party motor vehicle liability insurance as required under Motor Vehicles
Act,1988 in respect of motor vehicles operated in India by the Consultants or
their Personnel or any Sub-consultants or their Personnel for the period of
consultancy.
(b) Third Party liability insurance with a minimum coverage, of Rs. 1.0 million for
the period of consultancy.
(c) Professional liability insurance as per 3.4 (a) (ii) of SC of the consultancy, with
a minimum coverage equal to estimated remuneration and reimbursable.
(d) Employer's liability and workers' compensation insurance in respect of the
Personnel of the Consultants and of any Sub-consultant, in accordance with the
relevant provisions of the Applicable Law, as well as, with respect to such
Personnel, any such life, health, accident, travel or other insurance as may be
appropriate; and
(e) Insurance against loss of or damage to(i) equipment purchased in whole or in
part with funds provided under this Contract, (ii) the Consultants' property
used in the performance of the Services, and(iii)any documents prepared by the
Consultants in the performance of the Services.
"(i) taking any action under a civil works contract designating the Consultants as
"Authority’s Engineer", for which action, pursuant to such civil works contract,
the written approval of the Client as "Employer" is required".
3.9 The Consultants shall not use these documents for purposes unrelated to this
Contract without the prior written approval of the Client.
4.6 "The person designated as Team Leader cum Senior Highway Engineer in Appendix C
shall serve in that capacity, as specified in Clause GC 4.6."
6.2(a) "Payments for remuneration and reimbursable items made in accordance with
Clause GC 6:2(a) :
(i) Consultants shall be paid billing rates for services rendered by the
personnel of all categories namely (i) key Personnel; (ii) sub-Professional
personnel and (iii) Support staff on man-month basis . Billing rates of
remaining items of the financial proposal, namely (i) transportation , (ii)
Duty travel to site (iii) Office Rent, (iv) office supplies communication etc.
(v) reports & document printing and (vi) survey equipment etc. shall be
worked out month wise as per actual expenditure Beginning 13th months
Page 211 of 229
from the last date of submission of bid, billing rates shall be increased to
cover all items of contract i.e. remuneration, vehicle hire, office rent,
consumables, furniture etc. @ 5% every 12 months. However, for
evaluation and award of the Bid proposals, the quoted initial rate (as
applicable for first 12 months from last date of submission of bid) shall be
multiplied by the total time input for each position on this contract, i.e.
without considering the increase in the billing rates. All payments shall be
made in Indian Rupees and shall be subjected to applicable Indian laws
withholding taxes if any.
(ii) Remuneration paid pursuant to the rates set forth in Appendix G shall be
adjusted every twelve (12) months (and, the first time, with effect for the
billing rates earned in the 13thcalendar month after the last date of
submission of bid) by 5% every 12month for personnel.
Notwithstanding any other provisions in the agreement in this regard, this provision
will prevail and override any other provision to the contrary in this agreement.
6.2(b) (i) (1) Payment of Authority Engineer shall be released on approval of the monthly
reports. Report shall be approved by the Authority only if it includes all the
sections prescribed in the format and submitted as per specified timelines.
(2) Payment shall be released as per rates quoted in Appendix C3- Breakup of Local
currency costs
(3) For equipment based road inspection to be conducted in O&M phase, payment
shall be released as per actual use of equipment on road and rates quoted in
Appendix C3- Breakup of Local currency costs.
(5) It is understood(i)that the remuneration rates shall cover(A) such salaries and
allowances as the Consultants shall have agreed to pay to the Personnel as
well as factors for social charges and overhead, and (B)the cost of back
stopping by home office staff not included in the Personnel listed in Appendix
C, and(C)the Consultants' fee;(ii)that bonuses or other means of profit-sharing
shall not be allowed as an element of overhead, and(iii)that any rates specified
for persons not yet appointed shall be provisional and shall be subject to
revision, with the written approval of the Client, once the applicable salaries
and allowances are known.
(6) Remuneration for periods of less than one month shall be calculated on an
hourly basis for actual time spent in the Consultants' home office and directly
attributable to the Services(one hour being equivalent to 1/240th of a month)
and on a calendar-day basis for time spent away from home office(one day
being equivalent to 1/30th of a month).
6.2(b)(ii) The rates for foreign and local Personnel are set forth in Appendix G
2) The bank guarantee shall be in the amount and in the currency of the the
advance payment.
[Note: Insert account number, type of account and name and address of the Bank]
8.2 Disputes shall be settled by arbitration in accordance with the following provisions:
[Give detailed descriptions of the Services to be provided; dates for completion of various tasks,
place of performance for different tasks; specific tasks to be approved by Client, etc.]
[List format, frequency, contents of reports and number of copies; persons to receive them; dates
of submission etc. If no reports are to be submitted, state here "Not applicable".}
[List under: C-l Titles [and names, if already available}, detailed job descriptions and
minimum qualifications. Experience of Personnel to be assigned to
work in India, and staff- months for each.
C-3 Same as C-l for Key foreign Personnel to be assigned to work outside
India.
[Show here an acceptable form of medical certificate for foreign Personnel to be stationed in
India. If there is no need for a medical certificate, state here: "Not applicable. "]
The form of Medical Certificate as required under the rules of Govt. of India
The Consultants Key personnel and all other Professional / Sub Professional / Support
Staff/Sub-Consultancy personnel shall work 6 days (Mondays through Saturday) every week
and observe the Gazetted Holidays of Government of India as Holidays. The Consultant shall
work as per the work program of the EPC Contractor. In this context in case the work plan of
the Consultant needs suitable modifications, the same shall be carried out and submitted to the
client for consideration. The Consultants hours of work normally shall match with that of
Contractor’s activities on the site. No extra remuneration shall be claimed or paid for extra
hours of work required in the interest of Project completion.
In respect of foreign personnel, one day per trip as travel time from and to the country of the
Government shall be allowed.
F-1 Services, facilities and property to be made available to the Consultants by the
Client.
1. Monthly rates for local Personnel (Key Personnel and other Personnel)
To
Address of Employer:
1
WHEREAS [Name and address of Consultants] (hereinafter called “the
consultants”) has undertaken, in pursuance of Contract No. dated
to provides the services on terms and conditions set forth in this
Contract [Name of contract and brief description of works) (hereinafter
called the “the Contract”).
AND WHEREAS it has been stipulated by you in the said Contract that the Consultants shall
furnish you with a Bank Guarantee by a recognized bank for the sum specified there in as
security for compliance with his obligations in accordance with the Contract;
NOW THEREOF we hereby affirm that we are the Guarantor andresponsible to you, on behalf
2 [in words], such sum
of the Consultants up to a total of [amount of Guarantee]
being payable in the types and proportions of currencies in which the Contract Price is payable,
and we undertake to pay you, upon your first written demand and without cavil or argument,
any sum or sums within the limits of [amount of Guarantee] as aforesaid without your needing
to prove or to show grounds or reasons for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Consultants before
presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the
Contract or of the services to be performed there under or of any of the Contract documents
which may be made between you and the Consultants shall in any way release us from any
liability under this guarantee, and we hereby waive notice of any such change, addition or
modification.
The liability of the Bank under this Guarantee shall not be affected by any change in the
constitution of the consultants or of the Bank.
Notwithstanding anything contained herein before, our liability under this guarantee is
restricted to Rs. (Rs. ) and the
guarantee shall remain valid till . Unless a claim or a demand in
writing is made up on us on or before all our liability under this
guarantee shall cease.
This guarantee shall be valid for a period of 86 months i.e. upto 2 months beyond the expiry of
Particulars Details
Name of the Beneficiary National Highways and Infrastructure
Development Corporation Limited
Beneficiary Bank Account No. 90621010002659
Beneficiary Bank Branch IFSC SYNB0009062
Beneficiary Bank Branch Name Transport Bhawan, New Delhi
Beneficiary Bank Address Syndicate Bank, Transport Bhawan, 1st
Parliament street, New Delhi-110001
1.
Address 2.
(Name &Occupation)
Date
(To be stamped in accordance with Stamp Act, if any, of the country of issuing bank)
Date:
Dear Sir,
For Contract (hereinafter called the "Contract") (scope of work) and the Client having agreed to
make an advance payment to the Consultant for performance of the above Contract amounting
to (in words and figures) as an advance against Bank Guarantee to be furnished by the Consultant.
The Client shall have the fullest liberty without affecting in any way the liability of the Bank under
this Guarantee, from time to time to vary the advance or to extend the time for performance of the
contract by the Consultant. The Client shall have the fullest liberty without affecting this guarantee,
to postpone from time to time the exercise of any powers vested in them or of any right which they
might have against the Client and to exercise the same at any time in any manner, and either to
enforce or to forebear to enforce any covenants, contained or implied, in the Contract between the
Client and the Consultant other course or remedy or security available to the Client. The bankshall
not be relieved of its obligations under these presents by any exercise by the Client of its liberty with
reference to the matters aforesaid or any of them or by reason of any other act or forbearance or
other acts of omission or commission on the part of the Client or any other Indulgence shown by
the Client or by any other matter or thing whatsoever which under law would but for this provision
have the effect of relieving the Bank.
The Bank also agrees that the Client at its option shall be entitled to enforce this Guarantee against
Page 223 of 229
the Bank as a principal debtor, in the first instance without proceeding against the Consultant and
notwithstanding any security or other guarantee that the Client may have in relation to the
Consultant's liabilities.
Notwithstanding anything contained herein above our liability under this guarantee is limited to
and it shall remain in force upto and including And shall be extended from
time to time for such period (not exceeding one year), as may be desired by M/s. on
whose behalf this guarantee has been given.
Bank Guarantee has been sent to authority’s bank through SFMS gateway as per the details
below: -
Particulars Details
Name of the Beneficiary National Highways and Infrastructure
Development Corporation Limited
Beneficiary Bank Account No. 90621010002659
Beneficiary Bank Branch IFSC SYNB0009062
Beneficiary Bank Branch Name Transport Bhawan, New Delhi
Beneficiary Bank Address Syndicate Bank, Transport Bhawan, 1st
Parliament street, New Delhi-110001
WITNESS
(signature)
(Signature)
(Name)
(Name)
Dated
Strike out, whichever is not applicable.
Note1: The stamp papers of appropriate value shall be purchased in the name of bank
Who issues the "Bank Guarantee”.
Note 2: The bank guarantee shall be from a Nationalized Indian Bank or reputed foreign
Page 224 of 229
commercial Bank acceptable to client for Foreign Consultant with counter guarantee from
Nationalized Bank. Bank guarantee furnished by Foreign Consultant shall be confirmed by any
Nationalized Bank in India.
Letter of invitation
Letter of Award
Memorandum of Understanding
between
_____________________
And
__________________________
Whereas the NHIDCL (the ‘Employer’) has invited proposal for appointment of Authority’s Engineer
for
(Name of project) hereinafter called the Project.
(i) will be the lead partner and will be the other JV partner/s.
(ii) (lead partner) shall be the incharge of overall administration of contract and
shall be authorised representative of all JV partners for conducting all business for and on
behalf of the JV during the bidding process and subsequently, represent the joint venture for and
on behalf of the JV for all contractual matters for dealing with the Employer/EPC Contractor if
Consultancy work is awarded to JV.
(iii) All JV partners do hereby undertake to be jointly and severely responsible for all the obligation
and liabilities relating to the consultancy work and in accordance with the Terms of Reference
of the Request for Proposal for the Consultancy Services.
(iv) Subsequently, if the JV is selected to provide the desired consultancy services, a detailed MOU
indicating the specific project inputs and role of each partner/s along with percentage sharing
of cost of services shall be submitted to the Employer (Consultant may submit the detailed
MOU along with percentage sharing of cost at the time of bidding also).
DISCLAIMER
The Applicant must read all the instructions in the RFP and submit the same accordingly.