Ujjain Sewera

1
OFFICE OF THE UJJAIN MUNICIPAL CORPORATION, UJJAIN, DIST. - UJJAIN
TENDER DOCUMENT
LUMPSUM RATE TENDER FOR SURVEY, INVESTIGATION, DESIGN, CONSTRUCTION, TESTING AND
COMMISSIONING OF SEWERAGE NETWORK & SEWAGE TREATMENT FOR UJJAIN CITY UNDER
UJJAINMUNICIPAL CORPORATION, UJJAIN
NIT Number and Date :-----------

Agreement Number and Date:______________________________________
Name of Work: Sewerage Network & Sewage Treatment for Ujjain City under Ujjain Municipal Corporation,
UJJAIN
Name of the Contractor : ______________________________________
Probable Amount of Contract
(Rs. In Figure) : Rs 36752.57Lacs
(Rs. In Words) : Rupees Thirty Six Thousand Seven Hundred Fifty Two Lakhs and Fifty Seven Thousand
Only
Contract Amount
(Rs. In Figure) : ________________________________________
(Rs. In Words) : ________________________________________
Stipulated Period of Completion: 36 months including rainy season

2
Table of Contents
Page
Particulars
Section No No
Section 1 NIT 03
Instructions to Bidders (ITB) 06
Section 2 Bid Data Sheet 13
Annexure-A to M
Annexure - A- Key Dates 15
Annexure –B- Affidavit 16
Annexure –C- Pre Qualification Criteria 17
Annexure –D- Special Eligibility Criteria 18
Annexure –E- Specifications 19
Annexure –F- Procedure for participating in E-tendering 20
Annexure –G- Joint Venture 22
Annexure –H- Organizational Details 23
Annexure –I- Technical Proposal 24
Annexure –J- Financial Bid 31
Annexure –K- Materials to be issued by department 33
Annexure –L- Letter of Acceptance (LOA) 34
Annexure –M- Performance Security 35
Table of Clauses
Part-I General Conditions of Contract (GCC) 36
Contract Data 46
Annexure--N to W
Annexure –N- Drawings 49
Annexure –O- Detail of milestones 55
Annexure –P- Compensation of Delay 56
Annexure –Q- List of Equipment for Quality Control Lab 57
Section 3
Annexure –R- Price Adjustment 59
Annexure –S- Bank Guarantee form for Mobilization Machinery Advance 60
Annexure –T- Bank Guarantee Form for Secured Advance 61
Annexure –U- Physical Completion Certificate 63
Annexure –V- Final Completion Certificate 64
Annexure –W- Salient Features of Labour laws 65
Annexure –W1 - Construction Safety 67
Part-II Special Conditions of Contract (SCC) 71
Section 4 Price Break-up Schedule 77
Section 5 Agreement Form 87
Annexure - X to Z
Section 6 Annexure –X- Billing Break-Up 88
Annexure –Y- Operation and Maintenance (Service Level Agreement) 89
3
OFFICE OF THE UJJAIN MUNICIPAL CORPORATION, UJJAIN, DIST- UJJAIN
Section – 1
Notice Inviting e-Tenders
NIT No. 3407/e-tendering Date: 19-04-2017
Online Lumpsum bids for the following works under “AMRUT” are invited from registered contractors and
firms of repute fulfilling eligibility criteria:
Probable
Amount Completion
S.No. Work
(Rs. In Period (months)
lakhs)
Survey, Investigation, Design, Construction, Testing and

Commissioning of Sewerage Network& Sewage Treatment
in Ujjain City under Ujjain Municipal Corporation, Ujjain
including,
1.0 Providing laying and jointing of sewerage pipelines
including construction of manholes and sewer
appurtenances. 36 months
1.0 2.0 Construction, supply, erection, testing and 36752.57 including rainy
commissioning of Sewerage Treatment Plant including season
PLC-SCADA and RCC sumpwell alongwith providing
and installation of pumps from sumpwell to STP.
3.0 Providing house sewer chambers and laterals for
connecting sewer to consumer sewer lines
4.0 Providing and laying of HT feeder connection upto
Sewerage treatment plant
5.0 Providing house sewerage connections
1. Interested Bidder can view the NIT on website http://www.mpeproc.gov.in.and www.mpurban.gov.in

2. The Bid Document can be purchased only Online from 00:00 hrs 21-04-2017 to 17:30 hrs 22-05-
2017.
3. Amendment to NIT, if any, would be published on website only, and not in Newspaper.
The Bidder shall operate and maintain the Sewerage system of Ujjain City for 10 years after successful
completion of the works as per Tender. The initial period of 5 years after completion shall be treated as
Defect Liability Period (DLP).
COMMISSIONER
UJJAIN MUNICIPAL CORPORATION, UJJAIN
4
Notice Inviting e-Tenders

OFFICE OF THE UJJAINMUNICIPALCORPORATION,UJJAIN, DIST- UJJAIN
NIT No. 3407/e-tendering Date: 19-04-2017
Online lump-sum bids for the following works under “AMRUT” (estimated on UADD SOR w.e.f. 10/05/2012)
are invited from registered contractors and firms of repute fulfilling eligibility criteria:
S.No. Name of the work Probable Earnest Cost of Category of Time of

amount of Money Bid Contractor Completio
contract Deposit Document n
(Rs. In (EMD) (In (In
Lacs) Rs) Rupees)
Survey, Investigation, Valid
Design, Construction, Registration 36 months
Testing and Commissioning
of Sewerage Network of with the including
Ujjain City in UJJAIN Government rainy
MUNICIPAL area including, 36752.57 50,00,000/- 50,000/- of Madhya season.
Pradesh,
1.0 Providing laying and
PWD.
jointing of sewerage
pipelines including
construction of
manholes and sewer
appurtenances.
2.0 Construction, supply,
erection and
commissioning of
1.0 Sewerage treatment
plant and RCC
sumpwell alongwith
providing and
installation of pumps
from sumpwell to STP.
3.0 Providing house sewer
chambers and laterals
for connecting sewer to
consumer sewer lines
4.0 Providing and laying of
HT feeder connection
upto Sewerage
treatment plant
5.0 Providing house
sewerage connection
1. All details relating to the Bid Document(s) can be viewed and downloaded free of cost from the website
mentioned in NIT.
5
2. Bid document can be purchased after making online payment of portal fees through Credit/Debit/Cash
Card/internet banking.
3. At the time of submission of the Bid the eligible bidder shall be required to:
i) pay the cost of Bid Document;
ii) deposit the Earnest Money;
iii) Submit a check list; (As required in Clause 12 of Bid Data Sheet)
iv) Submit an affidavit duly Notarized as per Annexure – B
v) Undertaking as per Clause no. 13 (Special Condition Regarding Conditional TENDER of Section
– 3, Conditions of Contract, Part –II Special Conditions of Contract
Details can be seen in the Bid Data Sheet
4. ELIGIBILTY FOR BIDDERS:
(a) At the time of submission of the bid, the bidder should have valid registration with the Government of
Madhya Pradesh, PWD. However, such bidders who are not registered with the Government of
Madhya Pradesh and are eligible for registration can also submit their bids after having applied for
registration with appropriate authority.
(b) The bidder shall be required to have valid registration with MPPWD at the time of signing of the
Contract.
(c) Failure to sign the contract by the selected bidder, for whatsoever reason, shall result in forfeiture of
the earnest money deposit.
5. Pre-qualification – Prequalification conditions, wherever applicable, are given in the Bid Data Sheet &
Annexure - C.
6. Special Eligibility - Special Eligibility Conditions, if any, are given in the Bid Data Sheet & Annexure – D
7. The Bid Document can be Purchased only Online 00:00 hrs 21-04-2017 to 17:30 hrs 22-05-2017. Other
key dates may be seen in Bid data sheet.
8. Amendment to NIT, if any, would be published on website only, and not in Newspaper.
COMMISSIONER
UJJAIN MUNICIPAL CORPORATION
6
SECTION 2
INSTRUCTIONS TO BIDDERS (ITB)
A. GENERAL
1. SCOPE OF BID
The detailed scope of work, hereinafter referred to as “Work” is “Survey, Investigation, Design,
Construction Testing and Commissioning of waste water collection, treatment and disposal
system(Sewerage Project) and its operation and maintenance for a period of 10 years after completion of
construction work. The initial period of 5 years after completion shall be treated as Defect Liability Period
(DLP). A brief description of project is as given below,
Background
Population of Ujjain town under Ujjain Municipal Corporation, Ujjain
 Population (as per 2011 census) is515,215
 The estimated population for the 2020 is 6,13,830
 The estimated population for the 2035 is 7,35,840
 The estimated population for the 2050is 8,58,585
 The number of households in MUNICIPALCORPORATION (2020) are about122766
 The number of households in MUNICIPALCORPORATION (2033) are about 147168
 The number of households in MUNICIPALCORPORATION (2048) are about 171717
 The UJJAIN MUNICIPAL CORPORATION, UJJAIN has developed/completed water supply
project and the water @ 135 litres per capita per day (lpcd) is available for next 30 years period.
With the water availability ensured @ 135 lpcd it is very important to have an integrated sewerage system
in town for collection, treatment and safe disposal of generated waste water. At present there is no
sewerage system in the town and the sewage from households is generally collected in the individual
septic tanks or otherwise disposed off directly to the existing drains. The sewage from the households
and septic tanks finally goes into open drains and Nallahas and then finally discharged into Kshipra River
thereby polluting holy river and Ghats.
The above open drains/nallahs are creating nuisance for the common man. Therefore, an integrated
sewerage system is proposed, wherein it is envisaged that sewage is collected systematically in well-
designed sewers, transported upto the sewage treatment plant and it is treated in such a way that the
effluent satisfies the parameters prescribed by Central Pollution Control Board of India. After
Implementation of project, Treated Water will be reclaimed and is proposed to be used for horticulture,
road side irrigation, road washing and irrigation purposes.
Project
Ujjain Municipal Corporation, Ujjain wants to execute sewerage project for the probable population of
2050. The project report prepared by the Municipal Corporation, Ujjain envisage following works in the
project area,
i) Providing laying and jointing of sewerage pipelines including construction of manholes and sewer
appurtenances.
ii) Construction, supply, erection and commissioning of Sewerage treatment plant and RCC sumpwell
alongwith providing and installation of pumps from sumpwell to STP.
iii) Providing house sewer chambers and laterals for connecting sewer to consumer sewer lines
iv) Providing and laying of HT feeder connection up to Sewage treatment plant with PLC-SCADA
v) Providing House Sewerage Connection
vi) The construction shall be ensured in such a way that there is minimum possible inconvenience to the
public and the traffic. The reconstruction of roads will be carried out to original surface and pavement
conditions.
The tender is hereby invited for the execution of sewerage project wherein the successful Bidder has to
lay the sewer lines for entire Ujjain City including all necessary works related to sewer lines, sewer
appurtenances, sumpwells/sewage pumping stations, intermediate pumping and sewage treatment plant
7
including SCADA-PLC etc. and restore the roads to their original condition with respect to surface and
pavement characteristics. The house connections shall also be covered under this project.
The essence of this sewerage project shall be,
a) Providing 100% coverage to un-sewered area of Ujjain town.

b) Providing flexibility of connecting existing sewer network in private colonies to proposed sewer
network either at the outfall point or inlet of colony septic tank.
c) Providing flexibility to add the sewage from multistoried buildings to the proposed sewerage network
with the provision of payment on the basis of per household monthly tariff.
d) The collection of sewage including house hold connections to achieve the desired flow in the sewer
lines for generating minimum desired velocity in sewer lines.
e) Treatment of the sewage to prevailing standards so that the treated water may be reused / disposedof
as per accepted practices.
f) Reconstruction of roads to its original conditions.
Therefore,
i) The bidder by the completion of construction shall ensure house hold connections to each house
hold. The sewage connection shall be made upto the individual toilet outlet so as to collect the raw
sewage. For making the individual sewage connection, due considerations shall be given to access to
the house hold and accordingly side lanes and back lanes are to be identified and used. Existing
useful sewer lines, if found, shall also be suitably integrated with the proposed sewerage system.
ii) As far as possible the entire system shall be designed and operated on the principles of gravity flow.
The BOQ attached with the present invitation is based on detailed survey, investigation, tentative
designing and estimation as given in the Detailed Project Report (DPR). The Bidder shall examine the
DPR and its contents. For achieving the desired parameters and desired deliverables, the Bidder
shall carryout necessary survey and investigations and would prepare the detail designs and
drawings etc. as may be required for collection of sewage including pumping stations or other
structures as required on best engineering practices and fulfilling the requirement of CPHEEO
MANUAL, MOUD, DELHI. The Bidder shall also prepare detailed construction drawings as per actual
working conditions including usage of back lanes and side lanes and minimum obstruction to existing
utilities, roadways and railways.
iii) The Bidder shall make its own choice for process of Sewage Treatment but the technology for
Sewage Treatment should be proven technology, in working position for the last 5 years in India for a
capacity not less than the capacity of treatment proposed in the present project and this experience
should be fulfilled by the Technology Provider. The proposed technology for the biological treatment
in the proposed Sewage Treatment Plant should be based on,
a. The availability of land already identified by the UJJAINMUNICIPALCORPORATION, UJJAIN
b. Effluent characteristics should meet the standards set out by MoEF and CPCB for
discharging the treated water in inland water resources or disposal on land.
c. Reuse of the treated water in community purposes like horticulture/gardening, road side
irrigation, road washing, irrigation purposes and fire-fighting etc. Also use for irrigation and
industrial purposes should be explored.
The Bidder is required to take approval for all detailed designs and drawings for all components of this
project from Engineer-in-Chief, Urban Administration and Development Department, Bhopal.
8
On successful completion of the project as per best engineering practices the bidder shall operate and
maintain the system for next 10 years. The initial 5 years period upon completion of construction work of
this project shall be defect liability period (DLP).
The Bidder shall also explore the possibility of power generation for running of Sewage treatment plant.
The Detailed Project Report (DPR) for the work is available for viewing by the Bidder. However, it is
clarified that the data and detailing of project in the DPR could be taken as base data only. The bidder is
required to make his own assessment of work before bidding & the bidder shall not be entitled for claim
on account of any deficiency / discrepancy in the data /information available in DPR.
2. General Quality of Work:

The work shall have to be executed in accordance with the drawings (prepared by Contractor and
approved by the competent authority), technical specifications specified in the Bid Data Sheet/Contract
Data, and shall have to meet high standards of workmanship, safety and security of workmen and works.
3. PROCEDURE FOR PARTICIPATION IN E-TENDERING
The procedure for participation in e-tendering is given in the Bid Data Sheet.
4. ONE BID PER BIDDER
4.1 The bidder can be an individual entity or a joint venture (if permitted as per Bid Data sheet). In case the
J.V. is permitted, the requirement of joint venture shall be as per the Bid Data Sheet.
4.2 No bidder shall be entitled to submit more than one bid whether jointly or severally. If he does so, all bids
wherein the bidder has participated shall stand disqualified.
4.3 In case of Bid submitted by the Joint Venture all the members should be essentially registered with the
Government of Madhya Pradesh, PWD.
5. Cost of Bidding
The bidder shall bear all costs associated with the preparation and submission of his bid, and no claim
whatsoever for the same shall lie on the ULB.
6. Site Visit and examination of works
The bidder is advised to visit and examine the Site of Works and its surroundings and obtain for itself on
its own responsibility all information that may be necessary for preparing the bid and entering into a
contract for construction of the work. All costs shall have to be borne by the bidder.
B. BID DOCUMENTS
7. CONTENT OF BID DOCUMENTS
The Bid Document comprises of the following documents:
1. NIT with all amendments.
2. Instructions to Bidders,
3. Conditions of Contract:
i. Part I General Conditions of Contract and Contract Data; and
ii. Part II Special Conditions of Contract.
4. Specifications
5. Drawings,
6. Priced Bill of Quantities
7. Technical and Financial Bid
8. Letter of Acceptance
9. Agreement and
9
10. Any other document(s), as specified.

8. The bidder is expected to examine carefully all instructions, conditions of contract, the contract data,
forms, terms and specifications, bill of quantities, forms and drawings in the Bid Document. Bidder shall
be solely responsible for his failure to do so.
9. Pre-Bid Meeting (where applicable)
Wherever the Bid Data Sheet provides for pre-bid meeting:
9.1 Details of venue, date and time would be mentioned in the Bid Data Sheet. Any change in the
schedule of pre-bid meeting would be communicated on the website only, and intimation to
bidders would not be given separately.
9.2 Any prospective bidder may raise his queries and/or seek clarifications in writing before or during
the pre-bid meeting. The purpose of such meeting is to clarify issues and answer questions on
any matter that may be raised at that stage. The Employer may, at his option, give such
clarifications as are felt necessary.
9.3 Minutes of the pre-bid meeting including the list of the questions raised and the responses given
together with any response prepared after the meeting will be hosted on the website.
9.4 Pursuant to the pre-bid meeting if the Employer deems it necessary to amend the Bid Document,
it shall be done by issuing amendment to the online NIT.
10. Amendment of Bid Documents
10.1 Before the deadline for submission of bids, the Employer may amend or modify the Bid
Documents by publication of the same on the website.
10.2 All amendments shall form part of the Bid Document.
10.3 The Employer may, at its discretion, extend the last date for submission of bids by publication of
the same on the website.
C. PREPARATION OF BID
11. The bidders have to prepare their bids online, encrypt their Bid Data in the Bid Forms and submit Bid
Seals (Hashes) of all the envelopes and documents related to the Bid required to be uploaded as per
the time schedule mentioned in the key dates of the Notice Inviting e-Tenders after signing of the same by
the Digital Signature of their authorized representative.
12. DOCUMENTS COMPRISING THE BID
The bid submitted online by the bidder shall be in the following parts:
Part 1 – This shall be known as Envelope A and would apply for all bids. Envelop A shall contain the
following as per details given in the Bid Data Sheet:
i) Registration number or proof of application for registration and organizational details in format
given in the Bid Data sheet.
ii) Payment of the cost of Bid Document;
iii) Earnest Money;
iv) An affidavit duly notarized.
v) JV Agreement (Original) in case of JV.
vi) Undertaking as per Clause no. 13 (Special Condition Regarding Conditional TENDER of
Section – 3, Conditions of Contract, Part –II Special Conditions of Contract
Part 2 – This shall be known as Envelope B and required to be submitted only in works where pre-
qualification conditions and/or special eligibility conditions are stipulated in the Bid Data Sheet. Online
10
Envelop B shall contain a self-certified sheet duly supported by documents to demonstrate fulfillment of
pre-qualification conditions.
Part 3 – This shall be known as Envelope C and would apply to all bids. Envelop C shall contain
financial offer in the format prescribed enclosed with the Bid Data Sheet.
13. LANGUAGE
The bid as well as all correspondence and documents relating to the bid exchanged by the Bidder and the
Employer shall be in English or Hindi. Supporting documents and printed literature that are part of the Bid
may be in another language provided they are accompanied by an accurate translation of the relevant
passages in English. In such case, for the purposes of interpretation of the bid, such translation shall
govern.
14. TECHNICAL PROPOSAL
14.1 Only, in case of bids with pre-qualification conditions defined in the Bid data sheet, the Technical
Proposal shall comprise of formats and requirements given in the Bid Data Sheet.
14.2 All the documents / information enclosed with the technical proposals should be self-attested and
certified by the Bidder. The Bidder shall be liable for forfeiture of his earnest money deposit, if any
document / information are found false/fake/untrue before acceptance of Bid. If it is found after
acceptance of the Bid, the sanctioning authority may at his discretion forfeit his performance
security/guarantee, security deposit, enlistment deposit and take any other suitable action.
15. FINANCIAL BID
i. The bidder shall have to quote rates in format referred in Bid Data sheet, in Lumpsum, and not item
wise. If the bid is in absolute amount, overall percentage would be arrived at in relation to the NIT
amount. The overall percentage rate would apply for all items of work.
ii. Lumpsum offer shall be quoted in figures as well as in words. If any difference in figures and words
found, lower of the two shall be taken as valid and correct.
iii. The bidder shall have to quote rates inclusive of all duties, taxes, royalties and other levies; and the
Employer shall not be liable for the same. Excise exemption on pipe shall be available as per
norms.
iv. The material alongwith the units and rates, which shall be issued, if any, by the department to the
contractor, is mentioned in the Bid Data Sheet.
16. PERIOD OF VALIDITY OF BIDS
The bids shall remain valid for a period specified in Bid Data Sheet after the date of “close for biding” as
prescribed by the Employer. The validity of the bid can be extended by mutual consent in writing.
17. EARNEST MONEY DEPOSIT (EMD)
17.1 The Bidder shall furnish, as part of the Bid, Earnest Money Deposit (EMD), of the amount specified in the
Bid Data Sheet.
17.2 The EMD shall be in the form of Fixed Deposit Receipt of a scheduled commercial bank, issued in favour
of the name given in the Bid Data Sheet. The Fixed Deposit Receipt shall be valid for six months or more
after the last date of receipt of bids. However, other forms of EMD may be allowed by the employer by
mentioning it in the Bid Data sheet.
17.3 Bid not accompanied by EMD shall be liable for rejection as non-responsive.
17.4 EMD of bidders whose bids are not accepted will be returned within ten working days of the decision on the
bid.
11
17.5 EMD of the successful Bidder will be discharged when the Successful Bidder has signed the Agreement
and furnished the Bank Guarantee of required value for Performance Security& Additional Performance
Security, if any.
17.6 Failure to sign the contract by the successful/selected bidder, for whatsoever reason, shall result in
forfeiture of the Earnest Money Deposit.
D. SUBMISSION OF BID
18. The bidder is required to submit online bid duly signed digitally, and Envelop ‘A’ in physical form also at
the place prescribed in the Bid Data Sheet.
E. OPENING AND EVALUATION OF BID
19 PROCEDURE
19.1 Envelope ‘A’ shall be opened first online at the time and date notified and its contents shall be checked. In
cases where Envelop ‘A’ does not contain all requisite documents, such bid shall be treated as non-
responsive, and Envelop B and/or C of such bid shall not be opened.
19.2 Wherever Envelop ‘B’ (Technical Bid) is required to be submitted, the same shall be opened online at the
time and date notified. The bidder shall have freedom to witness opening of the Envelop ‘B’. Envelop ‘C’
(Financial Bid) of bidders who are not qualified in Technical Bid (Envelop ‘B’) shall not be opened.
19.3 Envelope ‘C’ (Financial Bid) of the qualified bidders shall be opened online at the time and date notified.
The bidder shall have freedom to witness opening of the Envelop ‘C’.
19.4 After opening Envelop ‘C’ all responsive bids shall be compared to determine the lowest evaluated bid.
19.5 The Employer reserves the right to accept or reject any bid, and to annul the biding process and reject all
the bids at any time prior to contract award, without incurring any liability. In all such cases reasons shall
be recorded.
19.6 The Employer reserves the right of accepting the bid for the whole work or for a distinct part of it.
20. CONFIDENTIALITY
20.1 Information relating to examination, evaluation, comparison and recommendation of contract award shall
not be disclosed to bidders or any other person not officially concerned with such process until final
decision on the bid.
20.2 Any attempt by a bidder to influence the Employer in the evaluation of the bids or contract award
decisions may result in the rejection of its bid.
F. AWARD OF CONTRACT
21. AWARD OF CONTRACT(ANNEXURE – L)
The Employer shall notify the successful bidder by issuing a ‘Letter of Acceptance’ that his bid has been
accepted.
22. PERFORMANCE SECURITY
22.1 Prior to signing of the Contract, the bidder to whom LOA has been issued shall have to furnish
Performance Security and Additional Performance Security of the amount, form and duration, etc. as
specified in the Bid Data Sheet.
22.2 If the Bid, which results in the lowest evaluated bid price, is seriously unbalanced or front loaded in the
opinion of the employer, the employer after evaluation, taking in to consideration the schedule of the
estimated contract price may require Additional Performance Security from the successful bidder for such
unbalanced bid price.
23. SIGNING OF CONTRACT AGREEMENT (ANNEXURE- M)
23.1 The successful bidder shall have to furnish Performance security and sign the contract agreement within
15 days of issue of LOA.
12
23.2 The signing of contract agreement shall be reckoned as intimation to commence the work within 14 days
of the signing of contract. No separate work order shall be issued by the Employer to the contractor for
commencement of work.
23.3 In the event of failure of the successful bidder to submit Performance Security and Additional
Performance Security,if any,or sign the Contract Agreement, his EMD shall stand forfeited without
prejudice to the right of the employer for taking action against the bidder.
24. CORRUPT PRACTICES
The Employer requires that bidders observe the highest standard of ethics during the procurement and
execution of contracts. In pursuance of this policy, the Employer:
i. may reject the bid for award if it determines that the bidder recommended for award has, directly or
through an agent, engaged in corrupt, fraudulent, collusive, or coercive practices in competing for
the Contract; and
ii. may debar the bidder if he is being blacklisted by any Department of State Government or GOI for
non-performance / substandard execution or any other reason what so ever in similar type of works.
iii. may debar the bidder declaring ineligible, either indefinitely or for a stated period of time, to
participate in bids, if it at any time determines that the bidder has, directly or through an agent,
engaged in corrupt, fraudulent, collusive, or coercive practices in competing for, or in executing, a
contract.
For the purposes of this provision, the terms set forth above are defined as follows:
a. “corrupt practice” means the offering, giving, receiving, or soliciting, directly or indirectly,
anything of value to influence improperly the actions of another party;
b. “fraudulent practice” means any act or omission, including a misrepresentation, that
knowingly or recklessly misleads, or attempts to mislead, a party to obtain a financial or other
benefit or to avoid an obligation;
c. “coercive practice” means impairing or harming, or threatening to impair or harm, directly or
indirectly, any party or the property of the party to influence improperly the actions of a party;
d. “Collusive practice” means an arrangement between two or more parties designed to achieve
an improper purpose, including influencing improperly the actions of another party.
[End of ITB]
13
Bid Data Sheet

General
S.No. Particulars Data
1 Office inviting Tender MUNICIPAL COMMISSIONER, UJJAIN MUNICIPAL
CORPORATION, UJJAIN(M.P.)
2 NIT No 3407
3 Date of NIT 19-04-2017
4 Bid document download From 21-04-2017 , 00:00 To 17:30 hrs 22-05-2017
available from date & time hrs
5 Website link http://www.mpeproc.gov.in
For Section 1 - NIT
Clause Particulars Data
reference
2 Portal fees As applicable
3 Cost of bid document ( in the Rs. 50,000-00
form of Demand Draft)
Cost of bid document MUNICIPAL COMMISSIONER, UJJAIN
payable to MUNICIPALCORPORATION, UJJAIN(M.P.)
Cost of bid document in favour MUNICIPAL COMMISSIONER, UJJAIN
of MUNICIPALCORPORATION, UJJAIN(M.P.)
4 Affidavit Annexure B
5 Pre-qualifications required Yes
If Yes, details Annexure C
6 Special Eligibility Yes
If Yes, details Annexure D
7 Key Dates Annexure A
For Section 2 - ITB

reference
1 Name of work Sewerage Network & Sewage Treatment for
Ujjain city under Ujjain Municipal Corporation,
UJJAIN
2 Specifications Annexure E
3 Procedure for participation in e- Annexure F
tendering
4 Whether Joint-venture is allowed YES
If yes, requirement for Joint venture Annexure G
9 Pre bid meeting to held YES
If Yes, Date, Time & Place Date:- 09-05-2017
Time from : 12:00 hrs.
Place : Directorate, Urban Administration and
Development, Bhopal
14

reference
12 Envelope –A containing : Online at www.mpeproc.gov.in upto 23-05-
i. Registration number or proof of 2017 till 17:30 hrs and hard copy submission of
application for registration and technical proposal at the office of
organizational details as per Superintending Engineer, Ujjain Municipal
Annexure ‘H’ Corporation at Mela Karyalaya Bhawan, Ujjain
ii. Cost of Bid Document upto 24-05-2017 till 17:30 hrs.
iii. EMD
iv. An affidavit duly notarized as per
Annexure –B
v. JV Agreement in Original (In
case of JV)
vi. Undertaking as per Clause no. 13
of Section – 3, Part –II Special
Conditions of Contract
Should reach in physical form
14 Envelope-B Technical Proposal Annexure – I and
Annexure – I (Format I-1 to I-5)
15 Envelope-C Financial Bid Annexure – J
Materials to be issued by the
department
16 Period of Validity of Bid 180 Days
17 Earnest Money Deposit Rs. 50,00,000/-
Forms of Earnest Money Deposit i. FDR/e-FDR
ii. Interest bearing securities of post office
EMD valid for a period of Not less than 180 days
FDR (Fixed Deposit Receipt) must be COMMISSIONER
drawn in favour of MUNICIPA CORPORATION, UJJAIN (M.P.)
21 Letter of Acceptance (LoA) Annexure L
22 Amount of Performance Security 1. 5% of the Capital cost of the project. Valid
up to 3 months beyond the completion of
design built component.
2. 5% of O & M and electrical cost, to be
submitted before the completion of design built
component valid up to 3 months beyond the
end of O&M period.
Additional Performance Security, if As per provision of clause 22.2 of ITB
any
Performance security& Additional Annexure M
Performance Security in the format
Performance security & Additional COMMISSIONER, UJJAIN MUNICIPAL
Performance Security in favor of CORPORATION, UJJAIN (M.P.)
Performance security & Additional Valid contract period plus 3 months

Performance Security valid up to
15
Annexure – A
(See clause 1, 7 of Section 1 NIT)

KEY DATES
Works Department
S.No Bidder's Stage Start Expiry Envelopes
Stage
Date Time Date Time
Purchase of
1 21-04-2017 00:00 hrs 22-05-2017 17:30
Tender-Online
Bid
2 Submission- 21-04-2017 00:00 hrs 23-05-2017 17:30 hrs
Online
Mandatory
3 submission Open 25-05-2017 11:00 hrs Envelope A
(Envelope -A)
Technical proposal
4 open (PQ 25-05-2017 11:00 hrs Envelope B
Envelope-B)
Financial Bid Open

5 01-06-2017 11:00 hrs Envelope C
(Envelope C)
Original Term Deposit Receipt of Earnest Money Deposit, Demand Draft for the cost of Bid Document and
Affidavit shall be submitted by the bidder so as to reach the office as prescribed in Bid Data Sheet, at least
one calendar day before specified start time and date in key dates for opening of technical proposal as per
key dates in Bid Data Sheet.
16
Annexure – B
(See clause 3 of Section 1-NIT)
|| AFFIDAVIT ||
(To be contained in Envelope A)
(On Non-Judicial Stamp of Rs.50.00)
I/we _______________________________________________________ who is/ are
_______________________ (status in the firm/ company) and competent for submission of the affidavit on behalf
of M/S ______________________ (contractor) do solemnly affirm an oath and state that:
I/we are fully satisfied for the correctness of the certificates/records submitted in support of the following
information in bid documents which are being submitted in response to notice inviting e-tender No.
______________ for __________________________ (name of work) dated _______ issued by the
________________ (name of the ULB).
I/we are fully responsible for the correctness of following self-certified information/ documents and
certificates:
1. That the self-certified information given in the bid document is fully true and authentic.
2. That:
a. Term deposit receipt deposited as earnest money, demand draft for cost of bid document and other
relevant documents provided by the Bank are authentic.
b. Information regarding financial qualification and annual turn-over is correct.
c. Information regarding various physical qualifications is correct.
3. No close relative of the undersigned and our firm/company is working in the department.
OR
Following close relatives are working in the department:
Name _______________ Post ____________________ Present Posting ___________
Signature with Seal of the Deponent (bidder)

I/ We, _____________________ above deponent do hereby certify that the facts mentioned in above
paras 1 to 3 are correct to the best of my knowledge and belief.
Verified today _____________ (dated) at ______________ (place).
Signature with Seal of the Deponent (bidder)

17
Annexure – C
(See clause 5 of Section 1 NIT)
PRE-QUALIFICATIONS CRITERIA
A. Financial
i. Experience of having successfully executed*,
a) three similar works each costing not less than the amount equal to 20% of the probable amount of
contract during the last 7 financial years; or
b) two similar works each costing not less than the amount equal to 30% of the probable amount of
contract during the last 7 financial years; or
c) one similar work of aggregate cost not less than the amount equal to 50% of the probable amount
of during the last 7 financial years;
In case of Sewerage related works similar works shall mean work related to sewerage project
comprising of essentially either of the following components,
i. Providing, laying, jointing of sewer pipeline of any material or nature

ii. Construction of Sewage Treatment Plants (STP) /Common Effluent Treatment plants (CETP)/
Effluent Treatment plants (ETP)
d) For ascertaining the value of successfully executed works in support of experience of the Bidder in
i(a), i(b) and i(c) under (A) Financial, the original cost of work can be adjusted as per increase in
Whole Sale Price Index (WPI) as given by Reserve Bank of India, from the date of work order of
the subjected work to till date. The certificate of the Chartered Accountant be produced for cost
adjustment.
ii. Average annual construction turnover on the construction works not less than 50% of the probable
amount of contract during the last 5 financial years.
iii. The Bidder shall have positive net-worth as per the audited Balance Sheet of last financial year.
iv. Bid-Capacity – (Deleted)
B. Physical (Deleted)
(i) Physical qualifications for the work in case of Sewerage related works shall be as below,
Minimum Physical Requirement

S. No. Item of Work Quantity
I II III
1 - -
2 - -
C. Successful Bidder shall employ having ‘A’ Class Electrical License for Electrical Works issued by State
Electricity Board M.P.
*Successfully executed would mean successfully completion and commissioning of the project.
18
Annexure – D
(See clause 6 of Section 1 NIT)
SPECIAL ELIGIBILITY CRITERIA
a) Submit a Technology Tie-up Agreement with a technology provider for Biological Treatment Section
proposed by him under this project. The technology provider should have provided technology and
core equipment for Sewage Treatment plant in last 5 years for at least one MUNICIPAL Sewage
Treatment Plant running successfully at present in India or a Country with similar weather conditions
having capacity not less than this tender or more of the capacity of Sewage Treatment plant proposed
in the project on the same technology.
19
Annexure – E
(See clause 2 of Section 2-ITB &
clause 10 of GCC)
Specifications
Enclosed after Annexure – Y

Specifications for Sewage Related Jobs
Table of Contents
S.No. Chapters Page No.
1.0 General 95
2.0 Pipeline 99
3.0 RCC Sump 109
4.0 Sewage Treatment plant 112
5.0 Pumps for sewage pumping
Part I Non Clog Submersible pumps 121
Part II Specifications for 415 V induction motors 123
Part III Cabling and motor control panel 125
Part IV Non Return valves 126
Part V Delivery Pipes 127
Part VI Rating and Name Plates 128
6.0 Electric Sub-Station 129
7.0 Specifications of Road 135
8.0 Suggested Brands of Equipment 136
(The soft copy of the specifications in four parts namely (1) Water Supply, Sewerage and Tube Well Works
(2) Building Water Supply, Drainage and Sanitary Installation (3) Roads & Bridge (4) Electrical Works shall
form part of the technical specifications of this work & is available at UADD Website
www.mpuraban.gov.in)
20
ANNEXURE-F
(See clause 3 of Section 2-ITB)
Procedure for participation in e-Tendering
1. Registration of Bidders on e-Tendering System
All the PWD registered bidders are already registered on the new e-procurement portal https://www,mpeproc.gov
.in. The user id will be the contractor ID provided to them from MP Online. The password for the new portal has
been sent to the bidders registered email ID. For more details may contact M/s Tata consultancy Services
th
Corporate Block, 5 floor, DB city Bhopal-462011, email id: [email protected]. Helpdesk phone
numbers are available on website.
2. Digital Certificate:
The bids submitted online should be signed electronically with a class III Digital Certificate to establish the identity
of the bidder submitting the bid online. The bidders may obtain class III Certificate issued by an approved
certifying Authority authorized by the controller of certifying Authorities, government of India. A class III digital
Certificate is issued upon receipt of the required proofs along with an application. Only upon the receipt of the
required documents, a digital certificate can be issued. For details please visit http:cca.gov.in.
Note:
i. It may take up to 7 working days for issuance of class III digital certificate; hence the bidders are advised to
obtain the certificate at the earliest. Those bidders who already have valid class III digital certificate need
not obtain another Digital Certificate for the same.
The bidders may obtain more information and the APPLICATION FORM REQUIRED TO BE SUBMITTED
FOR THE ISSUANCE OF DIGITAL CERTIFICATE FROM http:cca.gov.in.
ii Bids can be submitted till bid submission end date. Bidder will require digital signature while bid
submission. The digital certificate issued to the authorized user of a partnership firm/Private limited
company/Public Limited Company and user for online bidding will be considered as equivalent to a no-
objection certificate/power of attorney to that user.
In case of Partnership firm, majority of the partners have to authorize a specific individual through authority
letter signed by majority of partners o the firm.
In case of Private Limited company, Public Limited company, the Managing Director has to authorize a
specific individual through Authority Letter. Unless the certificate is revoked, it will be assumed to represent
adequate authority of the specific individual to bid on behalf of the organization for online bids as per
Information Technology Act 2000. This Authorized User will be required to obtain a digital certificate. The
Digital Signature executed though the use of the responsibility of Management/Partners of the concerned
firm to inform the Certifying Authority, if the authorized user changes, and apply for a fresh Digital
Certificate for the new Authorized user.
3. Set Up of Bidder’s Computer System:
In order for a bidder to operate on the e-tendering System, the Computer system of the bidder is required to be
set up for Operating System, Internet Connectivity, Utilities, Fonts, etc. The details are available at
https://www.mpeproc.gov.in.
4. Key Dates:
The bidders are strictly advised to follow the time schedule (Key dates as mentioned in Annexure - A) of the
bid of their side for tasks and responsibilities to participate in the bid, as all the stages of each bid are locked before
the start time and date and after the end time and date for the relevant stage of the bid as set by the Department.
5. Preparation and Submission of Bids
The bidders have to prepare their online, encrypt their bid data in the Bid forms and submit Bid of all the envelopes
and documents related to the Bid required to be uploaded as per the time schedule mentioned in the key dates of
21
the notice inviting e- Tenders after singing of the same by the Digital Signature of their authorized representatives.
6. Purchase of Bid Document
For purchasing of the bid document bidders have to pay Service Charge online ONLY which is Rs. [as per Bid
Data Sheet]. Cost of Bid document is separately mentioned in the detailed NIT. The Bid Document shall be
available for purchase to concerned eligible bidders immediately after online release of the bids and up to
scheduled time and date as set in the key dates. The payment for the cost of bid document shall be made online
through Debit/Credit card. Net banking or NEFT Challan through the payment gateway provided on the portal.
7. Withdrawal, Substitution and Modification of Bids
Bidder can withdraw and modify the bid before submission end date
22
ANNEXURE-G
(See clause 4 of Section 2-ITB)
JOINT VENTURE (J.V.)
If J.V. is allowed following conditions and requirements must be fulfilled –
1. Bids submitted by a joint venture of two or more firms as partners shall comply with the following requirements :
a. One of the partners shall be nominated as being Lead Partner, and this authorization shall be evidenced by
submitting a power of attorney signed by legally authorized signatories of all the partners;
b. The bid and, in case of successful bid, the Agreement, shall be signed so as to be legally binding on all partners;
c. The partner in charge shall be authorized to incur liabilities and receive instructions for and on behalf of any and
all partners of the joint venture and the entire execution of the contract, including payment, shall be done
exclusively with the partner in charge;
d. All the partners of the joint venture shall be liable jointly and severally for the execution of the contract in
accordance with the contract terms, and a statement to this effect shall be included in the authorization mentioned
under [c] above, as well as in the bid and in the Agreement [in case of successful bid];
e. Bidder shall submit the joint venture agreement indicating precisely the role and responsibilities of all the members
of JV in respect of planning, design, construction equipment, key personnel, work execution, and financing of the
project including Operation and Maintenance of the works. All members of JV should have active participation in
execution during the currency of the contract. This should not be varied/modified subsequently without prior
approval of the employer;
f. A copy of the Joint Venture Agreement entered into by the partners shall be submitted originally in envelope – A
and scanned copy should also be uploaded online with the bid.
g. The joint venture agreement shall be registered at the time of agreement, so as to be legally valid and binding on
all partners.
2. All the partners should meet out the minimum qualifying criteria required for the bid and collectively must meet the
criteria specified in full. Failure to comply with this requirement will result in rejection of the joint venture’s bid.
3. The performance security of joint venture shall be in the name of the partner Lead partner/joint venture.
4. Attach the power of attorney of the partners authorizing the Bid signatory(ies) on behalf of the joint venture
5. An individual Bidder cannot at the same time be member of a Joint Venture applying for this Bid. Further, a
member of a particular Bidder Joint Venture cannot be member of any other Bidder Joint Venture applying for this
bid.
6. A copy of the Joint Venture agreement entered into by the partners made on Rs. 1000/- Non-judicial stamp duly
notarized shall be submitted with the bid. However at the time of agreement bidder shall get the joint venture
agreement registered, so as to be legally valid and binding on all partners.
7. Furnish details of participation proposed in the joint venture as below:
PARTICIPATION DETAILS FIRM ‘A’ (Lead partner) FIRM ‘B’ FIRM ‘C’
Financial
Name of the Banker(s)
Planning
Construction Equipment
Key personnel
Execution of Work (Give details
on contribution of each)
7. The partners of J.V. should satisfy the qualification criteria as below,

a. The Lead Partner must have the share of minimum 51% in the J.V.
b. The other partner(s) must have a share of minimum 26% in the J.V.
c. The lead partner and the other partners must also meet 51% and 26% of the all qualification criteria
respectively except for the requirement of work experience described in Annexure 'C'. However both the
partners must satisfy the full (100%)qualification criteria jointly. For this purpose the qualification of individual
partners shall be added (for annual average turnover, for Bid Capacity Only).
d. All the partners shall have the positive net worth as per audited balance sheet of last financial years
8. For the meeting the minimum qualification criteria of experience of similar nature work,
i. Out of 3 similar works of value not less than the amount equal to 20% of Probable Amount of Contract(PAC),
at least 2 works must be done by lead partner and one work to be done by other partner,
Or
ii. Out of 2 similar works of value not less than the amount equal to 30% of PAC, at least 1(one) work must be
done by lead partner and 1 (one) work to be done by other partner,
Or
iii. In case of one similar work of value not less than the amount equal to 50% of PAC, the lead partner must
satisfy the criteria. However the other partner must satisfy the criteria in (i) above i.e., at least one work of
value not less than the amount equal to 20% of PAC.
23
ANNEXURE-H
(See clause 12 of Section 2 ITB & clause 4 of GCC)
ORGANIZATIONAL DETAILS
(To be enclosed with technical proposal)
S.No. Particulars Details
1. Registration No. issued by centralized (If applicable, scanned copy of proof of application
registration system of Govt. of MP or proof of for registration to be uploaded)
application for registration
2. Valid registration of Bidder through centralized Registration no………………. date……….
registration of Govt. of MP, PWD (Scanned copy of Registration to be uploaded)
3. Name of Organization/ Individual Proprietary
Firm/ Partnership Firm (Registered under
Partnership Act)/ Limited Company (Registered
under the Companies Act–1956)/ Corporation/
Joint Venture
4. Entity of Organization
Individual/ Proprietary Firm/ Partnership Firm
(Registered under Partnership Act)/ Limited
Company (Registered under the Companies
Act–1956)/ Corporation/Joint Venture
5. Address of Communication
6. Telephone Number with STD Code
7. Fax Number with STD Code
8. Mobile Number
9. E-mail Address for all communications
Details of Authorized Representative
10. Name
11. Designation
12. Postal Address with pin code
13. Telephone Number with STD Code
14. Fax Number with STD Code
15. Mobile Number
16. E-mail Address
Note: In case of partnership firm and limited company certified copy of partnership deed/ Articles of Association
and Memorandum of Association alongwith registration certificate of the company shall have to be
enclosed.
Signature of Bidder with Seal

Date: _____________
24
Annexure – I
(See clause 14 of Section 2 of
ITB)
Envelope – B, Technical Proposal

Technical Proposal shall comprise the following documents:
S.No. Particulars Details to be submitted
1 Experience - Financial and Physical Annexure – I (Format : I - 1)
2 Annual Turnover Annexure – I (Format : I - 2)
3 List of technical personnel for the key Annexure – I (Format: I - 3)
positions
4 List of Key equipment’s/ machines for Annexure – I (Format: I - 4)
quality control labs
5 List of Key equipment’s/ machines for Annexure – I (Format: I – 5)
construction work
Note:
1. Technical Proposal should be uploaded duly page numbered and indexed.
2. Technical Proposal uploaded otherwise will not be considered.
25
Annexure – I (Format: I-1)

(See clause 14 of Section 2 of
ITB
FINANCIAL & PHYSICAL EXPERIENCE DETAILS
A. Financial Requirement
The bidder should have completed either of the below:
a) three similar works each costing not less than the amount equal to 20% of the probable amount of contract
during the last 7 financial years; or
b) two similar works each costing not less than the amount equal to 30% of the probable amount of contract
during the last 7 financial years; or
c) one similar work of aggregate cost not less than the amount equal to 50% of the probable amount of
contract during the last 7 financial years;
To be filled in by the contractor:

i. Details of successfully completed similar works shall be furnished in the following format.
ii. Certificate duly signed by the employer shall also be enclosed for each completed similar work.
Agreement Name of Date of Date of Amount of Employer's

Number & Year Work Work Order Completion Completion Name and
Value of Address
Contract
Existing commitments – (Value of ‘C’ for Bid Capacity formula) (deleted)

Agreement Name of Date of Date of Amount of Amount Employer's
Number & Work Work Completion Contract Name and
Year Order Address
B. Physical Requirement: (DELETED)

Execution of similar items of work in any one financial year during the last 3 financial years should
not be less than the minimum physical requirement fixed for the work.
Actual Quantity Executed
S.No. Particulars (To be filled in by the contractor)
Year – 1 Year – 2 Year – 3
1 Physical qualification requirement No
2
3
Note: 1. Similar works: As described and detailed in Clause ‘A’ of Annexure ‘C’
26

(See clause 14 of Section 2 of ITB
ANNUAL TURN OVER
Requirement:
Average annual construction turnover on the construction works not less than 50% of the probable
amount of contract during the last 5 financial years;
To be filled in by the contractor:
Financial Year Payments received for contracts in progress or completed

1
2
3
4
5
Note:
i. Annual turnover of construction should be certified by the Chartered Accountant.
ii. Audited balance sheet including all related notes, and income statements for the above financial years to
be enclosed.
Bid Capacity (Deleted)

Applicants who meet the minimum qualifying criteria in the evaluation as stated above are to be evaluated further
for bid capacity as under:
Bid Capacity = (2.0 A X B) - C

Where,
A = Maximum value of civil engineering works executed in any one year during the
last five year (10% weightage per year shall be given to bring the value of work executed
at present price level)
B = Proposed contract period in years.
C = Amount if work in hand at present.
27

(See clause 14 of Section 2 of ITB & Clause 6 of
ITB)
LIST OF TECHNICAL PERSONNEL FOR THE KEY POSITIONS
Minimum Requirement Available with the bidder

Key Position
Key Position
Qualification
Qualification
Similar work
Similar work
requirement
Experience
Experience
experience
experience
Total Work
Total Work
Personnel
Minimum
Name of
S.No.
S.No.
Age
Age
Site Degree
1. Engineer 2 In Civil 3 years 5 years
Material Degree 10
2 Engineer 1 In Civil 5 years years
Constriction Diploma
3. Engineer 6 In Civil 3 years 5 years
Lab In- Diploma
4. charge 1 In Civil 3 years 5 years
Note: Designation mentioned above are only indicative performing different tasks and may be changed as per the
contractor’s organization.
28

(See clause 14 of Section 2 of ITB)
List of Key Equipments/ Machines for Quality Control Labs
The Contractor shall be required to carry out all mandatory quality control tests as per specifications of various items of
work under the project. The Contractor should demonstrate his capacity with respect to availability of key equipment/
machines required for carrying out mandatory tests under project. The pipes to be procured under this contract shall be
as per relevant BIS/IS/ISO codes of practice and inspected by the representatives of PDMC. The request in this regard
shall be made by the Contractor to PDMC.
Apart from above for the various civil works following Equipment/ Machines shall be required for quality
control.
Minimum requirement Available with the Bidder

S. Name of Equipment/ Machinery Quantity Name of Equipment/ Quantity
No. Machinery
1 Digging tools like pick axe, One set
shovel, etc.
2 IS Sieves Nos. with lid and pan ONE
(90 mm, 80 mm, 63 mm, SET
53 mm, 45 mm, 37.5 mm,
26.5 mm, 19 mm, 13.2 mm,
11.2 mm, 9.5 mm, 4.75 mm,
2.8 mm, 5.6 mm, 3.35 mm,
2.36 mm, 600 Micron,
425 Micron, 300 Micron,
90 Micron and 75 Micron)
3 Sand Pouring Cylinder with tray One set
complete for field Density test
4 Speedy moisture meter One set
complete with chemicals
5 Straight Edges 3.00 metre width Two set
6 Liquid Limit and plastic limit One set
testing apparatus complete with
water bottle and glass wares
7 Electronic/digital balance 5 kg One no.
8 Pan balance with weight box, 5 One no.
kg.
9 Slump cone Two no.
10 Concrete cube moulds (150 mm Twelve
X 150mm) no.
11 Free swelling index test Six no.
Apparatus
12 Flakiness and elongation testing Two no.
gauges
13 Water absorption test apparatus One no.
14 Specific gravity test apparatus One no.
15 B.S. compaction apparatus One no.
16 Proving rings One
each
17 Glass ware One set
18 Auto level and staff Three
nos.
19 Rapid moisture meter One no.
20 Post Hole Auger with One set
extensions
21 Measuring tape, One set
29
spatula, glassware,
porcelain dish, pestle
mortar
22 Standard Proctor Density Test One set
Apparatus with rammer
23 Electronic/digital balance 1 One set
kg with the least count of
0.01 gm
24 Camber Board Two no.
25 Core Cutter (10 cm dia) One set
10cm/15cm height complete with
dolly and
hummer.
26 CBR Testing machine One no.
27 Oven (ambient to 200°C) One no.
28 Digital Thermometers Three
no.
Aggregate Soundness One no.
test apparatus
30 Concrete cube testing One no.
machine
31 First aid box One no.
32 Sampling Pipette One no.
33 Balance One no.
34 Dial Gauges Six No.
35 Thickness gauge One set
36 Water still (4 ft.) One no.
37 A.I.V. testing equipment One no.
The above list of essential equipment for quality control is for guidance and is only illustrative but not complete.
Other apparatus and equipment as desired/required by the Engineer-in-Charge shall be procured by the
Contractor
30

LIST OF EQUIPMENTS / MACHINES FOR CONSTRUCTION WORK
The Contractor shall carryout the construction work in such a way that the requirements of the
specifications of each item of work under the project are fully satisfied. For achieving the quality
parameters as per the specifications, the contractor shall be required to deploy appropriate
machinery and equipment for carrying out the work. In this section, the Bidder is required to
demonstrate his capacity with respect to Key equipment and machinery that are required to
carry out this work successfully.
Minimum requirement Available with the Bidder

S. No. Name of Quantity Name of Quantity
Equipment/ Equipment/
Machinery Machinery
31
Annexure – J
FINANCIAL BID
(TO BE CONTAINED IN ENVELOPE C)
TENDER FOR A LUMP SUM CONTRACT:
I/We do hereby TENDER to execute the whole of the work described in the drawing and according to the annexed
specification for the sum of Rupees (in figures) ……………………………………………..…………………….… (in
words)……………………………………………………… (To be quoted in lump sum online and to be expressed both
in words and figures).I/We have visited the site of work and am/are fully aware of all the difficulties and conditions
likely to affect carrying out the work. I/We have fully acquainted myself/ourselves about the conditions in regard to
accessibility of site and quarries/kilns, nature and the extent of ground, working conditions including stacking of
materials, installation of tools and plant conditions effecting accommodation and movement of labor etc. required
for the satisfactory execution of contract.
Should this bid be accepted, I/We hereby agree to abide by and fulfill all the terms and provisions of the
said conditions of contract annexed hereto so far as applicable, or in default thereof to forfeit and pay to the
MUNICIPAL COMMISSIONER, UJJAIN MUNICIPAL CORPORATION, Madhya Pradesh or his successors in
office the sums of money mentioned in the said conditions.
Note:
i. Only Lump sum cost for the scope of work given therein shall be quoted.
ii. Lump sum offer shall be quoted in figures as well as in words. If any difference in figures and words found lower
of the two shall be taken as valid and correct Price. If the bidder is not ready to accept such valid and correct
Price and declines to furnish performance security and sign the agreement his earnest money deposit shall be
forfeited.
iii. In case the price is not given by a bidder, his bid shall be treated as non-responsive.
iv. All duties, taxes, and other levies payable by the bidder shall be included in the lump sum offer given by the
bidder. Only Exemption in Excise duty shall be available as per norms.
Dated______________
Signature of Bidder___________________
Name of Bidder
Address of Bidder_______________________________
The above said Bid is hereby accepted by me on behalf of the (Ujjain Municipal Corporation)
Dated day of _________________2017_______
SECURITIES
_______________________________________________________________________________
Name Address Occupation or Remarks
Profession
MUNICIPAL COMMISSIONER
UJJAIN (M.P.)
Witnesses :_________________________
Address:____________________________
32
The lump-sum cost for the Bid to be quoted Online shall be calculated as under,
1.0 Cost of Works (A) =
2.0 Operation and Maintenance Cost next 10 years (B)
S.No. Year Cost in Rs NPV taking Discount

factor @ 11% (Cost in
INR)
st
1.0 1 Year
2.0 2nd Year
rd
3.0 3 Year
th
4.0 4 Year
5.0 5th Year
th
6.0 6 Year
th
7.0 7 Year
th
8.0 8 Year
th
9.0 9 Year
10.0 10th Year
Total (B)
3.0 Power Consumption (C)

S.No. Year Electricity Consumption Cost of Power to be NPV taking Discount
(KwH) for entire system calculated @ Rs 6.50 factor @ 11% (Cost in
incl. SCADA-PLC, pumps per KwH INR)
and Sewage Treatment
plant
st
1.0 1 Year
nd
2.0 2 Year
rd
3.0 3 Year
4.0 4th Year
th
5.0 5 Year
th
6.0 6 Year
th
7.0 7 Year
8.0 8th Year
th
9.0 9 Year
th
10.0 10 Year
Total (C)
Note :
1 The charges for the power upto the electricity consumption as shown in table shall be borne by ULB.
However, the payment for any additional consumption of electricity in a particular year shall be made by
the Bidder on Prevailing rates of power at that time.
2 For arriving the NPV of the O&M and Electricity Charges the rate at Eleven(11) percent per annum will be
used to discount the annual future costs. The discount factor to be used is calculated below,
S.No. Year Discount factor to be used @

11% for arriving at NPV of O&M
and Electricity charges
1.0 1st Year 0.659
2.0 2nd Year 0.593
rd
3.0 3 Year 0.535
th
4.0 4 Year 0.482
th
5.0 5 Year 0.434
th
6.0 6 Year 0.391
th
7.0 7 Year 0.352
th
8.0 8 Year 0.317
9.0 9th Year 0.286
10.0 10th Year 0.258
Lump-sum cost for the Bid = Lumpsum Cost (A) + NPV Cost of 10 Years O&M (B) +
NPV Cost of Power for 10 years (C)
33
Annexure – K
MATERIALS TO BE ISSUED BY THE DEPARTMENT
DWC/HDPE pipe will be issued by the Ujjain Municipal Corporation, Ujjain. Total Length of pipe available with the
corporation is 68.059 km. Bidder will be supplied this material from the department and the amount of the material
will be deducted from the monthly contractor bill.
Details of Available DWC Pipes at UMC store at Ambodiya Treatment Plant
Sr. Quantity
DWC Pipe Issue Rate Total Amount
No. in meter
1 170/200 mm dia 34841 308.00 10731028.00
2 250/295 mm dia 22423 748.00 16772404.00
3 400/480 mm dia 10795 1488.00 16062960.00
Total 68059 43566392.00
34
Annexure – L
LETTER OF ACCEPTANCE (LOA)
Dear Sir (s),
Your bid for the work mentioned above has been accepted on behalf of the (Name of ULB) at your
bided lump sum offer as per scope of work given therein.
You are requested to submit the following within 15 (Fifteen) days from the date of issue of this letter:
a. The performance security/ performance guarantee of Rs. __________ (in figures) (Rupees
____________________________________________ in words) only being 5% of the capital cost of the project.
The performance security shall be in the shape of Term Deposit Receipt/ Bank Guarantee of any nationalized /
schedule commercial bank valid up to valid up to Valid Contract Period Plus three months.
(In prescribed Format as per Annexure – M)
b. The Additional Performance Security/ Additional Performance Guarantee of Rs. __________ (in figures) (Rupees
____________________________________________ in words) only. The performance security shall be in the
shape of Term Deposit Receipt/ Bank Guarantee of any nationalized / schedule commercial bank valid up Valid
Contract Period Plus three months. (In prescribed Format as per Annexure – M)
c. Duly signed Contract Agreement in Agreement Form as prescribed in Section – 5
Please note that

(i) the time allowed for carrying out the work as entered in the bid is __________ months including/excluding rainy
season, shall be reckoned from the date of signing the Contract Agreement and
(ii) the performance security/ performance guarantee of Rs. __________ (in figures) (Rupees
____________________________________________ in words) only being 5% of O & M and electrical cost, to be
submitted before the completion of design built component valid up to 3 months beyond the end of O&M period.
The performance security shall be in the shape of Term Deposit Receipt/ Bank Guarantee of any nationalized /
schedule commercial bank. (In prescribed Format as per Annexure – M)
Signing the contract agreement shall be reckoned as intimation to commencement of work and no separate letter
for commencement of work is required.
Therefore, after signing of the agreement, you are directed to contact Engineer-in-charge within 14days for
taking the possession of site and necessary instructions to start the work.
Yours faithfully,
UJJAIN MUNICIPAL CORPORATION, UJJAIN
35
Annexure – M
PERFORMANCE SECURITY/ADDITIONAL PERFORMANCE SECURITY

To
_______________________________[Name of Employer]
_______________________________
_______________________________[Address of Employer]
______________________________
WHEREAS_______________________[name and Address of Contractor]
(Hereinafter called “the Contractor”) has undertaken, in pursuance of Letter of Acceptance No._______________
Dated _________to execute_________[Name of Contract and brief description of Works] (herein after called “the
Contract”).
AND WHEREAS it has been stipulated by you in the said Contract that the contractor shall furnish you
with a Bank Guarantee by a recognized bank for the sum specified therein as security for compliance with his
obligation in accordance with the contract;
AND WHREREAS we have agreed to give the Contractor such a Bank Guarantee:
NOW THEREFORE we hereby affirm that we are the Guarantor and responsible to you on behalf of the
Contractor, up to a total of ___________[amount of Guarantee]*__________ (in words), such sum being payable
in the types and proportions of currencies in which the contract price is payable, and we undertake to pay you,
upon your first written demand and without cavil or argument, any sum or sums within the limits of_____________[
amount of Guarantee] as aforesaid without your needing to prove or to show grounds or reasons for your demand
for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the contractor before presenting us
with the demand.
We further agree that no change or addition to or other modification of the terms of the Contract of the
Works to be performed there under or of any of the Contract documents which may be made between you and the
Contractor shall in any way release us from any liability under this Guarantee, and we hereby waive notice of any
such change, addition or modification.
This Guarantee shall be valid until 3(three) months from the date of expiry of the Defect Liability Period.
Signature, Name and Seal of the Guarantor________________________________________________
Name of Bank__________________________________________________________________________
Address_______________________________________________________________________________
Phone No., Fax No., E-mail Address, of Signing Authority___________________________________
Date__________________________________________________________________________________
* An amount shall be inserted by the Guarantor, representing the percentage the Contract Price specified in the
Contract including additional security for unbalanced Bids, if any and denominated in Indian Rupees.
36
SECTION 3
Part – I General Conditions of Contract [GCC]
Table of Clauses of GCC

Clause Particulars Clause Particulars
no no
A. General 21 Payments for Variations and / or Extra
Quantities
1 Definitions 22 No compensation for alterations in or
restriction of work to be carried out.
2 Interpretations and Documents 23 No Interest payable
3 Language and Law 24 Recovery from Contractors
4 Communications 25 Tax
5 Subcontracting 26 Check Measurements
6 Personnel 27 Termination by Engineer in charge
7 Force Majeure 28 Payment upon Termination
8 Contractor's Risks 29 Performance Security
9 Liability For Accidents To Person 30 Security Deposit
10 Contractor to Construct the Works 31 Price Adjustment
11 Discoveries 32 Mobilization and Construction
Machinery Advance
12 Dispute Resolution System 33 Secured Advance
B. Time Control 34 Payment certificates
13 Programme E. Finishing the Contract
14 Extension of Time 35 Completion of Certificate
15 Compensation for Delay 36 Final Account
16 Contractor’s quoted percentage F. Other Conditions of Contract
C. Quality Control 37 Currencies
17 Tests 38 Labour
18 Correction of Defects noticed during 39 Compliance with Labour Regulations&
the DefectLiability Period Construction Safety
D. Cost Control 40 Audit and Technical Examination
19 Variations - Change in original 41 Death and Permanent Invalidity of
Specifications, Designs, Drawings etc. Contractor
20 Extra Items 42 Jurisdiction
43 Monthly RA bills
37
A. General
1. Definitions
1.1 Bill of Quantities: means the priced and completed Bill of Quantities forming part of the Bid.
1.2 Chief Engineer: means Chief Engineer of UADD.
1.3 Completion: means completion of the work as certified by the Engineer-in-Charge, in accordance with
provisions of agreement.
1.4 Contract: means the Contract between the Employer and the Contractor to execute, complete and/or maintain
the work. Agreement is synonym of Contract and carry the same meaning wherever used.
1.5 Contract Data Sheet: means the documents and other information which comprise of the Contract.
1.6 Contractor: means a person or legal entity whose bid to carry out the work has been accepted by the Employer.
1.7 Contractor's bid : means the completed bid document submitted by the Contractor to the Employer.
1.8 Contract amount : means the amount of contract worked out on the basis of accepted bid.
1.9 Completion of work : means completion of the entire contracted work. Exhaustion of quantity of any particular
item mentioned in the bid document shall not imply completion of work or any component thereof.
1.10 Day: means the calendar day.
1.11 Defect : means any part of the work not completed in accordance with the specifications included in the
contract.
1.12 Department: means department of Urban Administration and Development, Madhya Pradesh and UJJAIN
MUNICIPAL CORPORATIONas the case may be.
1.13 Drawings : means drawings including calculations and other information provided or approved by the Engineer-
in-Charge.
1.14 Employer : means the party as defined in the Contract Data, who employs the Contractor to carry out the work.
The employer may delegate any or all functions to a person or body nominated by him for specified functions.
The word Employer/Government/Department wherever used denote the Employer
1.15 Engineer: means Assistant Resident Engineer of PDMC AMRUT.
1.16 Engineer in charge: means Resident Engineer of PDMC AMRUT.
1.17 Engineer In Chief :Engineer In Chief of UADD
1.18 Equipment : means the Contractor's machinery and vehicles brought temporarily to the Site for execution of
work.
1.19 Government: means Government of Madhya Pradesh.
1.20 In Writing: means communicated in written form and delivered against receipt.
1.21 Material : means all supplies, including consumables, used by the Contractor for incorporation in the work.
1.22 Schedule of Rates : means, Schedule of Rates (SOR) of Urban Administration and Development Department,
Government of Madhya Pradesh w.e.f. 10th May 2012 with up to date amendments.
1.23 PDMC : Means WAPCOS LTD ( A Mini-Ratna PSU under Ministry of Water Resources, River Development and
Ganga Rejuvenation Govt. of India) have been appointed as Project Development and Management Consultant
(PDMC) by UADD M.P. in April, 2016 for AMRUT Project in M.P. (Package – II).
1.24 Superintending Engineer: means Superintending Engineer of the Concerned Division of the MP, UADD as the
case may be.
1.25 Stipulated date of completion: means the date on which the Contractor is required to complete the work. The
stipulated date/ period is specified in the Contract Data.
1.26 Specification: means the specification of the work included in the Contract and any modification or addition
made or approved by the Engineer-in-Charge.
1.27 Start Date:means the 14 days after the signing of agreement for the work.
1.28 Sub-Contractor: means a person or corporate body who has a Contract (duly authorized by the Employer) with
the Contractor to carry out a part of the construction work under the Contract.
1.29 Temporary Work: means work designed, constructed, installed, and removed by the Contractor that are
needed for construction or installation of the work.
1.30 Tender / Bid, Tenderer /Bidder: are the synonyms and carry the same meaning where ever used.
1.31 UADD : Urban Administration and Development Department
1.32 Variation: means any change in the work which is instructed or approved as variation under this contract.
1.33 Work: the expression "work" or "works" where used in these conditions shall unless there be something either in
the subject or context repugnant to such construction, be construed and taken to mean the work by virtue of
contract, contracted to be executed, whether temporary or permanent and whether original, altered, substituted
or additional.
38
2. Interpretations And Documents

2.1 Interpretations
In the contract, except where the context requires otherwise:
a. words indicating one gender include all genders;
b. words indicating the singular also include the plural and vice versa.
c. provisions including the word “agree”, “agreed” or “agreement” require the agreement to be recorded
in writing;
d. written” or “in writing” means hand-written, type-written, printed or electronically made, and resulting in
a permanent record;
2.2 Documents Forming Part of Contract:

1. NIT with all amendments.
2. Instructions to Bidders
3. Conditions of Contract:
i. Part I General Conditions of Contract and Contract Data; with all Annexures
ii. Part II Special Conditions of Contract.
4. Specifications
5. Drawings
6. Bill of Quantities
7. Technical and Financial Bid
8. Agreement
9. Any other document (s), as specified.
2.2.1 Priority of bid document

1. Bid Data Sheet
2. Contractor Data Sheet
3. Special Condition of Contract
4. General Condition of Contract
5. Scope of Work
6. Specifications
7. Bill of Quantity
8. Drawings
3. Language and Law

The language of the Contract and the law governing the Contract are stated in the Contract Data.
4. Communications
All certificates, notice or instruction to be given to the Contractor by Employer/Engineer shall be sent on
the address or contact details given by the Contractor in [Annexure H of ITB]. The address and contract
details for communication with the Employer/Engineer shall be as per the details given in Contract Data
Sheet. Communication between parties that are referred to in the conditions shall be in writing. The notice
sent by facsimile (fax) or other electronic means (email) shall also be effective on confirmation of the
transmission. The notice sent by registered post or speed post shall be effective on delivery or at the
expiry of the normal delivery period as undertaken by the postal service. In case of any change in address
for communication, the same shall be immediately notified to Engineer-in-Charge
5. Subcontracting
Subcontracting shall be permitted for contracts value more than amount specified in the Contract Data with
following conditions.
a. The Contractor may subcontract up to 25 percent of the contract price, only with and after the approval
of the Employer in writing, but will not assign the Contract. Subcontracting shall not alter the
Contractor's obligations.
b. The following shall not form part of the sub-contracting:
i. hiring of labour through a labour contractor,
ii. the purchase of Materials to be incorporated in the works,
39
iii. hiring of plant & machinery

c. The sub-contractor will have to be registered in the appropriate category in the centralised
registration system for contractors of the GoMP.
6. Personnel
6.1 The Contractor shall employ for the construction work and routine maintenance the technical personnel as
provided in the Annexure I-3 of Bid Data sheet, if applicable. If the Contractor fails to deploy required number
of technical staff, recovery as specified in the Contract Data will be made from the Contractor.
6.2 If the Engineer asks the Contractor to remove a person who is a member of the Contractor's staff or work
force, stating the reasons, the Contractor shall ensure that the person leaves the Site within three days and
has no further connection with the Works in the Contract.
7. Force Majeure
7.1 The term "Force Majeure" means an exceptional event or circumstance:
a) Which is beyond a party’s control,
b) Which such party could not reasonably have provided against before entering into the contract,
c) Which, having arisen, such party could not reasonably have avoided or overcome, and
d) Which is not substantially attributed to the other Party
Force Majeure may include, but is not limited to, exceptional events or circumstances of the kind listed
below, so long as conditions (a) to (d) above are satisfied:
(i) War, hostilities (whether war be declared or not), invasion, act of foreign enemies),
(ii) Rebellion, terrorism, sabotage by persons other than he contractor’s Personnel, revolution,
insurrection, military or usurped power, or civil war,
(iii) Riot, commotion, disorder, strike or lockout by persons other than the Contractor’s Personnel,
(iv) Munitions of war, explosive materials, ionising radiation or contamination by radio activity, except ass
may be attributed to the Contractor’s use of such munitions, explosives, radiation or radio activity,
and
(v) Natural catastrophes such as earthquake, hurricane, typhoon or volcanic activity,
7.2 In the event of either party being rendered unable by force majeure to perform any duty or discharge any
responsibility arising out of the contract, the relative obligation of the party affected by such force majeure
shall upon notification to the other party be suspended for the period during which force majeure event lasts.
The cost and loss sustained by either party shall be borne by respective parties.
7.3 For the period of extension granted to the Contractor due to Force Majeure the price adjustment clause shall
apply but the penalty clause shall not apply. It is clarified that this sub clause shall not give eligibility for price
adjustment to contracts which are otherwise not subject to the benefit of Price adjustment clause.
7.4 The time for performance of the relative obligation suspended by the force majeure shall stand extended by
the period for which such cause lasts. Should the delay caused by force majeure exceed twelve months, the
parties to the contract shall be at liberty to foreclose the contract after holding mutual discussions.
8. Contractor's Risks
8.1 All risks of loss of or damage to physical property and of personal injury and death which arise during and in
consequence of the performance of the Contract are the responsibility of the Contractor.
8.2 All risks and consequences arising from the inaccuracies or falseness of the documents and/or information
submitted by the contractor shall be the responsibility of the Contractor alone, notwithstanding the fact that
designs/drawings or other documents have been approved by the department.
9. Liability for Accidents to Person

The contractor shall be deemed to have indemnified and saved harmless the Government and/or the
employer, against all action, suits, claims, demands, costs etc. arising in connection with injuries suffered by
any persons employed by the contractor or his subcontractor for the works whether under the General law
or under workman's compensation Act, or any other statute in force at the time of dealing with the question
of the liability of employees for the injuries suffered by employees and to have taken steps properly to
ensure against any claim there under.
10. Contractor to Construct the Works

10.1 The Contractor shall construct,install, test, commission, operate and maintain the Works in accordance with
the Specifications and Drawings as specified in the Contract Data
10.2 In the case of any class of work for which there is no such specification as is mentioned in contract Data,
such work shall be carried as per best Engineering practice or as directed by Engineer In Charge. In the
event of any disparity between the written specifications and BIS provisions, the provisions in BIS shall prevail.
10.3 The contractor shall supply and take upon himself the entire responsibility of the sufficiency of the
scaffolding, timbering, Machinery, tools implements and generally of all means used for the fulfilment of this
contract whether such means may or may not approved of or recommended by the Engineer.
40
11. Discoveries
Anything of historical or other interest or of significant value unexpectedly discovered on the Site shall be the
property of the Employer. The Contractor shall notify the Engineer of such discoveries and carry out the
Engineer's instructions for dealing with them.
12. Dispute Resolution System

12.1 No dispute can be raised except before the Competent Authority as defined in Contract data in writing giving
full description and grounds of Dispute. It is clarified that merely recording protest while accepting
measurement and/or payment shall not be taken as raising a dispute.
12.2 No issue of dispute can be raised after 45 days of its occurrence. Any dispute raised after expiry of 45 days
of its first occurrence shall not be entertained and the Employer shall not be liable for claims arising out of
such disputes.
12.3 The Competent Authority shall decide the matter within 45 days.
12.4 Appeal against the order of the Competent Authority can be preferred within 30 days to the Appellate
Authority as defined in the Contract data. The Appellate Authority shall decide the dispute wiithin 45 days.
12.5 Appeal against the order of the Appellate Authority can be preferred before the Madhya Pradesh Arbitration
Tribunal constituted under Madhya Pradesh MadhyasthamAdhikaranAdhiniyam, 1983.
12.6 The contractor shall have to continue execution of the works with due diligence notwithstanding pendency of
a dispute before any authority or forum.
B. Time Control
13. Programme
13.1 Within the time stated in the Contract Data, the Contractor shall submit to the Engineer for approval a
Programme showing the general methods, arrangements, order, and timing for all the activities in the
Works for the construction of works.
13.2 The program shall be supported with all the details regardingkey personnel, equipment and machinery
proposed to be deployed on the works for its execution. The contractor shall submit the list of equipment
and machinery being brought to site, the list of key personnel being deployed, the list of
machinery/equipment being placed in field laboratory and the location of field laboratory along with the
Programme
13.3 An update of the Programme shall be a programme showing the actual progress achieved on each activity
and the effect of the progress achieved on the timing of the remaining Works, including any changes to the
sequence of the activities.
13.4 The Contractor shall submit to the Engineer for approval an updated Programme at intervals no longer
than the period stated in the Contract Data. If the Contractor does not submit an updated Programme
within this period, the Engineer may withhold the amount stated in the Contract Data from the next
payment certificate and continue to withhold this amount until the next payment after the date on which the
overdue Programme has been submitted.
13.5 The Engineer's approval of the Programme shall not alter the Contractor's obligations
14. Extension of Time

14.1 If the Contractor desires an extension of time for completion of the work on the ground of his having been
unavoidably hindered in its execution or on any other grounds, he shall apply, in writing, to the Engineer-
in-charge, on account of which he desires such extension. Engineer-in-charge shall forward the aforesaid
application to the competent authority as prescribed.
14.2 The competent authority shall grant such extension at each such occasion within a period of 30 days of
receipt of application from contractor and shall not wait for finality of work. Such extensions shall be
granted in accordance with provisions underclause -7 or clause- 15 of this agreement.
14.3 In case of the work already in progress, the contractor shall proceed with the execution of their works,
including maintenance thereof, pending receipt of the decision of the competent authority as aforesaid with
all due diligence.
15. Compensation for delay

15.1 The time allowed for carrying out the work, as entered in the agreement, shall be strictly observed by the
Contractor.
15.2 The time allowed for execution of the contract shall commence (14 days from the date of signing of the
agreement). It is clarified that the need for issue of work order is dispensed with.
15.3 In the event milestones are laid down in the Contract Data for execution of the works, the contractor shall
have to ensure strict adherence to the same.
41
15.4 Failure of the Contractor to adhere to the timelines and/or milestones shall attract such liquidated damages
as is laid down in the Contract Data
15.5 In the event of delay in execution of the works as per the timelines mentioned in the contract data the
Engineer-in- charge shall retain from the bills of the Contractor Amount equal to the liquidated damages
liveable until the contractor makes such delays good. However, the Engineer-in-charge shall accept
bankable security in lieu of retaining such amount.
15.6 If the contractor is given extension of time after liquidated damages have been paid, the engineer in charge
shall correct any over payment of liquidated damages by the Contractor in the next payment certificate.
15.7 In the event the contractor fails to make good the delay until completion of the stipulated contract period
(including extension of time) the sum so retained shall be adjusted against liquidated damages levied.
16. Contractor's quoted offer : NA

The contractor’s quoted lump sum offer referred to in the "Bid for works" will be deducted/ added from/to
the net amount of the bill after deducting the cost of material supplied by the department.
C. Quality Control
17. Tests
17.1 The Contractor shall be responsible for:
a. Carrying out the tests prescribed in specifications, and
b. For the correctness of the test results, whether preformed in his laboratory or elsewhere.
17.2 The contractor shall have to establish field laboratory within the time specified and having such equipment
as are specified in the Contract Data.
17.3 Failure of the contractor to establish laboratory shall attract such penalty as is specified in the Contract
Data.
17.4 Ten percent of the mandatory tests prescribed under the specifications shall be got carried out through
Laboratories accredited by National Accreditation Board of Laboratories (NABL) by the Engineer-In –
Charge at the cost of the Contractor or such testing charges will be borne by the employer and will be
recovered/deducted from the payments due to the Contractor.
18. Correction of Defects noticed during the Defect Liability Period

18.1 Thedefect liability period of work in the contract shall be the Contract Data
18.2 The Contractor shall promptly rectify all defects pointed out by the Engineer well before the end of the
Defect Liability Period. The Defect Liability Period shall automatically stand extended until the defect is
rectified.
18.3 If the Contractor has not corrected a Defect pertaining to the Defect Liability Period to the satisfaction of
the Engineer, within the time specified by the Engineer, the Engineer will assess the cost of having the
Defect corrected, and the cost of correction of the Defect shall be recovered from the Performance
Security or any amount due or that may become due to the contractor and other available securities.
D. Cost Control
19. Variations - Change in original Specifications, Designs, Drawingsetc.

19.1 The Engineer in charge shall have power to make any alterations, omissions or additions to or
substitutions for the original specifications, drawings, designs and instructions, that may appear to him to
be necessary during the progress of the work and the contractor shall carry out the work in accordance
with any instructions which may be given to him in writing signed by the Employer, and such alterations,
omission, additions or substitutions shall not invalidate the contract and any altered, additional or
substituted work, which the contractor may be directed to do in the manner above specified, as part of the
work, shall be carried out by the contractor on the same conditions in all respects on which he agree to do
the main work.
19.2 The time for the completion of the work shall be extended in the proportion that the altered, additional or
substituted work bears to the original contract work and the certificate of the Engineer in charge shall be
conclusive as to such proportion.
20. Extra items
20.1 All such items which are not in the priced BOQ shall be treated as extra items.
21. Payments for Variations and / or Extra Quantities

21.1 The rates for the additional (Extra Quantities), altered or substituted work/ extra items under this clause
shall be worked out in accordance with the following provisions in their respective order:-
a. The contractor is bound to carry out the additional (Extra quantity), work at the same rates as are specified
in the contract for the work.
42
b. If the item is not in the priced BOQ and is included in the SOR of the department, the rate shall be arrived
at by applying the quoted tender percentage on the SOR rate.
c. If the rates of the altered or substituted work are not provided in applicable SOR-such rates will be derived
from the rates for a similar class (type) of work as is provided in the contract (priced BOQ) for the work.
d. If the rates are for the altered, substituted work cannot be determined in the manner specified in the sub
clause (c) above-then the rates for such composite work item shall be worked out on the basis of the
concerned schedule of rates minus/plus the percentage quoted by the contractor.
e. If the rates of a particular part or parts of the item is not in the schedule of rates and the rates for the
altered, or substituted work item cannot be determined in the manner specified in sub clause (b) to (d)
above, the rate for such part or parts will be determined by the Competent Authority as defined in the
Contract data on the basis of the rate analysis derived out of prevailing market rates when the work was
done.
f. But under no circumstances, the contractor shall suspend the work on the plea of non acceptability of
rates on items falling under sub clause (a) to (d). In case the contractor does not accept the rate approved
by Engineer in charge for a particular item, the contractor shall continue to carry out the item at the rates
determined by the Competent Authority. The decision on the final rates payable shall be arrived at through
the dispute settlement procedure.
22. No compensation for alterations in or restriction of work to be carried out.

22.1 If at any time after the commencement of the work, the Government, for any reason whatsoever, not
require the whole or any part of the work as specified in the bid to be carried out, the Engineer in charge
shall give notice in writing of the fact to the Contractor and withdraw that whole or any part of the work.
22.2 The Contractor shall have no claim to any payments or compensation whatsoever, on account of any profit
or advantage which he might have derived from the execution of work in full or on account of any loss
incurred for idle men and machinery due to any alteration or restriction of work for whatsoever reason.
22.3 The Engineer in charge may supplement the work by engaging another agency to execute such portion of
the work, without prejudice to his rights.
23. No Interest Payable
No interest shall be payable to the Contractor on any payment due or awarded by any authority.
24. Recovery from Contractors

Whenever any claim against the Contractor for the payment arises under the contract, the Department
shall be entitled to recover such sum by:
(a) Appropriating, in part or whole of the Performance Security and additional Performance Security , if any;
and/or Security deposit and/or any sums payable under the contract to the contractor..
(b) If the amount recovered in accordance with (a) above is not sufficient, the balance sum may be recovered
from any payment due to the contractor under any other contractor of the department, including the
securities which become due for release.
(c) The department shall, further have an additional right to effect recoveries as arrears of land revenue under
the M.P. Land revenue Code.
25. Tax
25.1 The rates quoted by the Contractor shall be deemed to be inclusive of the sales and other levies, duties,
cess, toll, taxes of Central and State Governments, local bodies and authorities. But the rates shall be
excluding excise duty exemption on the items as per norms of excise.
25.2 The liability, if any, on account of quarry fees, royalties, octroi and any other taxes and duties in respect of
materials actually consumed on public work, shall be borne by the Contractor.
25.3 Any Changes in the taxes due to change in legislation or for any other reason shall not be payable to the
contractor.
26. Check Measurements

26.1 The department reserves to itself the right to prescribe a scale of check measurement of work in general
or specific scale for specific works or by other special orders.
26.2 Checking of measurement by superior officer shall supersede measurements by subordinate officer(s),
and the former will become the basis of the payment.
26.3. Any over/excess payments detected, as a result of such check measurement or otherwise at any stage
upto the date of completion of the defect liability period specified in this contract, shall be recoverable from
the Contractor, as per clause 24 above.
43
27. Termination by Engineer in Charge

27.1 If the contractor fails to carry out any obligation under the Contract, the Engineer in charge may by notice
require the Contractor to make good the failure and to remedy it within a specified reasonable time.
27.2 The Engineer in charge shall be entitled to terminate the contract if the Contractor
a) Abandons the works or otherwise plainly demonstrates the intention not to continue performance of his
obligations under the contract;
b) the Contractor is declared as bankrupt or goes into liquidation other than for approved reconstruction or
amalgamation;
c) without reasonable excuse fails to comply with the notice to correct a particular defect within a reasonable
period of time;
d) the Contractor does not maintain a valid instrument of financial Security, as prescribed;
e) the Contractor has delayed the completion of the Works by such duration for which the maximum amount
of liquidated damages is recoverable;
f) If the Contractor fails to deploy machinery and equipment or personnel or set up a field laboratory as
specified in the Contract Data.
g) if the Contractor, in judgemental of the engineer in charge has engaged in corrupt or fraudulent practices
in competing for or in executing the contract;
h) Any other fundamental breaches as specified in the Contract Data.
27.3 In any of these events or circumstances, the engineer in charge may, upon giving 14 days’ notice to the
contractor, terminate the contract and expel the Contractor from the site. However, in the case of sub
paragraph (b) or (g) of clause 27.2, the Engineer in charge may terminate the contract immediately.
27.4 Notwithstanding the above, the Engineer in charge may terminate the contract for convenience by giving
notice to the contractor.
28. Payment upon Termination

28.1 If the contract is terminated under clause 27.3, the Engineer shall issue a certificate for value of the work
accepted on final measurements, less advance payments and penalty as indicated in the Contract Data.
The amount so arrived at shall be determined by the Engineer-in-charge and shall be final and binding on
both the parties.
28.2 payment on termination under clause 27.4 above, the Engineer shall issue a certificate for the value of the
work done, the reasonable cost of removal of Equipment, repatriation of the contractor’s personnel
employed solely on the works, and the contractor’s costs of protecting and securing the works and less
advance payments received up to the date of the certificate, less other recoveries due in terms of the
contract and less taxes due to be deducted at source as per applicable law.
28.3 If the total amount due to the Employer exceeds any payment due to the Contractor, the difference shall be
recovered as per clause 24 above.
29. Performance Security
The Contractor shall have to submit performance security and additional performance security, if any, as
specified in Bid data sheetat the time of signing of the contract. The contractor shall have to ensure that
such performance security and Additional performance, if an, security remains valid for the period as
specified in the Contract data.
30. Security Deposit
30.1 Security deposit shall be deducted from the each running bill at the rate as specified in the contract data.
The total amount of security deposit so deducted shall not exceed the percentage of contract price
specified in the Contract data.
30.2 The Security may be replaced by equivalent amount of bank guarantee or fixed deposit receipt assigned to
the Employer, with validity up to 3(three) months beyond the completion of defect Liability PERIOD/
extended Defect Liability.
30.3 The Security deposit shall be refunded on completion of defect liability period.
31. Price Adjustment (Deleted)

32. Mobilization Advance
32.1 Payment of advances shall be applicable if provided in the Contract Data.
32.2 If applicable, the Engineer in charge shall make interest bearing advance payment to the contractorof the
amounts started in the Contract Data, against provision by the contractor of an unconditional Bank
Guarantee in a form and by nationalized/Scheduled banks, in the name as stated in the Contract data, in
amounts equal to the advance payment. The Guarantee shall remain effective until the advance payment
has been repaid, but the amount of the guarantee shall be progressively reduced by theamounts repaid by
the contractor.
32.3 The rate of interest chargeable shall be as per Contract data.
44
32.4 The advance payment shall be recovered as stated in the Contract data by deducting proportionate
amounts from payment otherwise due to the Contractor. No account shall be taken of the advance
payment or its recovery in assessing valuations of work done, variations, price adjustments, compensation
events, or liquidated damages.
33. Secured Advance (Deleted)
34. Payment Certificates

The payment to the contractor will be as follows for construction work:
(a) The contractor shall submit to the engineer monthly statement of the value of the work executed less the
cumulative amount certified previously, supported with detailed measurement of the items of work
executed as per the Billing Break-up in section 6.
(b) The engineer shall check the Contractor’s monthly statement and certify the amount to be paid to the
contractor.
(c) The value of work executed shall be determined, based on the measurements approved by the
Engineer/Engineer in charge.
(d) The value of work executed shall comprise the value of the quantities of the items in the Billing Breakup
given in Section 6.
(e) The value of work executed shall also include the valuation of variations and compensation events.
(f) All payments shall be adjusted for deductions for advance payment, security deposit, other recoveries in
terms of contract and taxes at source as applicable under the law.
(g) The Engineer may exclude any item certified in a previous certificate or reduce the proportion of any item
previously certified in any certificate in the light of later information.
(h) Payment of intermediate certificate shall be regarded as payments by way of advance against the final
payment and not as payments for work actually done and completed.
(i) Intermediate payment shall not preclude the requiring of bad, unsound and imperfect or unskilled work to
be removed and taken away and reconstructed or be considered as an admission of the due performance
of the contractor any part thereof, in any respect or the occurring of any claim.
(j) The payment of final bill shall be governed by the provisions of clause 36 of GCC.
E. Finishing the Contract
35. Completion Certificate

35.1 A completion certificate in the prescribed format in Contract data shall be issued by the Engineer in charge
after physical completion of the work.
35.2 After final payment to the contractor, a final completion certificate in the prescribed format in the contract
data shall be issued by the Engineer in charge.
36. Final Account

36.1 The Contractor shall supply the Engineer with a detailed account of the total amount that the Contractor
considers payable for works under the Contract within 21 days of issue of certificate of physical completion
of works. The Engineer shall issue a letter for start of Defects Liability period/O&M period and certify any
payment that is due to the Contractor within 45 days of receiving the Contractor’s account if it is correct
and complete. If the account is not correct or complete, the Engineer shall issue within 45 days a schedule
that states the scope of the corrections or additions that are necessary. If the Account is still unsatisfactory
after it has been resubmitted, the matter shall be referred to the competent authority as defined in the
Contract data, who shall decide on the amount payable to the contractor after hearing the Contractor and
the Engineer in Charge.
36.2 In case the account is not received within 21 days of issue of Certificate of Completion as provided in
clause 35.2 above, the Engineer shall proceed to finalize the account and issue a payment certificate
within 28 days.
F. Other Conditions of Contract

37. Currencies
All payments will be made in Indian Rupees.
38. Labour
38.1 The Contractor shall, unless otherwise provided in the Contract, make his own arrangements for the
engagement of all staff and labour, local or other, and for their payment, housing, feeding and transport.
38.2 The Contractor shall, if required by the Engineer, deliver to the Engineer a return in detail, in such form
and at such intervals as the Engineer may prescribe, showing the staff and the numbers of the several
45
classes of labour from time to time employed by the Contractor on the Site and such other information as
the Engineer may require.
39. COMPLIANCE WITH LABOUR REGULATIONS

39.1 During continuance of the Contract, the Contractor and his sub Contractors shall abide at all times by all
existing labour enactments and rules made there under, regulations, notifications and bye laws of the
State or Central Government or local authority and any other labour law (including rules), regulations, bye
laws that may be passed or notification that may be issued under any labour law in future either by the
State or the Central Government or the local authority. Salient features of some of the major labour laws
that are applicable to construction industry are given in the Contract data. The Contractor shall k48
eep the Employer indemnified in case any action is taken against the Employer by the competent authority on
account of contravention of any of the provisions of any Act or rules made there under, regulations or
notifications including amendments. If the Employer is caused to pay or reimburse, such amounts as may
be necessary to cause or observe, or for non-observance of the provisions stipulated in the
notifications/byelaws/Acts/Rules/ regulations including amendments, if any, on the part of the Contractor,
the Engineer/Employer shall have the right to deduct any money due to the Contractor including his
amount of performance security. The Employer/Engineer shall also have right to recover from the
Contractor any sum required or estimated to be required for making good the loss or damage suffered by
the Employer. The employees of the Contractor and the Sub-Contractor in no case shall be treated as the
employees of the Employer at any point of time.
39.2 Construction Safety

The contractor should be well conversant with technical as well as administrative and legal aspects of
safety and judicial pronouncement. The contractor shall all times take all reasonable precautions and
safety measures to maintain safety of personnel and property. The contractor shall, at his own expenses
and throughout the period of the contract ensure appropriate and suitable arrangements for health, safety
and hygiene requirements for the surroundings. The State and Central Government prevailing all Statues
in this regard must be complied in letter and spirit throughout the period of contract.
40. Audit and Technical examination

Government shall have the right to cause an audit and technical examination of the works and the final bill
of the contract including all supporting vouchers, abstract etc. To be made after payment of the final bill
and if as a result of such audit and technical examination any sum is found to have been overpaid in
respect of any work done by the contractor under the contract or any work claimed by him to have been
done under the contract and found not to, have been executed, the contractor shall be liable to refund the
amount of overpayment and it shall be lawful for government to recover the same from him in the manner
prescribed in clause 24 above and if it is found that the contractor was paid less than what was due to him,
under the contract in respect of any work executed by him under it, the amount of such under payment
shall be duly paid by government to the Contractor.
41. Death or permanent invalidity of contractor

If the Contractor is an individual or a proprietary concern, partnership concern, dies during the currency of
the contract or becomes permanently incapacitated, where the surviving partners are only minors, the
contract shall be closed without levying any damages/ compensation as provided for in clause 28.2 of the
contract agreement. However, if the competent authority is satisfied about the competence of the
survivors, then the competent authority shall enter into a fresh agreement for the remaining work strictly on
the same terms and conditions under which the contract was awarded.
42. Jurisdiction
This contract has been entered into the State of Madhya Pradesh and its validity, construction,
interpretation and legal effect shall be subjected to the exclusive jurisdiction of the courts in Ujjain or of the
courts at the place where this agreement is entered into. No other jurisdiction shall be applicable.
43. Monthly RA Bills
The payment certificates shall be regulated as per the provisions of clause 34 of the contract.
43.1 Upon the signing of agreement the Engineer shall decide the date of submission of monthly statement (RA
Bills) as mentioned in clause 34 (a)
43.2 The Engineer shall check the Contractor’s monthly statement (RA Bills) and certify the amount to be paid
to the contractor within 7 days of submission of monthly statement (RA Bills).
43.3 The employer shall ensure the payment to the Contractor as per clause 34 (d), (e), (f) &(g) within 10
days of submission of monthly statement (RA Bills).
[End of GCC]
46
Contract Data

reference
1.14 Employer UJJAIN MUNICIPALCORPORATION, UJJAIN
Engineer Assistant Resident Engineer of Project Development
1.15
and Management Consultants (PDMC)
Engineer in charge Resident Engineer of Project Development and
1.16
Management Consultants (PDMC)
1.22 Stipulated period of completion 36 months
3 Language & Law of Contract English & Indian Contract Act 1872
Address & contact details of the As per Annexure H
4 Contractor
Address & contact details of the __________________________________________
Employer/Engineer-phone, Fax, __________________________________________
e-mail.
5 Subcontracting permitted for 25% of the Contract value
contract value
Technical Personnel to be As per Annexure I (Format I-3)
provided by the contractor –
6 requirement &
Penalty, if required Technical Rs. 30,000/- per month per person for Degree Holder
personal not employed Rs. 18,000/- per month per person for Diploma
Holder
10 Specifications Annexure E
Drawings As per Annexure N
Competent authority for deciding Superintending Engineer of UADD in charge of
dispute under Dispute resolution Concerned Division
system
12 Appellate Authority for deciding Engineer –In-Chief /Chief Engineer UADD
dispute under Dispute resolution
system
13 Period of submission of updated 30 days upon signing the agreement
construction program
Amount to be withheld or not 0.20% of the Contract Amount
submitting construction program
in the prescribed period
14 Competent Authority for granting Appropriate authority within the Urban Local Body
Time Extension
15 Milestones laid down for the YES
contract
If Yes, details of milestones As per Annexure O
Liquidated damage As per Annexure P
17 List of equipments for lab As per Annexure Q
Time to establish lab 2 months after signing the agreement
Penalty for not establishing field 0.20% of the Contract amount till the establishment of
Laboratory Lab
18 Defect Liability Period 5 (Five) years after physical completion of work
21 Competent authority for Chief Engineer/Engineer-in-Chief UADD
determining the rate
27 Any other conditions for breach NIL
of contract
47

reference
28 Penalty Penalty shall include
(a)Security deposit as per clause 30 of General
conditions of contract and
(b)Liquidated damages imposed as per clause 15 or
performance security (Guarantee) including
additional performance security (Guarantee), if any,
as per clause 29 of General conditions of contract,
whichever is higher.
29 Performance Guarantee Valid Contract Period Plus Three Months &will be
(security) & Additional returned after issue of physical completion certificate
Performance Guarantee as per clause 35.1
(Security) shall be valid up to
Security deposit to be deducted At the rate of 5 %
30 from each running bill
Maximum limit of deduction of Up to 5 % of Final contract amount and will be
security deposit returned after successful completion of Defect
Liability Period.
31 Price adjustment formula and As per Annexure R
procedure to calculate (NOT APPLICABLE)
31.1(1) Price adjustment shall be
applicable (NOT APPLICABLE)
32 32.1 Mobilization and Yes

Construction Machinery Advance
applicable
32.2 If yes, unconditional Bank In the format prescribed in Annexure - S
Guarantee
32.3 If yes, Rate of interest Interest rate as per notified bank rate on the date of
chargeable on advance inviting tender
32.4 If yes, Type & Amount 1. Mobilization advance-Not more than 10% of
payment that can be paid contract amount
32.5 If yes, Recovery of Advance Recovery of Mobilization and/or Construction
payment Machinery advance shall commence when 10% of
the contract amount is executed and recovery of total
advance shall be done on pro-rata basis and shall be
completed by the time work equivalent to 80% of the
contract amount is executed.
In addition to the recovery of principal amount,
recovery of interest shall be carried out as calculated
on the outstanding amount of principal at the close of
each month. The interest shall be accrue from the
day of payment of advance and the recovery of
interest shall commence when 10% of the contract
amount is executed and shall be completed by the
time work equivalent to 80% of the contract amount
is executed.
33 33.1 Secured Advance applicable No
33.2If yes, Unconditional bank In the format prescribed in Annexure-T

Guarantee
48

reference
33.3 If yes, Conditions for a) The materials are in accordance with the
secured Advance specification of works,
b) Such materials have been delivered to site,
and are properly stored and protected against
damage or deterioration to the satisfaction of the
engineer. The contractor shall store the bulk
material in measurable stacks,
c) The Contractor’s records of the requirements,
ordered, receipt and use of materials are kept in
a form approved by the Engineer and such
records shall be available for inspection by the
Engineer;
d) The contractor has submitted whit his
monthly statement the estimated value off the
materials on site together with such documents
as may be required by the engineer for the
purpose of valuation of the materials and
providing evidence of ownership and payment
thereof;
f) The quantity of materials are not excessive
and shall be used within a reasonable time as
determined by the engineer.
33.4 If yes, recovery of secured The advance shall be repaid from each
advance succeeding monthly payments to the extent
materials [for which advance was previously
paid] have been incorporated into the works.
35 Completion certificate- After As per Annexure – U
physical completion of the work
Final Completion Certificate – As per Annexure – V
after final payment on completion
of the work
36 Competent Authority Chief Engineer/Engineer-in-Chief, UADD
39 39.1 Salient features of some of As per Annexure – W

the major labour laws that are
applicable
39.2 Salient features of some As per Annexure – W1
Construction Safety laws that are
applicable
41 Competent Authority Appropriate authority within the Urban Local
Body (Authority Entering in the agreement in
ULB )
49
Annexure – N
(See clause 10 of Section 3 of GCC)
DRAWINGS
Sewer Network Zone – 1(Phase I Work)
S NO. Name of Drawing

1. Schematic Drawing
2. Scheme at a Glance Zonal Connectivity Diagram
3. Sewerage System Layout Drawing for Sewer Laying Zone-1 A
4. Sewerage System Layout Drawing for Sewer Laying Zone-1 B
5. Sewerage System Layout Drawing for Sewer Laying Zone-1 C
6. Drawing for RCC Special Type Manhole
50
51
52
53
54
55
Annexure – O
DETAILS OF MILESTONES
The time allowed for the carrying out the work, as entered in the tender form shall be strictly observed by
the contractor and shall be deemed to be essence of the contract and shall be reckoned immediately 14
days after the signing of agreement.
The work shall throughout the stipulated period of contract be proceeded with all due diligence keeping in
view that time is the essence of the contract. The contractor shall be bound in all cases, to complete the
following financial target,
- 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed,
- 3/8th of the work before 1/2 of such time has elapsed
- 3/4th of the work before 3/4 of such time has elapsed.
56
Annexure – P
COMPENSATION FOR DELAY
If the contractor fails to achieve the milestones, and the delay in execution of work is attributable to the
contractor, the Employer shall retain an amount from the sums payable and due to the contractor as per
following scale –
i. Slippage up to 25% in financial target during the milestone under consideration – 2.5% of the work
remained unexecuted in the related time span.
ii. Slippage exceeding 25% but up to 50% in financial target during the milestone under consideration –
5% of the work remained unexecuted in the related time span.
iii. Slippage exceeding 50% but up to 75% in financial target during the milestone under construction –
7.5% of the work remained unexecuted in the related time span.
iv. Slippage exceeding 75% in financial target during the milestone under consideration – 10% of the work
remained unexecuted in the related time span.
Note: For arriving at the dates of completion of time span related to different milestones, delays which are
not attributable to the Contractor shall be considered. The slippage on any milestone is if made good in
subsequent milestones or at the time of stipulated period of completion, the amount retained as above
shall be refunded. In case the work is not completed within the stipulated period of completion along with
all such extensions which are granted to the Contractor for either Employer’s default or Force Majeure, the
compensation shall be levied on the contractor at the rate of 0.05% per day of delay limited to maximum
of 10% of contract price.
The decision of appropriate authority within the Urban Local Body after scrutiny and recommendation by
Chief Engineer/Engineer-in-Chief UADDshall be final and binding upon both the parties.
57
Annexure – Q
LIST OF EQUIPMENT FOR QUALITY CONTROL LAB
(To be filled-in by the bidder)
The following Equipments/ Machines shall be required for quality control for the various civil works.
Minimum Requirement Available with the Bidder
S. Name of Equipment/ Machinery Quantity Name of Equipment/ Quantity
No. Machinery
1 Digging tools like pick axe, One set
shovel, etc.
2 IS Sieves Nos. with lid and pan (90 ONE
mm, 80 mm, 63 mm, SET
53 mm, 45 mm, 37.5 mm,
26.5 mm, 19 mm, 13.2 mm,
11.2 mm, 9.5 mm, 4.75 mm,
2.8 mm, 5.6 mm, 3.35 mm,
2.36 mm, 600 Micron,
90 Micron and 75 Micron)
3 Sand Pouring Cylinder with tray One set
complete for field Density test
4 Speedy moisture meter One set
complete with chemicals
5 Straight Edges 3.00 metre width Two set
6 Liquid Limit and plastic limit testing One set
apparatus complete with water
bottle and glass wares
7 Electronic/digital balance 5 kg One no.
8 Pan balance with weight box, 5 kg. One no.
9 Slump cone Two no.
10 Concrete cube moulds (150 mm X Twelve
150mm) no.
11 Free swelling index test Six no.
Apparatus
12 Flakiness and elongation testing Two no.
gauges
13 Water absorption test apparatus One no.
14 Specific gravity test apparatus One no.
15 B.S. compaction apparatus One no.
16 Proving rings One each
17 Glass ware One set
18 Auto level and staff Three
nos.
19 Rapid moisture meter One no.
20 Post Hole Auger with One set
extensions
21 Measuring tape, One set
spatula, glassware,
porcelain dish, pestle
mortar
22 Standard Proctor Density Test One set
Apparatus with rammer
23 Electronic/digital balance 1 One set
kg with the least count of
0.01 gm
24 Camber Board Two no.
25 Core Cutter (10 cm dia) One set
10cm/15cm height complete with
dolly and
58
hammer.
26 CBR Testing machine One no.
27 Oven (ambient to 200°C) One no.
28 Digital Thermometers Three no.
Aggregate Soundness One no.
test apparatus
30 Concrete cube testing One no.
machine
31 First aid box One no.
32 Sampling Pipette One no.
33 Balance One no.
34 Dial Gauges Six No.
35 Thickness gauge One set
36 Water still (4 ft.) One no.
37 A.I.V. testing equipment One no.
The above list of essential equipment for quality control is indicative and for guidance and is not complete.Other
apparatus and equipment as desired/required by the Engineer-in-Charge shall be procured by the Contractor
59
Annexure – R
PRICE ADJUSTMENT (DELETED)

The formulas for adjustment f price are as follow:
R= Value of Work as DefinedInClause31.2(3)Of General Conditions Of Contract
Weightages*of component in the work
Sno Component Percentage of component in the work
1 Cement-Pc
2 Steel-P s
3 Bitumen-P b
4 POL -Pf
*Weight agesofvariouscomponentsofthe workshall be asdeterminedbythecompetenttechnicalsanctionauthority.
Adjustmentforcementcomponent
(II) Priceadjustmentforincreaseordecreasein thecost
ofcementprocuredbythecontractorshallbepaidinaccordance withthefollowingformula:
VC= 0.85 x PC/100 x R x (C1-C0)/C0
Vc= increase or decrease in the cost of work during the month under
consideration due to changes in rates for cement.
Co= The all India wholesale price index for Grey cement on the date of opening of Bids as
published by the Ministry of Industrial Development, Government of India, New Delhi.
(www.eaindustry.nic.in)
C1= The all India average wholesale price index for Grey cement for the month under
consideration as published by Ministry of Industrial Development, Government of India,
New Delhi.(www.eaindustry.nic.in)
Pc= Percentage of cement component of the work
Note : For the application of this clause, index of Grey Cement has been chosen to represent
Cement group.
Adjustment of steel component
Price adjustment for increase or decrease in the cost of steel procured by the Contractor shall be
paid in accordance with the following formula:
Vs= 0.85 x PS x /100 x R x (S1-S0)/S0
Vs= Increase or decrease in the cost of work during the month under
consideration due to changes in the rates for steel.
S0= The all India wholesale price index for steel (Bars and Rods) on the date of opening of
Bids as published by the Ministry of Industrial Development, Government of India, New
Delhi. (www.eaindustry.nic.in)
Si = The all India average wholesale price index for steel (Bars and Rods) for the month
under consideration as published by Ministry of Industrial Development, New Delhi.
(www.eaindustry.nic.in)
Ps= Percentage of steel component of the work.
Note : For the application of this clause, index of Bars and Rods has beenchosen to represent
steel group.
Adjustment of POL (fuel and lubricant) component
(V) Price adjustment for increase or decrease in cost of POL ( fuel and lubricant ) shall be paid in
accordance with the following formula:
Vf= 0.85 x Pf / 100 x R x ( Fi – Fo) / Fo
Vf = Increase or decrease in the cost of work during the month under consideration due to
changes in rates for fuel and lubricants.
Fo = The official retail price of High Speed Diesel (HSD) at the existing consumer pumps of IOC at nearest
center on the date of opening of Bids.
Fi = The official retail price of HSD at the existing consumer pumps of IOC at nearest center for the 15th day of
month of the under consideration.
Pf = Percentage of fuel and lubricants component of the work.
Note:Fortheapplicationofthisclause,thepriceofHighSpeedDieselhasbeen chosentorepresentfuelandlubricantsgroup.
60
Annexure - S
(See clause 32 of Section
3 -GCC )
BANK GUARANTEE FORM' FOR MOBILIZATION AND CONSTRUCTION MACHINERY ADVANCE
To,
______________ [name of Employer]
______________ [address of Employer]
______________ [name of Contractor]
ln accordance with the provisions of the General Conditions of Contract, clause 31 ("Mobilization and
Construction Machinery Advance") of the above-mentioned Contract________________[name and address of
Contractor] (hereinafter called "the Contractor") shall deposit with ________________[name of Employer] a
bank guarantee to guarantee his proper and faithful performance under the said Clause of the Contract in an
amount of [amount of Guarantee* [in words].
We, the ______________________ [bank of financial institution] as instructed 'by the Contractor, agree
unconditionally and irrevocably to guarantee as primary obligator and not as surety merely, the payment to
_____________ [name of Employer] on his first demand without whatsoever right of obligation on our part and
without his first claim to the Contractor, in the amount not exceeding [amount of guarantee]*[in words].
We further agree that no change or addition to or other modification of the terms of the Contractor or Works to
be performed there under or of any of the Contract documents which may be made between [name of
Employer] and the Contractor, shall in any way release us from any liability under this guarantee, and we
hereby waive notice of any such change, addition or modification.
This guarantee shall remain valid and in full effect from the date of the advance payment under the Contract
until ______________[name of Employer] receives full repayment of the same amount from the Contractor.
Yours truly,
Signature and Seal :
Name of Bank/Financial Institution:
Address : '
Date :
* An amount shall be inserted by the Bank or Financial Institution representing the amount of the Advance
Payment, and denominated in Indian Rupees.
61
Annexure –T
(See clause 33 of Section 3- GCC)
Bank Guarantee Form for Secured Advance

62
INDENTURE FOR SECURED ADVANCES

Thisindenturemadethe…………………….dayof………………… 20_between
(hereinaftercalledthecontractorwhichexpressionshallwherethecontextsoadmitsorimpliesbedeemedtoincludehisexecutors
,administratorsandassigns)ortheonepartandtheemployeroftheotherpart.
Whereasbyanagreementdated....................... (hereinaftercalledthe said agreement) the contractor has agreed.
ANDWHEREAS,thecontractorhasappliedtotheemployerthathemaybeallowedadvancedonthesecurityofmaterialsabsolutely
belongingtohimandbroughtbyhimtothesiteoftheworksthesubjectofthesaidagreementforuseintheconstructionof
suchoftheworksashehasundertakentoexecutiveatratesfixedforthefinishedwork(inclusiveof
thecostofmaterialsandlabourandothercharges)
andwhereastheemployerhasagreedtoadvancetothecontractorthesumofrupees
onthesecurityofmaterialsthequantities
andotherparticularsofwhicharedetailedinaccountsofsecuredadvanceattachedtotherunningaccountbillforthesaidworkssignedbyt
hecontractoron
andtheemployerhasreservedtohimselftheoptionofmakinganyfurtheradvanceoradvanceson
thesecurityofothermaterialsbroughtbythecontractortothesiteofthesaidworks.
NowTHISINDENTUREWITNESSETHthatinpursuanceofthesaidagreementand inconsideration ofthesum
ofrupees……………………………………….. onor
beforetheexecutionofthesepresentspaidtothecontractorbytheemployer(thereceiptwhereofthecontractordoth
herebyacknowledge)andofsuchfurtheradvances(ifany)asmaybemadetohimasaforsaidthecontractordothherebycovenantandag
reewiththepresidentanddeclareas follows:
That thesaidsumofrupees……………………………………. soadvancedbytheemployerto
(1) Thecontractorasaforesaidandall oranyfurthersumofsumsadvancedas aforesaid

shallbeemployedbythecontractorinortowardsexpendingtheexecutionofthesaid
worksandfornootherpurposewhatsoever.
(2) Thatthematerialsdetailsinthesaidaccountofsecuredadvanceswhichhavebeen
offeredtoandacceptedbytheemployerassecurityareabsolutelythecontractor's
ownproprietyandfreefromencumbrancesofanykindandthecontractorwillnot
makeanyapplicationfororreceiveafurtheradvanceonthesecurityofmaterials
whicharenotabsolutelyhisownpropertyandfreefromencumbrancesofanykind
andthecontractorindemnifiedtheemployeragainstallclaimstoanymaterialsin respectof whichan
advancehasbemadetohimasaforesaid.
(3) That the materials detailed in the said account of Secured Advances and all other materials on the security of which
any further advance or advances may hereafter be made as aforesaid (hereafter called the said materials) shall be
used by the Contractor solely in the execution of the said works in accordance with the directions of the Engineer.
(4) That the Contractor shall make at his own cost all necessary and adequate arrangements for the proper watch, safe
custody and protection against all risks of the said materials and that until used in construction as aforesaid the said
materials shall remain at the site of the said works in the Contractor's custody and on his own responsibility and shall
at all times be open to inspection by the Engineer or any officer authorized by him. In the event of the said materials
or any part thereof being stolen, destroyed or damaged or becoming deteriorated in a greater degree than is due to
reasonable use and wear thereof the Contractor will forthwith replace the same with other materials of like quality or
repair and make good the same required by the Engineer.
(5) That the said materials shall not be removed from the site of the said works except with the written permission of
the Engineer or an officer authorized by him on that behalf.
(6) That the advances shall be repayable in full when or before the Contract receives payment from the Employer of
the price payable to him for the said works under the terms and provisions of the said agreement. Provided that if
any intermediate payments are made to the Contractor on account of work done than on the occasion of each such
payment the Employer will be at liberty to make a recovery from the Contractor's bill for such payment by deducting
there from the value of the said materials than actually used in the construction and in respect of which recovery has
not been made previously, the value for this purpose being determined in respect of each description of materials at
the rates at which the amounts of the advances made under these presents were calculated.
63
(7) That if the Contractor shall at any time make any default in the performance or observance in any respect of any of
the terms and provisions of the said agreement or of these presents the total amount of the advance or advances
that may still be owing of the Employer shall immediately on the happening of such default be repayable by the
Contractor to be the Employer together with interest thereon at twelve percent per annum from the date or respective
dates of such advance or advances to the date of repayment and with all costs, charges, damages and expenses
incurred by the Employer in or for the recovery thereof or the enforcement of this security or otherwise by reason of
the default of the Contractor and the Contractor hereby covenants and agrees with the Employer to reply and pay the
same respectively to him accordingly.
(8) That the Contractor hereby charges all the said materials with the repayment to the Employer of the said sum of
Rupees...............................and any further sum of sums advanced as aforesaid and all costs, charges, damages and
expenses payable under these presents PROVIDED ALWAYS and it is hereby agreed and declared that
notwithstanding anything in the said agreement and without prejudice to the power contained therein if and whenever
the covenant for payment and repayment here-in-before contained shall become enforceable and the money owing
shall not be paid in accordance there with the Employer may at any time thereafter adopt all or any of the following
courses as he may deem best:
(a) Seize and utilize the said materials or any part thereof in the completion of the said works on behalf of the
contractor in accordance with the provision in that behalf contained in the said agreement debiting the
contractor with the actual cost of effecting such completion and the amount due to the contractor with the
value of work done as if he had carried it out in accordance with the said agreement and at the rates
thereby provided. If the balance is against the contractor, he is to pay same to the Employer on demand.
(b) Remove and sell by public auction the seized materials or any part thereof and out of the moneys arising
from the sale retain all the sums aforesaid repayable or payable to the Employer under these presents and
pay over the surplus (if any) to the Contractor.
(C) Deduct all or any par of the moneys owing out of the security deposit or any sum due to the Contractor
under the said agreement.
(9) That except in the event of such default on the part of the contractor as aforesaidinterest on the said advance shall
not be payable.
(10) That in the event of any conflict between the provisions of these presents and the said agreement the provisions of
these presents shall prevail and in the event of any dispute or difference arising over the construction or effect of
these presents the settlement of which has not been here-in-before expressly provided for the same shall be referred
to the Employer whose decision shall be final and the provision of the Indian Arbitration Act for the time being in
force shall apply to any such reference.
64
Annexure - U
(See clause 35 of section 3 -GCC)
Physical Completion Certificate
Name of Work:
____________________________________________________________________________________
____________________________________________________________________________________
____________________________________________________________________________________
Agreement No. ______________________Date________________________

Amount of Contract Rs __________________________
Name of Agency: ______________________________
Used MB No.: __________________________________
Last measurement recorded
a. Page No. & MB No.:____________________________
b. Date:_______________________________________
Certified that the above mentioned work was physically completed on................. (Date) and taken over
on.................... (Date) and that I have satisfied myself to best of my ability that the work has been done properly.
Date of issue
Engineer In Charge
________________
________________
65
Annexure-V
(See clause 35 of section 3 -GCC)
Final Completion Certificate
Name of Work:
___________________________________________________________________________________________
___________________________________________________________________________________________
____________________________
Agreement No._______________________________________ Date: ______________
Name of Agency:________________________________________________________
Used MB No._______________________________
Last Measurement recorded
b. Page No. & MB No._______________________
c. Date___________________________________
Certified that the above mentioned work was physically completed on__________(date)
And taken over on__________(date).
Agreement amount Rs.____________
Final amount paid to contractor Rs._____________
Incumbency of officers for the work
I have satisfied myself to best of my ability that the work has been done properly.
Date of Issue
Engineer In Charge
________________
________________
66
Annexure – W
(See clause 39 of Section 3 -GCC)
Salient Features of Some Major Labour Laws Applicable
(a) Workmen Compensation Act 1923: - The Act provides for compensation in case of injury by accident arising
out of and during the course of employment.
(b) Payment of Gratuity Act 1972: - Gratuity is payable to an employee under the Act on satisfaction of certain
conditions on separation if an employee has completed the prescribed minimum years (say, five years) of
service or more or on death the rate of prescribed minimum days’(say, 15 days) wages for every completed
year of service. The Act is applicable to all establishments employing the prescribed minimum number (say,
10) or more employees.
(c) Employees P.F. and Miscellaneous Provision Act 1952: The Act Provides for monthly contributions by the
Employer plus workers at the rate prescribed (say, 10% or 8.33%). The benefits payable under the Act are:
i. Pension or family pension on retirement or death as the case may be. '
ii. Deposit linked insurance on the death in harness of the worker.
iii. Payment of P.F. accumulation on retirement/death etc.
(d) Maternity Benefit Act 1951: - The Act provides for leave and some other benefits to women employees in
case of confinement or miscarriage etc.
(e) Contract Labour (Regulation & Abolition) Act 1970: - The Act provides for certain welfare measures to be
provided by the Contractor to contract labour and in case the Contractor fails to provide, the same are
required to be provided, by the Principal Employer by Law. The principal Employer is required to take
Certificate of Registration and the Contractor is, required to take license from the designated Officer. The
Act is applicable to the establishments or Contractor of Principal Employer if they employ prescribed
minimum (say 20) or more contract labour.
(f) Minimum Wages Act 1948: - The Employer is to pay not less than the Minimum Wages fixed by appropriate
Government as per provisions of the Act if the employment is a scheduled employment. Construction of
buildings, roads, runways is scheduled employment.
(g) Payment of Wages Act 1936: - It lays down as to by what date the wages are to be paid, when it will be paid
and what deductions can be made from the wages of the workers.
(h) Equal Remuneration Act 1979: - The Act provides for payment of equal wages for work of equal nature to
male and female workers and for not making discrimination against female employees in the matters of
transfers, training and promotions etc.
(i) Payment of Bonus Act 1965: - The Act is applicable to all establishments employing prescribed minimum
(say, 20) or more workmen. The Act provides for payments of annual bonus 'within the prescribed range of
percentage of wages to employees drawing up to the prescribed amount of wages, calculated in the
prescribed manner. The Act does not apply to certain establishments. The newly set-up establishments are
exempted for five years in certain circumstances. States may have different number of employment size.
(j) Industrial Disputes Act 1947: - The Act lays down the machinery and procedure for resolution of industrial
disputes, in what situations a strike or lock-out becomes illegal and what are the requirements for laying off
or retrenching the employees or closing down the establishment.
(k) Industrial Employment (Standing Orders) Act 1946: - It is applicable to all establishments employing
prescribed minimum (say, 100, or 50). The Act provides for laying down rules governing the conditions of
employment by the Employer on matters provided in the Act and gets these certified by the designated
Authority.
(l) Trade Unions Act 1926: - The Act lays down the procedure for registration of trade unions of workmen and
Employers. The Trade Unions registered under the Act have been given certain immunities from civil and
criminal liabilities.
(m) Child Labour (Prohibition & Regulation) Act 1986: - The Act prohibits employment of children below 14 years
of age in certain occupations and processes and provides for regulations o employment of children in all
67
other occupations and processes. Employment of child labour is prohibited in building and construction
industry.
(n) Inter-State Migrant Workmen's (Regulation of Employment & Conditions of Service) Act 1979: - The Act is
applicable to an establishment which employs prescribed minimum (say, five) or more inter-state migrant
workmen through an intermediary (who has recruited workmen in one state for employment in the
establishment situated in another state). The inter-State migrant workmen, in an establishment to which this
Act becomes applicable, are required to be provided certain facilities such as Housing, Medical-Aid,
Travelling expenses from home up to the establishment and back etc.
(o) The Building and Other Construction workers (Regulation of Employment and Conditions of Service) Act 1996
and the Cess Act of 1996: - All the establishments who carry on any building or other construction work and
employs the prescribed minimum (say, 10) or more workers are covered under this Act. All such
establishments are required to pay cess at the rate not exceeding 2% of the cost of construction as. may be
modified by the Government., The Employer of the establishment- is required to provide safety measures at
the building or construction work and other welfare measures, such as canteens, first-aid facilities,
ambulance, housing accommodations for workers near the-work place etc. The Employer to whom the Act
applies has to obtain a registration certificate from the Registering Officer appointed by the Government.
(p) Factories Act 1948: - The Act lays down the procedure for approval of plans before setting up a factory, health
and safety provisions, welfare provisions, working hours, annual earned leave and rendering information
regarding accidents or dangerous occurrences to designated authorities. it is applicable to premises
employing the prescribed minimum (say, 10) persons or more with aid of power or another prescribed
minimum (say, 20) or more persons without the aid of power engaged in manufacturing process.
68
Annexure – W1
(See clause 39 of Section 3 -GCC)
CONSTRUCTION SAFETY
1) IS: 3696(Part-1, 2) Safety code for scaffolds and ladder
2) IS: 3764 Safety code for excavation work
3) IS: 7205 Safety code for erecting of structural steel work
4) SP: 70-2001 Handbook on Construction Safety Practices
1. On all excavation work, safety precautions for the protection of life and property are essential: While
measures to avoid inconveniences to the public are desirable. Such measures and precautions include the
erection and maintenance signs (to forewarn public), barricades, bridges, and detours: placing and
maintenance of lights both for illumination and also as danger signals, provision of watchmen to
exclude unauthorised persons particularly children, from trespassing on the work: and such other
precautions as local conditions may dictate.
2. Suitable scaffolds should be provided for workmen for all works that cannot safely be done from the
ground, or from solid construction except such short period work as can be done safely from ladders.
When a ladder is used, an extra mazdoor shall be engaged for holding the ladder and if the ladder is used
for carrying materials as well suitable footholds and hand-hold shall be provided on the ladder and the
ladder shall be given an inclination not steeper than ¼ to 1(¼ horizontal and 1 vertical.)
3. Scaffolding of staging more than 3.6 m (12ft.) above the ground or floor, swung or suspended from an
overhead support or erected with stationary support shall have a guard rail properly attached or bolted,
braced and otherwise secured at least 90 cm. (3ft.) high above the floor or platform of such scaffolding or
staging and extending along the entire length of the outside and ends there of with only such opening as
may be necessary for the delivery of materials. Such scaffolding or staging shall be so fastened as to
prevent it from swaying from the building or structure.
4. Working platforms, gangways and stairways should be so constructed that they should not sag unduly
or unequally, and if the height of the platform or the gangway or the stairway is more than 3.6 m (12ft.)
above ground level or floor level, they should be closely boarded, should have adequate width and should
be suitably fastened as described in (2) above.
5. Every opening in the floor of a building or in a working platform shall be provided with suitable
means to prevent the fall of person or materials by providing suitable fencing or railing whose minimum
height shall be 90 cm. (3ft.)
6. Safe means of access shall be provided to all working platforms and other working places. Every
ladder shall be securely fixed. No portable single ladder shall be over 9m. (30ft.) in length while the
width between side rails in rung ladder shall in no case be less than 29 cm. (11½") for ladder upto and
including 3 m. (10 ft.) in length. For longer ladders, this width should be increased at least ¼” for each
additional 30 cm. (1 foot) of length. Uniform step spacing of not more than 30 cm shall be kept.
Adequate precautions shall be taken to prevent danger from electrical equipment. No materials on any of
the sites or work shall be so stacked or placed as to cause danger or inconvenience to any person or the
public. The contractor shall provide all necessary fencing and lights to protect the public from accident
and shall be bound to bear the expenses of defence of every suit, action or other proceedings at law that
may be brought by any person for injury sustained owing to neglect of the above precautions and to pay
any damages and cost which may be awarded in any such suit; action or proceedings to any such person
or which may, with the consent of the contractor, be paid to compensate any claim by any such person.
7. (a) Excavation and Trenching - All trenches 1.2 m. (4ft.) or more in depth, shall at all times be
supplied with at least one ladder for each 30 m. (100 ft.) in length or fraction thereof, Ladder shall extend
from bottom of the trench to at least 90 cm. (3ft.) above the surface of the ground. The side of the
trenches which are 1.5 m. (5ft.) or more in depth shall be stepped back to give suitable slope or securely
held by timber bracing, so as to avoid the danger of sides collapsing. The excavated materials shall not be
placed within 1.5 m. (5ft.) of the edges of the trench or half of the depth of the trench whichever is more.
69
Cutting shall be done from top to bottom. Under no circumstances, undermining or undercutting shall be
done.
(b) Safety Measures for digging bore holes:-
(i). If the bore well is successful, it should be safely capped to avoid caving and collapse of the bore
well. The failed and the abandoned ones should be completely refilled to avoid caving and collapse;
(ii). During drilling, Sign boards should be erected near the site with the address of the drilling
contractor and the Engineer in-charge of the work.
(iii). Suitable fencing should be erected around the well during the drilling and after the installation of
the rig on the point of drilling, flags shall be put 50m alround the point of drilling to avoid entry of
people;
(iv). After drilling the borewell, a cement platform (0.50m x 0.50m x 1.20m) 0.60m above ground level
and 0.60m below ground level should be constructed around the well casing;
(v). After the completion of the bore well, the contractor should cap the bore well properly by welding
steel plate, cover the bore well with the drilled wet soil and fix thorny shrubs over the soil. This should
be done even while reparing the pump;
(vi). After the bore well is drilled the entire site should be brought to the ground level.
8. Demolition - before any demolition work is commenced and also during the progress of the work, (i)
All roads and open areas adjacent to the work site shall either be closed or suitably protected.
(ii) No electric cable or apparatus which is liable to be a source of danger or a cable or apparatus used by
the operator shall remain electrically charged.
(iii) All practical steps shall be taken to prevent danger to persons employed from risk of fire or
explosion or flooding. No floor, roof or other part of the building shall be so overloaded with debris or
materials as to render it unsafe.
9. All necessary personal safety equipment as considered adequate by the Engineer-in-Charge should be
kept available for the use of the person employed on the site and maintained in a condition suitable for
immediate use, and the contractor should take adequate steps to ensure proper use of equipment by those
concerned. The following safety equipment shall invariably be provided:--.
(i) Workers employed on mixing asphaltic materials, cement and lime mortars shall be provided with
protective footwear and protective goggles.
(ii) Those engaged in white washing and mixing or stacking of cement bags or any material which is
injurious to the eyes, shall be provided with protective goggles.
(iii) Those engaged in welding works shall be provided with welder’s protective eyeshields.
(iv) Stone breaker shall be provided with protective goggles and protective clothing and seated at
sufficiently safe intervals.
(v) When workers are employed in sewers and manholes, which are in active use, the contractors shall
ensure that the manhole covers are opened and ventilated at least for an hour before the workers are
allowed to get into the manholes, and the manholes so opened shall be cordoned off with suitable railing
and provided with warning signals or boards to prevent accident to the public. In addition, the contractor
shall ensure that the following safety measure are adhered to :-
(a) Entry for workers into the line shall not be allowed except under supervision of the JE or any other
higher officer.
(b) At least 5 to 6 manholes upstream and downstream should be kept open for at least 2 to 3 hours
before any man is allowed to enter into the manhole for working inside.
(c) Before entry, presence of Toxic gases should be tested by inserting wet lead acetate paper which
changes colour in the presence of such gases and gives indication of their presence.
(d) Presence of Oxygen should be verified by lowering a detector lamp into the manhole. In case, no
Oxygen is found inside the sewer line, workers should be sent only with Oxygen kit.
(e) Safety belt with rope should be provided to the workers. While working inside the manholes, such
rope should be handled by two men standing outside to enable him to be pulled out during emergency.
(f) The area should be barricaded or cordoned of by suitable means to avoid mishaps of any kind. Proper
warning signs should be displayed for the safety of the public whenever cleaning works are undertaken
during night or day.
70
(g) No smoking or open flames shall be allowed near the blocked manhole being cleaned. (h) The malba
obtained on account of cleaning of blocked manholes and sewer lines should be immediately removed to
avoid accidents on account of slippery nature of the malba.
(i) Workers should not be allowed to work inside the manhole continuously. He should be given rest
intermittently. The Engineer-in-Charge may decide the time up to which a worker may be allowed to
work continuously inside the manhole.
(j) Gas masks with Oxygen Cylinder should be kept at site for use in emergency.
(k) Air-blowers should be used for flow of fresh air through the manholes. Whenever called for, portable
air blowers are recommended for ventilating the manholes. The Motors for these shall be vapour proof
and of totally enclosed type. Non sparking gas engines also could be used but they should be placed at
least 2 metres away from the opening and on the leeward side protected from wind so that they will not
be a source of friction on any inflammable gas that might be present.
(l) The workers engaged for cleaning the manholes/sewers should be properly trained before allowing to
work in the manhole.
(m) The workers shall be provided with Gumboots or non sparking shoes, bump helmets and gloves,non
sparking tools, safety lights and gas masks and portable air blowers (when necessary). They must be
supplied with barrier cream for anointing the limbs before working inside the sewer lines.
(n) Workmen descending a manhole shall try each ladder stop or rung carefully before putting his full
weight on it to guard against insecure fastening due to corrosion of the rung fixed to manhole well.
(o) If a man has received a physical injury, he should be brought out of the sewer immediately and
adequate medical aid should be provided to him.
(p) The extent to which these precautions are to be taken depend on individual situation but the decision
of the Engineer-in-Charge regarding the steps to be taken in this regard in an individual case will be final.
(vi) The Contractor shall not employ men and women below the age of 18 years on the work of painting
with products containing lead in any form. Wherever men above the age of 18 are employed on the work
of lead painting, the following precaution should be taken:
- (a) No paint containing lead or lead products shall be used except in the form of paste or readymade
paint.
(b) Suitable face masks should be supplied for use by the workers when paint is applied in the form of
spray or a surface having lead paint is dry rubbed and scrapped.
(c) Overall shall be supplied by the contractors to the workmen and adequate facilities shall be provided
to enable the working painters to wash during and on the cessation of work.
10. An additional clause (viii)(i) of Safety Code (iv) the Contractor shall not employ women and men
below the age of 18 on the work of painting with product containing lead in any form, wherever men
above the age of 18 are employed on the work of lead painting, the following principles must be
observed for such use :
(i) White lead, sulphate of lead or product containing these pigment, shall not be used in painting
operation except in the form of pastes or paint ready for use.
(ii) Measures shall be taken, wherever required in order to prevent danger arising from the application of
a paint in the form of spray.
(iii) Measures shall be taken, wherever practicable, to prevent danger arising out of from dust caused by
dry rubbing down and scraping.
(iv) Adequate facilities shall be provided to enable working painters to wash during and on cessation of
work.
(v) Overall shall be worn by working painters during the whole of working period.
(vi) Suitable arrangement shall be made to prevent clothing put off during working hours being spoiled
by painting materials.
(vii) Cases of lead poisoning and suspected lead poisoning shall be notified and shall be subsequently
verified by medical man appointed by competent authority.
(viii)The employer may require, when necessary medical examination of workers. (ix) Instructions with
regard to special hygienic precautions to be taken in the painting trade shall be distributed to working
painters.
71
11. When the work is done near any place where there is risk of drowning, all necessary equipments
should be provided and kept ready for use and all necessary steps taken for prompt rescue of any person
in danger and adequate provision, should be made for prompt first aid treatment of all injuries likely to be
obtained during the course of the work.
12. Use of hoisting machines and tackle including their attachments, anchorage and supports shall
conform to the following standards or conditions:-
(i) (a) These shall be of good mechanical construction, sound materials and adequate strength and free
from patent defects and shall be kept repaired and in good working order.
(b) Every rope used in hoisting or lowering materials or as a means of suspension shall be of durable
quality and adequate strength, and free from patent defects.
(ii) Every crane driver or hoisting appliance operator, shall be properly qualified and no person under the
age of 21 years should be in charge of any hoisting machine including any scaffolding winch or give
signals to operator.
(iii) In case of every hoisting machine and of every chain ring hook, shackle swivel and pulley block
used in hoisting or as means of suspension, the safe working load shall be ascertained by adequate
means. Every hoisting machine and all gear referred to above shall be plainly marked with the safe
working load. In case of a hoisting machine having a variable safe working load each safe working load
and the condition under which it is applicable shall be clearly indicated. No part of any machine or any
gear referred to above in this paragraph shall be loaded beyond the safe working load except for the
purpose of testing.
(iv) In case of departmental machines, the safe working load shall be notified by the Electrical
Engineerin-Charge. As regards contractor’s machines the contractors shall notify the safe working load
of the machine to the Engineer-in-Charge whenever he brings any machinery to site of work and get it
verified by the Electrical Engineer concerned.
13. Motors, gearing, transmission, electric wiring and other dangerous parts of hoisting appliances
should be provided with efficient safeguards. Hoisting appliances should be provided with such means as
will reduce to the minimum the risk of accidental descent of the load. Adequate precautions should be
taken to reduce to the minimum the risk of any part of a suspended load becoming accidentally displaced.
When workers are employed on electrical installations which are already energized, insulating mats,
wearing apparel, such as gloves, sleeves and boots as may be necessary should be provided. The worker
should not wear any rings, watches and carry keys or other materials which are good conductors of
electricity.
14. All scaffolds, ladders and other safety devices mentioned or described herein shall be maintained in
safe condition and no scaffold, ladder or equipment shall be altered or removed while it is in use.
Adequate washing facilities should be provided at or near places of work.
15. To ensure effective enforcement of the rules and regulations relating to safety precautions the
arrangements made by the contractor shall be open to inspection by the Engineer-in-Charge or their
representatives.
16. Notwithstanding the above clauses from (1) to (14), there is nothing in these to exempt the contractor
from the operations of any other Act or Rule in force in the Republic of India.
72
Section 3
Part-II Special Conditions of Contract [SCC]
1. GENERAL:
The special conditions are supplementary conditions to the TENDER and shall form the part of the
contract.
1.1 It shall be the responsibility of BIDDER to co-ordinate with traffic authority, Railways, MPRDC, M.P.
Electricity Board, Telephone authority, various authorities including Public Health Engineering, Water
resource Department for obtaining necessary permissions regarding crossing of road/railway tracks, shift
of various types of public utilities like existing pipe line, sewer line, cable etc. as may be required for the
due fulfillment of the obligations under this contract. UJJAIN MUNICIPALCORPORATION, UJJAIN shall
deposit all charges including charges for Electric Connection, Crossing of Railway and Road way etc. as
may be necessary for seeking required permissions from different authorities but it shall be the primary
responsibility of the contractor/firm to pursue with various authorities and obtain the permissions at the
earliest. If as a result of excavation of trenches the underground services such as water main electric
telephones cable, sewer lines become naked and unsupported it shall be the responsibility of the
contractor to make suitable and necessary arrangement as per direction of the Engineer-in-Charge for
their protection and no extra payment on this account will be made to the contractor. Any damages caused
to the above mentioned underground services due to negligence of the contractor or otherwise the same
shall be made good by the contractor at his own cost.
2.0 Accuracy of Lines, Levels and Grades

2.1 The various works shall be done true to line, level and grade. The periodical checking of these by the
Engineer or Engineer's representative shall not absolve the Contractor of his responsibility regarding their
accuracy. In case of any deviation or discrepancy in line, level or grade at the meeting faces, the
contractor shall make good the discrepancy at his own cost and without any compensation for the
additional work if any involved. Whenever such a discrepancy is found to arise at the junction of works
being carried out by different Contractors the responsibility to set right their respective discrepancies shall
be fixed by the Engineer whose decision shall be final and binding on the Contractors concerned.
Engineer shall further have the unquestioned right if need be to rectify the discrepancies and recover the
cost from the Contractor or Contractors according to proportions as he May consider reasonable.
2.2 The details of location and the nearest permanent bench marks. Reference Grid Marks shall be obtained
by the Contractor in writing from the Engineer. Temporary bench mark for day to day use shall be fixed
with reference to above permanent bench marks with double leveling. The Grid Co-ordinates and its
references May be obtained from the Engineer.
3.0 Arrangements of Water and Electric Power
Arrangement for water and electric power required by the Contractor for the works shall be made by him at
his own cost. Employer will however recommend to the State Electricity Board for giving the connection
and power to the Contractor. However the Employer will bear no responsibility in this respect.
4.0 Measures for Prevention of Fire
4.1 The Contractor shall not set fire to any standing Jungle, trees, brush wood or grass without a written
permission from the Engineer.
4.2 When such permission is given and also in all cases when destroying out of dug trees, brush wood, grass
etc. by fire, the Contractor shall take necessary measures to prevent such fire spreading to or otherwise
damaging surrounding property.
4.3 Any damage caused by the spreading of such fire, whether in or beyond limits of the Employer's property,
the amount of the damage shall be recovered by the Engineer from the Contractor's Bills as damages or
deducted by any other duly authorized officer from any sums that May be due or become due from the
Employer to the Contractor under the contractor otherwise.
4.4 The Contractor shall bear the expenses of defending any action or law proceedings that May be brought
by any person by injury sustained owing to neglect of precautions to prevent the spread of fire and shall
pay any damage and cost that May be awarded in consequence.
5.0 Site Order Book

73
A site order book shall be kept at the Employer's office on the site of the work. As far as possible all orders
regarding the works are to be entered in this book. All entries therein shall be signed by the Engineer on
his representative and the contractor or his authorized representative. In important cases the Engineer will
countersign the entries which have been made. The site order book shall not be removed from the work
site except with written permission of the Engineer and the Contractor or his representative shall be bound
to take note of all instructions and directions meant for the Contractor as entered in the site order book
without having to be called on separately to note them. The Engineer shall submit periodically copies of
the remarks in the site order book to the Employer for record and to the contractor for submitting
compliance report.
6.0 Foundations Depth/Levels.
The drawings indicate the general foundation levels to be adopted for the different conditions of the
structures. During execution these levels May be modified to suit the site conditions. The Contractor shall
not be liable to any compensation for any minor delays on this account. However this May be considered
for granting suitable extension in the completion period if necessitated by such events.
7.0 Approach Road
Necessary approach roads for various construction of components of the work like Sump Well, STP, etc.
shall be satisfactorily constructed and maintained by the Contractor at his own cost.
8.0 Regulation and Bye-Laws----
The contractor shall conform to the regulations, bye laws or any other statutory rules made by any local
authorities or by the Government and shall protect and indemnify the Employer against any claims or
liability arising from or based on the violations of any such laws, ordinance, regulations, orders and
decrees etc.
9.0 Contractor to use Excavated Hard Rock
All useful materials like hard rock etc. excavated by the Contractor at site shall be the property of
Employer and shall be issued to the Contractor at the issue rate of Rs. 200/- per cum. It shall be binding
on the Contractor to use it as rubble, metal aggregate etc. after breaking into the required size for concrete
work and as directed by the Engineer.
10.0 Income Tax
During the course of contract period, deductions of Income Tax shall be made at the prevailing rate of
Department of Income Tax Government of India and as revised from time to time as per the advice of
Income Tax authorities.
11.0 Supply and Arrangement of Materials
(1) The contractor shall make his own arrangement for supply of materials including cement and steel. The
contractor shall be responsible for all transportation and storage of the materials at site and shall bear all
the related costs. The Engineer shall be entitled at any time to inspect or examine all such materials. The
contractor shall provide reasonable assistance for such inspection or examination as May be required.
(2) The contractor shall keep an accurate record of use of materials like cement and steel used in the works in
a manner prescribed by the Engineers.
12.0 Cement
(a) The Contractor shall stock his requirement so as to ensure utilization of cement within 60 days but in no
case later than 90 days Cement older than the period aforesaid shall not be used on any work except with
the written permission of the Engineer, and after satisfactorily passing such lest as he May specify. The
Contractor shall forthwith remove from the work such cement that Engineer has not allowed. The final
disposal of such cement shall comply with the rules in force at the time and as the Engineer May approve
(b) Large stocks of cement shall not be kept at the works but only sufficient quantities shall be kept to assure
continuity of the work. The Contractor shall provided and maintain efficient water proof storage sheds for
cement on the site of work. It shall be stacked on the platform 30 cms. above the floor level and shall be
covered with tarpaulin or any other impervious covering materials in order to protect the cement bags from
moisture. The cement shall be neatly stacked in an orderly manner so as to allow an easy access and
count. The arrangement of storage and utilization shall be such as to ensure the utilization of cement in
the order of its arrival at the stores and the Contractor shall maintain satisfactory records which would at
any time show the date of receipt and proposed utilization of cement laying in the stores at site.
(c) The Engineer shall at all time have access to the stores at sites of the Contractor. He shall have authority
to check and examine the method of storage, record accounting and security provided by the Contractor.
The Contractor shall comply with instructions that May be issued by the Engineer in this connection. The
Contractor shall further at all times satisfy the Engineer on demand and by the production of records and
books or submission of returns and proforma or by other proofs that May be demanded that the cement
brought from the approved manufacturer with date of receipt & consumption etc. The Contractor shall at all
74
times keep his records up to date to enable the Engineer to apply such checks as he May desire to
impose.
The contractor shall provide a double locking arrangement to the store the key of one of the locks being
with the Engineer or his representative at site. The Engineer or his authorized agent will have the authority
to verify the stocks and check the consumption in any manner he thinks proper.
13.0 Special Condition Regarding Conditional TENDER

The BIDDER will have to give an under taking with the instrument of Earnest Money to the effect that there are
no conditions in the TENDER and if any conditions are found the same shall be ignored.
If such an under taking is not found with the Earnest Money, the TENDER will not be opened and not taken into
consideration. However in case the contractor gives such an undertaking at the time of opening of TENDER, the
same may be considered.
14.0 Design and Drawings
(1) The Detailed project report prepared by UJJAIN MUNICIPAL CORPORATION will be basic data for guidance of
Contractor. The contractor will not claim whatsoever on account of deficiency in the data of Detailed Project
Report.
(2) Bidder shall carryout detail survey and investigations (including soil test) as may be required for preparation of
detail designs and drawings.
(3) The detailed design and drawing shall be prepared by Contractor and submitted to Government Engineering
College and PDMC for examination through MUNICIPAL COMMISSIONER and the observations made by the
examining institute shall be duly incorporated by Contractor without any claims what so ever in this regard.
Thereafter the drawing duly vetted by engineering college shall be submitted to chief engineer for final
approvals.
(4) The approved drawings shall remain in the sole custody of the Engineer. The Contractor shall obtain and make
at his own expense any further copies required by him. At the completion of the contract the Contractor shall
return to the Engineer all Drawings provided under the Contract.
(5) One copy of the Drawings to be kept on Site.
One copy of the Drawings furnished to the Contractor as aforesaid, shall be kept by the Contractor on the site
and the same shall at all reasonable times be available for inspection and use by the Engineer and the
Engineer's Representative and by any other person authorized by the Engineer in writing.
(6) As- Built Drawings
The contractor shall submit to the Engineer-in-Charge within 21 days of Physical completion, “Completion”
Drawings as detailed below. These drawings shall be accurate and correct in all respects and shall be
shown to and approved by the Engineer-in-charge.
Completion drawings as below on two prints and one polyester copy shall be supplied by the contractor
along with a soft copy in CD. These drawings shall be developed in latest version of Auto-CAD. Drawings
shall be of standard as stated below.
I. Site plan showing all features existing and as constructed under this contract with all external dimensions
of clear spaces among those, diameter and materials of pipeline etc. complete.
II. Architectural, Civil and Structural details of all components of the plant including plans at different levels,
elevations from all sides as well as sectional etc. complete with all dimensions including Structural
Thickness, Concrete Grade, Reinforcement details, finishing details, schedules of doors and windows,
details of associated fittings and features complete.
III. All piping, plumbing and electrical details with dimensions, diameters etc. complete at specific cases
isometric views of piping may be necessary.
IV. Dimensioned details of all electrical, mechanical and instrumentation equipments including accessories
along with arrangement inside the buildings or enclosures, connected piping and cabling layout etc. all
complete.
V. Dimensioned details of all control and measuring device lined weirs, V-notches, probes, valves, gates,
consoles, panels, switch diagrams/Circuit diagrams shall be used wherever applicable.
VI. L-sections for pipelines laid externally, showing pipe profile, ground profile, soil condition, bedding, location
of specials, valves and other accessories complete.
VII. Dimensioned details of all site development works such as roads, drainage, cables pipelines, landscaping
etc. complete with layout, cross – sections, levels etc. complete.
All drawings shall be prepared in appropriate scale and with adequate notes, legends, titles etc. for clarity.
(7) Disruption of Progress
The Contractor shall give written notice to the Engineer whenever planning or progress of the works is likely to
be delayed or disrupted unless any further drawing or order, including a direction, instruction or approval is
issued by the Engineer within a reasonable time. The notice shall include details of the drawing or order required
and of why and by when it is required and of any delay or disruption likely to be suffered if it is late.
75
(8)Delay and Cost of delay of Drawings

If, by reason of any failure or inability of the Engineer to issue within a time reasonable in all the circumstances
any drawing or order required by the Contractor in accordance with sub-clause (3) of this Clause, the Contractor
suffers delay then the Engineer shall take such delay into account in determining any extension of time to which
the Contractor is entitled under Clause 44 hereof. However the Contractor shall not be entitled to any
compensation for such delay, except extension of time.
(9)Further Drawings and Instructions
The Engineer shall have full power and authority to supply to the Contractor from time to time during the
progress of the Works such further drawings and instructions as shall be necessary for the purpose of the proper
and adequate execution and maintenance of the Works The Contractor shall carry out and be bound by the
same.
15.0 Operation and Maintenance
Contractor shall operate and maintain the Sewerage project of MUNICIPALCORPORATION, UJJAINfor
10 years after successful completion of works, for which Contractor shall be paid separately as per
Annexure ‘J’ Financial Bid. The details of the operation and maintenance charges payable along with the
payment schedule are given in Annexure Y.
16.0 Sufficiency of TENDER
The Contractor shall be deemed to have satisfied himself before tendering as to the correctness and
sufficiency of his TENDER for the Works and of the rates and prices of various Quantities and the
Schedule of Rates and Prices, if any, which TENDER rates and prices shall, except in so for as it is
otherwise provide in the Contract, cover all his obligations under the Contract and all matters and things
necessary for the proper execution and maintenance of the Works. If, however, during the execution of the
Works the Contractor shall encounter physical conditions, other than climatic conditions on the Site, or
artificial obstructions, which conditions or obstruction could, in his opinion, not have been reasonable
foreseen by an experienced contractor the Contractor shall forthwith give written notice thereof to the
Engineer's Representative and if in the opinion of the Engineer, such conditions or artificial obstructions
could not have been reasonably foreseen by an experienced contractor, than the Engineer shall certify
and the Employer shall pay the additional cost to which the Contractor shall have been put by reason of
such conditions, including the proper and reasonable cost. However the Engineer in charge decision shall
be final & binding.
17.0 Planned Reconstruction of Roads Damaged By Project Elements Laying of Pipeline

17.1 In case the pipelines are to be laid under the existing roads / lanes/Bye-lanes, the dismantling of existing
roads/lanes/bye-lanes shall be made in such a way that after laying of pipes or other such structures that are
required to be constructed / placed under the road, the road /lanes/bye-lanes shall be restored to the original
position. This mean that if prior to proposed construction, the road was Black topped with specific composition of
the pavement than after construction, the road shall be constructed by the contractor with the same composition
and specifications. This will also apply for concrete road or any other surface of roads.
17.2 The laying of pipes or other structures under the road is likely to involve public inconvenience such as
interruption to traffic or interference in normal right of way. The Contractor shall ensure that because of the
execution of work minimum possible public inconvenience is caused. For ensuring this, pipeline laying and road
reconstruction work shall be carried out and completed in lengths specified by Employer (not more than 250 mtr.
in one defined stretch of road).The further excavation, dismantling of road and laying of pipes in the same
stretch of road shall not be started unless the earlier work of laying has been completed with full reconstruction
of roads. The scheduling of work shall be got approved by the Engineer In Charge.
18.0 Guidelines for Supervision and Monitoring of Execution of Works Under AMRUT
Procedures to be adopted by the contractor/PDMC as per the following guidelines and format as mentioned
below.
76
77
78
Section 4
Price Break-Up Schedule
Pro-rata
S.N Laying and jointing of DWC AND RCC sewer pipes of Different Diameters Share %
o.
Work of providing, laying and jointing including testing ,commissioning and trial run of
200mm to 400mm DWC HDPE pipes (conforming to IS 16098-2013-Part 2(with up-to-date 19.20
amendments),and 500mm to 2000mm non-pressure (NP3&NP4) RCC socket & spigot
pipes (conforming to IS 458-2003 having total length 454931.00mtr with suitable jointing
material including testing of joints, cost of pipe, jointing material etc complete
Material Dia UNIT Quantity Cost/m

DWC 200/295 mm M 287947 767.00
1. DWC 400/480 mm M 107322 1524.00
RCC/NP3 500 mm M 37862 2117.00
RCC/NP4 800 mm M 4059 5440.00
RCC/NP4 1000 mm M 7524 7075.00
RCC/NP4 1200 mm M 1540 9608.00
RCC/NP4 1600 mm M 2670 14625.00
RCC/NP4 1800 mm M 3359 17126.00
RCC/NP4 2000 mm M 2648 20500.00
Total Metre 454931.0
Construction of 40784 NOS of Circular and Rectangular Manhole of Various Depth 7.32
As Per Standard Specification
Man hole for property connection (House
2
connection) in narrow lanes.
For individual house
Constricting of Man hole with S.O.R UADD

specifications having inside size
600x450mm and 900mm deep including Pre
(a) Cast RCC Man hole Cover (Heavy Duty) No 26873 4818.00
500mm dia having 100mm thickness
conforming to IS : 12592 – 2002 Complete
For cluster of houses
Construction of Man hole with S.O.R UADD

specifications having inside size 90x80 cm
and 45 cm deep including C.I. cover with
frame (light duty) 455x610 mm internal
(b) No. 1318 7290.00
diameter, total weight of cover and frame to
be not less than 38 kg (weight of cover 23
kg and weight of frame 15 kg):
Construction of Man hole with S.O.R UADD

specifications having inside size 90x80 cm
and 60 cm deep including C.I. cover with
(c) frame (light duty) 455x610 mm internal No. 3953 8028
diameter, total weight of cover and frame to
be not less than 38 kg (weight of cover 23
kg and weight of frame 15 kg):
79
Construction of circular type manhole

900mm internal dia. at bottom, 560 mm dia
at top total depth of manhole 900 mm in
brick masonry with 1:5 cement mortar (1
cement : 5 fine sand), 12 mm thick Cement
plaster 1:3 (1 cement : 3 coarse sand)
finished with a floating coat of neat cement.
22.5 cm foundation in cement concrete
grade M-10 (Nominal Mix) with stone
(d) aggregate 40mm nominal size, RCC top No. 7937 6913.0
slab cement concrete M-20 (Nominal Mix)
with stone aggregate 20mm nominal size
and making channel in cement concrete
grade M-15 (Nominal Mix) with stone
aggregate 20mm nominal size neatly
finished, curing fixing of ISI marked heavy
duty SFRC cover etc. complete as per
standard design.
M 1557.00 3934.00
Extra for increasing depth of manhole
(e) mentioned at item (d) above from depth of
900mm to 1650mm.
Construction of circular type manhole 1200 No. 160 13215.00

mm internal dia at bottom, 560mm dia at
top in brick masonry class designation
40 with 1:4 cement mortar 1:4 (1 cement : 4
Coarse sand) 1680 mm depth, 12mm thick
cement plaster 1:3 cement plaster (1
cement : 3 Coarse sand) finished with a
floating coat of neat cement. 30cm thick
foundation in cement concrete grade M-10
(f) (Nominal Mix) with stone aggregate
40mm nominal size, RCC grade M-20
(Nominal Mix) with stone aggregate M-20
nominal size on top slab and making
channel in cement concrete grade M-15
(Nominal Mix) with stone aggregate 20
mm nominal size neatly finished, curing and
fixing of SFRC cover and frame (heavy duty
HD-20) 560mm internal dia conforming to IS
12592.
Extra for increasing depth of Manhole M 49 5400.00
mentioned at item no.14.10 from 1680 mm
(g) to 2290mm with modular brick class
designation 40
Construction of circular type of manhole

1500 mm internal dia. at bottom, 560 mm
dia at top, total depth of manhole 2650mm
in brick masonry with 1:5 cement mortar ( 1
cement : 5 fine sand), 12 mm thick Cement
plaster 1:3 (1 cement : 3 coarse sand )
(h) No. 501 19683.00
finished with a floating coat of neat cement.
30 cm thick foundation in Cement concrete
grade M-7.5 (Nominal Mix) with stone
aggregate 40 mm nominal size, RCC
Cement Concrete grade M-20 (Nominal Mix)
with 20mm Nominal size on top slab and
80
making channel in cement concrete grade

M-15 (Nominal Mix) with stone aggregate 20
mm nominal size neatly finished, curing
fixing of ISI marked reinforced concrete
heavy duty cover (including transportation of
cover) complete. as per standard design.

(i) mentioned at above Item (f) from depth M 382.40 8758.00
2.65 m to 4.25m
(j) mentioned at above Item (f) from depth M 459.25 14979.00
4.25m to 9.75m
RCC Special Type manhole with drop
manhole arrangement including high flood
(k) No. 42 145000.00
protection arrangementas per enclosed
drawing
Providing MS/CI/Plastic Encapsulated on
12mm dia. Steel bar (IS:10910) foot rests
and fixing in manhole with CC blocks of
Cement Concrete grade M-10 (Nominal Mix)
(l) with stone aggregate 20 mm nominal size of Kg 126858.20 71.00
size 30x20x15cm
With 20mm square bar/ casting one foot rest
(average weight of 1 foot rest 2.35kg
Work of House Sewer Connections (Pipes)
Providing, Laying, Jointing and suppy of DWC HDPE Pipes of renowned duly tested
3 inclusive of all texes related to central, state and municipal, inclusive of excise duty, 3.91
Inspection Charges, Transportation charges, transit insurences/ loading and unloading and
stacking at site/store etc. complete.
Providing, Laying, Jointing and supply of

DWC HDPE Pipes of renowned duly tested
inclusive of all taxes related to central, state
and municipal, inclusive of excise duty,
(a)
Inspection Charges, Transportation
charges, transit insurances/ loading and
unloading and stacking at site/store etc.
complete.
170/200 mm M 482100.00 298.00
Excavation, filling and road restoration

For laying the pipe line existing surface/roads structure shall be dismantled in appropriate
width. The dismantling of various layers of roads shall be carried out as per requirements
but within the particular item given in Schedule of rates. The pipe shall be laid over the
approved bedding and in true level as per specifications.
4 41.27
After laying the pipe the back filling with appropriate material shall be carried out in such a
way that the compaction is achieved to 100% OF MDD.for reconstruction of roads,the sub
grade, the sub base, the base course and the surface layers shall be constructed as per
specifications. The surface and composition of pavement of road being reconstructed over
the laid pipe shall be the same as the road which was existing before the laying of pipe
Earth work Excavation for pipe trench in all

kind of soil and WBM in areas including
4.1 dressing, watering and ramming and
disposal of excavated earth lead upto 50
met. and lift up to 1.5m disposal earth to be
levelled , neatly dressed.
81
4.1 Ordinary Soil including dressing,watering Cum 855182.00 129.10

(A) and ramming
4.1 Soft rock with or without blasting or Cum 898010.06 211.00
(B) bituminous pavement
4.2 Hard Soil/moorum, moorum mixed with Cum 24744.00 230.00
(C) boulders etc.
Extra for every additional lift of 1.5m or part Cum 1146871.00 5.00
4.1 there of over item A to C.
(D)
Dismantling C.C./R.C.C. WORK BY Cum 80127.70 703.0
MECHENICAL MEAN including staking of
4.2 serviceable material and disposal of
unserviceable material with in 50m lead (
for CC road)
Filling available excavated earth in trenchs, Cum 2572371.6 29.00

plinth sides of foundation in layer not
exceeding 20cm. In depth including
4.3 consolidation of each layer by ramming
watering, lead up to 50m and lift up to1.5m
in all kind of soil.
Filling with moorum for pipe bedding or over Cum 36968.00 625.00
4.4 the pipe including supply of moorum
Construction of dry lean cement concrete Cum 56630.60 2715.00

Sub- base over a prepared sub-grade with
coarse and fine aggregate conforming to IS:
383, the size of coarse aggregate not
exceeding 25 mm, aggregate cement ratio
not to exceed 15:1, aggregate gradation
after blending to be as per table of MORTH
4.5 specification 600-1, cement content not to
be less than 200 kg/ cum, optimum moisture
content to be determined during trial length
construction, concrete strength not to be
less than 10 Mpa at 7 days, mixed in a
batching plant, transported to site, laid with
paver with electronic sensor/ mechanical
paver, compacting with 8-10 tonnes
vibratory roller, finishing and curing and as
per relevant clauses of section-603
Construction of dowel jointed, plain cement Cum 36592.08 4698.00
concrete pavement in M- 30 grade concrete
over a prepared sub base with 43 or higher
grade cement, maximum size of coarse
aggregate not exceeding 25 mm, mixed in a
batching and mixing plant as per approved
mix design, transported to site, laid with a
fixed form or slip form paver with spreading
the concrete by shovels, rakes Compacted
using needed, screed and plate vibratos
4.6 and finished in a continuous operation
including provision of contraction,
expansion, construction and longitudinal
joints, joint filler, separation membrane,
sealant primer, joint sealant, debonding
strip, placing of dowel bar and tie rod
admixtures as approved, curing compound,
finishing to lines and grades as per
approved drawings as per IRC-15 2002 and
as per relevant clauses of section-602 of
specifications complete but including cost of
82
steel in dowel bar and tie rod etc.

Providing & laying mechanically mixed
cement concrete 20mm maximum size
4.7 graded crushed stone including cost of
centering & Shuttering
PCC M20 Cum 71532.79 4778.00
Construction of granular sub-base by
providing coarse graded material, spreading
in uniform layers with on prepared surface,
mixing by mix in place method at OMC, and
4.8 compacting with vibratory roller to achieve
the desired density, complete in all respect
and as per relevant clauses of section-400.
Grading-II Material Cum 36968 614.00
Cutting of Water bound macadam road and Cum 12300.00 693.00
making good the same including supply of
4.9 extra quantities of materials i.e. aggregate,
moorum screening and labour required
Construction of granular sub-base by
providing coarse graded material,
spreading in uniform layers with on
4.10 prepared surface, mixing by mix in place
method at OMC, and compacting with
vibratory roller to achieve the desired
density, complete in all respect and as per
relevant clauses of section-400.
Grading-II Material Cum 24000 614
Providing and applying primer coat & Tack Sqm 80000 26
Coat with bitumen emulsion on prepared
surface of granular Base including clearing
of road surface and spraying primer at the
4.11 rate of 0.75 kg/sqm using
mechanical/Manual means and as per
relevant clauses of section-502.
Providing and laying bituminous macadam Cum 8000 5565

with hot mix plant using crushed aggregates
of specified grading premixed with
bituminous binder, transported to site, laid
over a previously prepared surface with
mechanical paver finisher to the required
grade, level and alignment and rolled as per
4.12 clauses 501.6 and 501.7 to achieve the
desired compaction complete in all respects
and as per relevant clauses of section-504.
for Grading I ( 80-100mm thickness )
bitumen content 3.25%
Providing and laying semi dense bituminous Cum 5179.2 7822

concrete with hot mix plant using crushed
aggregates of specified grading, premixed
with bituminous binder, transporting the hot
mix to work site, laying with mechanical
paver finisher to the required grade, level
4.13 and alignment, rolling with smooth wheeled,
vibratory and tandem rollers to achieve the
desired compaction in all respects and as
per relevant clauses of section-508. (Only
cement will be used as filler).
83
Transportation rate of different other

material in comparison with 20mm metal.
4.14
Total Qty excavated stuff to be transported
For Lead up to 1KM Cum 22890 91
Installation of Product Pipe by Manual
Jacking Method including making of entry
and exits pits, all related civil works like
excavation shoring/strutting etc., Manual
shielding excavation lowering of pipe
segments in the jacking pit, laying and
jointing of product pipe line through jacking
4.15 process from the jacking pit and restoration
of site after project completion as per the
instructions of the Engineer-in-charge all
complete except the cost of the pipe. (upto
100 meter of installation length)
Above 1500mm and upto 1800mm

In hard Soil M 15 68000
In stoney Soil M 135 92000
Above 1800mm and upto 2200mm
In hard Soil M 15 102000
In stoney Soil M 135 130000
Installation of Product Pipe by Pipe

ramming method including making of entry
and exits pits, all related civil works like
4.16 excavation shoring/strutting etc. and
restoration of site after completion (Up to
100m),
Pipes above 450mm and up to 600mm
In Hard Soil M 20 35438

In Hard Rock M 180 51883
Random rubble stone masonry with hard Cum 466 2671
stone in foundation & Plinth including
4.17 levelling up with cement concrete m-5
(Stone aggregate 20 mm) at plinth level with
cm 1:6
5 Construction of sewage Collection System and Pumping Machinary and Force main
(sewage pumping Station)
A- Designing (aesthetically), and constructing
RCC Dry cum wet well/RCC sumps in mix
of M-30 required capacity including
excavation in all types of strata, foundation
concrete, container walls, bottom slabtop
RCC roof slab, 20 mm thick cement plaster
with water proofing compound in CM 1:3
proportion to inside face of the container, 1.61
including chlorinated reburised paint from
inside and acrylic paint on the external
surfaces including refilling and disposing of
surplus stuff with in lead of 50M, all labour
and Material Charges, for laying and
jointing of pipe assembly for inlet, outlet
washout connections with Sluice valves,
84
overflow and bypass arrangement

consisting of C.I. M.S. D/F. pipes upto 10m
outside the structure, special and valves
for valves of suitable diameters, providing
stair case(RCC) & accessories such as
M.S. ladder inside and outside, C.I.
Manhole frame and cover, water top slab,
B.B. Masonry chamber for all valves,
ventilating shaft, including giving
satisfactory hydraulic test and water
tightness test as per IS Code and
Providing three coats of cement paints to
all exposed surface of structure including
roof surface etc. complete as per design
data, criteria obligatory requirements and
detailed specifications. Anti-termite
treatment shall be given for underground
portion of the structure. Protection
arrangement for sump well approach slab
for access in well. Providing Grit chamber
with coarse and fine screen, Bypass
channel Gate Valve, Dewatering Pumps,
and area sufficient to accommodate 5
Pumping Sets and suction delivery
System, Manifolds, Suitable Exhaust fans,
Super Structure, Gate, Window,
approaches, Suitable, Control Panel all
complete.
Cum 2298 Rate

Analysis
Pro Rata Percentage for Item No. 5(B), 5(C), & 5(D)
B Supplying spirally
welded/ERW/SAW/fabricated M.S. pipes
(commercial Quality) including procurements
of plates, gas cutting to required size rolling,
tack welding assembling in suitable lengths to
form pipes, welding on automatic welding
machine and forming 'V' edge on both ends of
pipes including all taxes (central and locl ), 1.22
railway freight, insurance unloading from
railway wagon, loading in to truck, transport to
stores/site, unloading, stacking, etc, complete
as per IS-3589 and IS-5504 as applicable as
per specification ( NO negative tolerance in
thickness is permissible).
1200 mm dia and 10mm Thick MS Pipes M 2500 17960

C Providing and making inner cement mortar
lining to M.S. pipes with mechanical devices in
cement mortar 1:1 proportion, including cost of
all material,labour,special sand required,
machinery, power generation, all equipment
and taking necessary access opening and
manholes, cut at suitable intervals as directed
0.03
by Engineer-In-Charge and rewilding the
same after done with double plates pipes
including necessary excavation, refilling
concrete braking and remaking if any, braking
guniting and remaking the same, repainting
where even required with epoxy paint in three
coats, all dewatering including emptying the
85
pipe line and refilling the same after done with

(water to be supplied by department free of
cost within 5Km lead at fixed point and all
other arrangement to be done by agency),
including carrying out" C" value performance
test of pipe line , complete job as per the
direction of Engineer-In-Charge.
12mm thick for pipe up to 1200mm diameter Sqm 2826 377
D Providing and applying with mechanical

arrangement 1:3 proportion cement sand
gunite, 40 to 50 mm thick to M. S. pipe surface
under 2.1 kg per sqcm to 2.80 kg per sqcm
Pressure including removing the loose
materials as directed by Engineer-in-charge
and including scrapping the surface with wire 0.11
brushes, degreasing cleaning by compressed
air and providing fixing wire febric as per
Annexure – A of IS 3589-2001 as reinforced
curing for 21 days disposing off the rebound
materials within a lead of 50 M, etc Complete
as directed by Engineer-in-charge.
1200 mm dia and 10mm Thick MS Pipes Sqm 9577 416
E Lowering laying in position to correct line and

level M.S. Pipes including M.S. Specials
with/without any out coating such as distance
pieces straps band stapersetc, on pedestal or
chairs upon formation the rate to include 0.04
loading unloading hoisting marginal cutting
wherever required, assembling and tack
welding, and transportation up to 500m etc
complete
1200 mm dia and 10mm Thick MS Pipes M 2500 640
F Providing, erecting,testing and commissioning
at site of Horizontal Centrifugal Pumps
suitable for 92 MLD plant as per CPHEEO
manual with complete in all respects i.e
discharge valves spread manifold Pressure
1.59
Gauges, Level switch, MOC of pump as CI
Casing, Impeller and other wetted parts in SS-
316, Shaft SS-410 with suitable rating motor
class F insulation and IP55 Protection, 3Hp,
440 V, 50 HZ
(As per Quotations collected from Market)
Two Pumps each suitable to pump sewage No. 2 7200000
peak flow/4 i.e 625 LPS 32m Head 360HP
Three Pumps each suitable to pump sewage No. 3 14000000
peak flow/4 i.e 1250 LPS 32m Head 700HP
Providing and fabrication of common pipes M 32 3102
manifold, valves and special complete in all
respect as per the direction of engineer in-
charge
Providing and erection of suitable control No. 2 550000
panel for above pumps
Provide pump for dewatering, 3 Pumps
(Required for dewater from dry well)
2HP No. 1 30000
3HP No. 1 45000
5HP No. 1 750000
86
Total
6 Construction of Effulent Disposal Recycling, Reuse and Recharging of Near By
0.86
Water Bodies After Package Treatment
Providing, Laying and Jointing non- M 500 598
Pressure (NP-2) RCC socket & Spigot
pipes with rubber gasket joints including
testing of joints (Conforming to IS: 458-
1988, ISI marked (Laying as per IS: 783:
1985)
Providing pumping main of 200 mm dia for M 500 1876

length of 500 mt for pumping
recycled/treated water from effleunt
collection sump well to nearby Water
Bodyincluding valves and everything (DI
K7 Pipe)
Provision of mini package treatment plant Mld 2 2500000

to be installed for treatment and recharging
of RudraSagar(Block Cost)
Renovation and Lining of Rudrasagar area LS 9600000

with Cement Concrete as per Engineer-in-
Charge
7 CONSTRUCTION OF THE SEWAGE TREATMENT PLANT WITH OTHER ALIED
21.28
WORKS
Construction of 1 number STP based on MLD 92 8500000
SBR or suitable technology for achieving
desire quality of sewage 1 having capacity
92 MLD. The plant shall have SCADA-PLC
for controlling and quality monitoring at inlet
and outlet point of process treatment
including sewage laboratory and
administrative building all complete
8 Construction of Electrical substation, Installation, Erection, Testing commissioning
and of power line as per MPSEB Specification (approval, sanction and release to be 1.56
obtained from MPSEB)
A Cost per Km L T Line including Substation KM 3.0 1500000.0
Total Cost of 3.0 Km HT/LT Line for SPS &
STP
B Provision for DG Set KVA 890 9000
C Transformer for STP and SPS KVA 3750 9000
Total (Percentage) 100%
Note:
1.0 Under this agreement, it is clarified that any payment for the work of feeder/ distribution/ road
reconstruction/ house service connection/ HT feeder for any executed quantity shall only be made on
the item rates given against each item of the work, after these given rates are adjusted by a factor
explained in point no. 2 below. Accordingly the total lumpsum accepted tender cost shall be adjusted as
per actual work done under these items.
Thus, any increase or decrease in the work described above (pipe line, road reconstruction and
house connection work) shall be paid or deducted from the total agreement cost of the work on
the basis of the unit rates of actual quantities of these items executed.
2.0 The final rates of above items shall be the rates plus or minus the overall percentage of the approved
lumpsum tender cost. If the accepted cost of this tender is “x” than all the above mentioned rates shall be
adjusted by a factor of “x” / (__) and the increase/reduction shall be done on the basis of such adjusted rates.
3.0 As per clause 21 of GCC if any order for change of scope is issued the contractor shall be liable to
execute quantities more than the above quantities, if required as per site conditions and payment for
such excess work shall also be made on the adjusted rates mentioned in point no. 2 above. Such
excess quantities shall however remain within the 10% of the agreement cost of the total work.
87
4.0 Bidder shall be responsible for road reconstruction of pipe trenches till one rainy season. In case of any
repair to be made because of bad quality of construction the same shall be made good without any
extra cost.
5.0 Bidder shall carry out fencing along the boundary of Sumpwell and STP.
6.0 The scope of work includes shifting of electric poles, crossing of Railway/Highway as may be required for
laying of pipeline. No extra payments shall be made to the contractor for doing the same.
7.0 For Manhole Item contractor can use Precast Manholes if feasible with prior approval from Engineer-In-
Charge. However, payment for such item will be restricted to rates provided in BOQ for similar items.
88
SECTION 5
AGREEMENT FORM
AGREEMENT
(On Non Judicial Stamp Paper of Rs. 1000.00)
This agreement, made on the day of __________________between (name and address of Employer)
(hereinafter called “the Employer) and ________________(name and address of contractor) hereinafter called
"the Contractor" of the other part.
Whereas the Employer is desirous that the Contractor execute ____________________(name and
identification number of Contract) (hereinafter called "the Works") and the Employer has accepted the Bid by
the Contractor for the execution and completion of such Works and the remedying of any defects therein, at a
cost of Rs. __________________________
NOW THIS AGREEMENT WITNESSED as follows:

1. In this Agreement, words and expression shall have the same meanings as are respectively assigned to them
in the conditions of contract hereinafter referred' to and they shall be deemed to form and be read and
construed as part of this Agreement.
2. In consideration of the payments to be made by the Employer to the Contractor as hereinafter mentioned, the
Contractor hereby covenants with the Employer to execute and complete the Works and remedy any defects
therein in conformity in all aspects with the provisions of the contract.
3. The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the
Works and the remedying the defects wherein Contract Price or such other sum as may become payable under
the provisions of the Contract at the times and in the manner prescribed by the Contract.
4. The following documents shall be deemed to form and be ready and construed as part of this Agreement viz.
i. Letter of Acceptance
ii. Contractor's Technical and FinancialBid
iii. Condition of Contract: General and Special
iv. Contract Data
v. Bid Data
vi. Drawings
vii. Bill of Quantities and _
viii. Any other documents listed in the Contract Data as forming part of the Contract.
In witnessed whereof the parties there to have caused this Agreement to be executed the day and year first
before written.
The Common Seal of affixed in the presence of:
Signed, Sealed and Delivered by the said __________________________________________________ in

the presence of:
Binding Signature of Employer ________________________________
Binding Signature of Contractor________________________________

89
Section-6
ANNEXURE :X
BILLING BREAK-UP
Sewerage Network &Misc work including Transportation, Laying, Jointing and Testing (19.20% of the total
sanctioned cost)
1 5% shall be payable to the Contractor after approval of designs and drawings.
2 50% shall be payable to the Contractor on supply of pipes.
3 30% shall be payable to the Contractor after laying of pipeline in all respect on pro-rata basis (i.e, with
the on progress of work).
4 10% shall be payable on Successful Testing of the pipeline.
5 5% shall be payable after completion of the whole work and trial run for a period of 1 month.
For House Sewer chambers and Manholes (7.32 % of the total sanctioned cost)
1. 5% shall be payable to the Contractor after approval of Designs and drawings.
2. 85% shall be payable to the Contractor on civil construction.
3. 10% shall be payable to the Contractor after completion & Successful Testing of the connection.
For Sewage Treatment plant,Pumping Machinery and Force Main (25.88 % of the total sanctioned cost)
1. 5% shall be payable to the Contractor after approval of designs and drawings.
2. 10% shall be payable to the Contractor after completion of excavation and foundation works.
3. 15% shall be payable to the Contractor after completion of works upto ground level.
4. 10% shall be payable to the Contractor after supply of all electrical and mechanical equipments.
5. 30% shall be payable to the Contractor on super structure work on pro-rata basis
6. 10% shall be payable to the Contractor after erection, installation of all electrical and mechanical
equipments.
7. 10% shall be payable on Successful Testing.
8. 10% shall be payable after completion of the whole work and trial run for a period of 1 month.
For Electrical Substation, Installation, Erection, Testing Commissioning and Power Line(1.56 % of the total
sanctioned cost)
1 5% shall be payable to the Contractor after approval of Designs and drawings.
2 65% shall be payable to the Contractor on supply of all the electro-mechanical items at site.
3 25% shall be payable to the Contractor on erection and complete fitting of motors and pumps at site.
4 5% shall be payable to the Contractor after completion of the whole work
For House Sewer Connection(3.91 % of the total sanctioned cost)
1 5% shall be payable to the Contractor after approval of designs and drawings.
2 50% shall be payable to the Contractor on supply of material including pipe, specials etc.
3 30% shall be payable to the Contractor after completion of laying of 50% length of pipeline in all
respect incl. road restoration on pro-rata basis.
4 10% shall be payable on Successful Testing of the connections.
5 5% shall be payable after completion of the whole work and trial run for a period of 1 month.
Excavation, pipe bedding, refilling, Road restoration work for Distribution Network (41.27% of the total
sanctioned cost)
Payment for Excavation, pipe bedding, refilling, road restoration work shall be made as per actual work done on
unit rate basis.
For Effluent Disposal Recycling, Reuse and Recharging of near by water body after Package
Treatment(0.86 % of the total sanctioned cost)
1. 5% shall be payable to the Contractor after approval of designs and drawings.

2. 50% shall be payable to the Contractor on supply of material including pipe, specials etc.
3. 30% shall be payable to the Contractor after completion of laying of 50% length of pipeline in all
respect incl. road restoration on pro-rata basis.
4. 10% shall be payable on Successful Testing of the connections.
5. 5% shall be payable after completion of the whole work and trial run for a period of 1 month.
90
ANNEXURE:Y
Operation and Maintenance:
The Bidder shall be responsible for the operation and maintenance of the project for a period of 10 years
from the date of successful completion of the work. During O&M all the expenses for repairs, replacements &
consumables except electricity (to be borne by ULB upto the limit as given below) shall be on the part of
Bidder. It shall be the responsibility of Bidder that the system runs at desired capacity and efficiency during
the O&M period. ULB shall extend all the necessary support to the Bidder for fulfilling the Obligations for
operating and maintaining the system successfully. During O&M the scope of Contractor shall be to operate
and maintain the sewerage system and Sewage Treatment plant. A brief detail is given in Service level
agreement.
Details of minimum Staff to be deployed by Bidder for Operation and maintenance of the project,
S.No. Particulars Minimum Experience No. Minimum

Qualification monthly salary
at the start of
O&M in
Rupees
1.0 Project Manager B.E.(Civil) 5 years 01 30,000
2.0 Mechanical Engineer Dip (Mech) 3 years 01 18,000
3.0 Chemist BSc.(Che) 3 years 01 12,000
4.0 Electrician ITI (Elect.) 3 years 01 7,200
5.0 Skilled labours - - 12 7,200
6.0 Un skilled labours - - 12 6,000
7.0 Sweeper - - 30 7,200
The payment against the O&M shall be made in 4 equal installments after completion of each quarter.Period of
Operation and Maintenance can be extended upto 15 years on the same terms and conditions as mentioned in
this Bid. If bidder does not employ the no. of staffs shown, proportionate deduction shall be made accordingly.
91
Service Level Agreement
The variations allowed in treated effluent quality during Operation & Maintenance (O&M) period of 10 years and during
Defect Liability Period, and penalty for not maintaining the standards are as below:
The treated water quality and other key deliverable standards shall be demonstrated by the Contractor at,
The nominal design flow

(1) 25% of nominal design flow*
(2) 10% above the nominal design flow*
(3) The pollutant concentration of all incoming pollutants as freight (i.e. kg/day in terms of flow received) in a range
of 75% to 110% of the pollutant freight calculated at the design pollutant concentration and nominal design flow.
*On some occasions during the year like festivals, excessive rain, extreme weather conditions etc.
Parameter Maximum Allowed Concentration (MAC)
BOD 10 mg/l
TSS 10 mg/l
Faecal Coliforms(FC) 230 MPN/100 ml
Total Nitrogen as N 10 mg/l
Ammonia Nitrogen as N 2 mg/l
Total Phosphorus as P 2 mg/l
* An event is defined as online reporting duration, not exceeding 3 minutes i.e. a maximum of total 30 minutes a day
i.e. 98% system reliability.
Non-compliance to demonstrate the plant performance during the completion tests with respect to treated water quality
and sludge quality for a continuous period of 72 hours, is not acceptable and the Contractor shall rectify the facility to
demonstrate the performance. Not being able to demonstrate the plant performance shall render the plant as “Non-
Acceptable” leading to a Liquidity Damages of 10% of contract Price and shall forfeit the Performance Securities.
Contractor to maintain guarantee parameters for treated effluent quality during O & M period and during Defect Liability
Period. These quality parameters are subject to presumptions that actual Pollutants like BOD, TSS, Nitrogen) load will
not exceed design pollutant load for every parameter. However, on some occasions during the year (i.e festivals,
excessive rain, extreme weather conditions), individual pollutant concentration (mg/l) can exceed up to 10% of design
parameters, and total sewage flow can exceed up to 10% design flow.
The treated effluent parameters shall be demonstrated with 24 hour composite samples with 95% compliance on
monthly basis.
The Maximum Allowed Concentration (MAC) on individual grab samples shall not be more than 2 times of the above
specified 95 percentile value.
If any parameter of any grab sample exceeds the MAC values, the sample shall be considered as “Non-Compliant”.
Guarantee for Faecal Coliform shall be based on 30 days geometric mean value. However, if pollutants load (kg/day)
exceeds the design pollutant load per day basis, or total flow exceeds the design capacity (24 hr basis), no penalty shall
be applicable.
During trial run and commissioning, no penalties will be applied and Contractor will rectify the plant to ensure
successful commissioning.
However, during DLP of 60 months and O & M period of 10 yrs, MUNICIPALCORPORATION, UJJAIN will impose
following penalties/liquidated damages for not maintaining the guaranteed parameters, as described below:
92
Condition A:-
Liquidated Damages for non-compliance of treated effluent standards
Event Triggering the recovery of Liquidity Liquidated Frequency

Damages Damages
Non-conformance with MAC forBOD Rs. 2000/- For every event of non- conformance*
Standard
Non-conformance with MAC for TSS Rs. 2000/- For every event of non-conformance*
Standard
Non-conformance with MAC For Total Rs. 2000/- For every event of non-conformance*
Nitrogen
Non-conformance with MAC for Ammonia Rs. 2000/- For every event of non-conformance*
Nitrogen
Non-conformance with MAC for Faecal Rs. 2000/- For every event of non-conformance**
Coliform Standard
* An event is defined as online reporting duration, not exceeding 3 minutes i.e. a maximum of total 30 minutes a
day i.e. 98% system reliability.
** An event is defined as daily composite sample, not exceeding one non-conforming sample in 30 days i.e. 97%
system reliability.
The cumulative of above liquidated damages shall not exceed the monthly O&M cost (Maximum liquidated
Damages).
Condition-B: Breakdown of Equipment:

In case of breakdown of equipment for more than the stipulated time period as below, on discretion of Engineer-in-
Charge, the Contractor shall be penalized as mentioned below:
Equipment Breakdown Time Penalty Imposed

Period
Critical Equipment/ beyond 72 hours i.e. 3% of Monthly O&M

Instrumentation (Critical 72 hours Cost per day of
equipment shall mean those default beyond
equipment’s / systems which are permitted
essential to ensure the plants breakdown time
performance and it shall include period
all flow and treated water quality
measuring instruments and
systems including submersible
mixers , blowers, sludge and
MLSS recirculation pumps,
disinfection (chlorination system),
filters electrical systems such as
critical electrical system such
transformers, electrical panels
93
etc.)
Breakdown Time Penalty to be Penalty to be
Equipment/ Systems Period Imposed Imposed
(B) Semi-Critical
Equipment
Semi 2% of Monthly O&M
Critical equipment shall Mean More than 7 days Cost
those equipments / systems which per day of default
are beyond
normally necessary to ensure the permitted breakdown
plants time
performance and they shall include
all Period.
screens, grit removal systems,
primary
clarifiers, bio reactors (aeration
system),
secondary clarifiers, sludge
thickening,
and digestion systems
etc.
( C) Non Critical 1% of Monthly O&M
Equipment More than 10 days Cost
Non Critical equipment shall per day of default
mean beyond
those equipments/ systems which permitted breakdown
have time
been provided at the plant but Period.
not critical towards operation of the
plant/ for delivering the plants
performance, such as area lighting,
air conditioners, instruments etc.
The cumulative of above liquidated damages shall not exceed the monthly O&M cost (Maximum Liquidated Damages).
NOTE: In case the non-conformance, on a continuous basis, due to Condition A and Condition B becomesequal to or
more than 50% of the monthly O&M value for a period more than 3 months in a year i.e. 90 days in a year, then the
Employer reserves the right to terminate the Contract after en-cashing all the Security Deposits, Retention Money and
Performance Guarantees.
Condition- C:
Grid Power Failure:
In any case, if the Grid Power failure is more than 8 hrs in a single occasion in a day orcumulative Grid Power failure is
more than 8 hrs in a day
a) No treatment standards will be compulsory. However, contractors are encouraged to maintain standards as far as
possible. No penalties will be imposed on contractor for the above contingencies. Above relaxation shall be applicable
only for a period of 24 hours after resuming regular Grid Power.
Condition-D:
Cost of Electrical Energy:
Contractor shall give complete details of Total Power Consumption, Guarantee Power Generation and Net Grid Power
(if any) consumed in the STP/ WWTP.
During Operation and Maintenance, damages payable by Contractor to Employer on excess consumption of Net Electrical
Energy shall be equal to the actual cost of the excess energy used for Operation and Maintenance of the Works for
STP/WWTP under the Contract, based on the Guaranteed Consumption Provided by the Contractor and the current rates
charged to the Employer for Electricity Consumed. Such payable amount will be assessed for each month during the O&M.
Period in which the Actual Power Consumption exceeds the Guaranteed Power Consumption calculated on a “Kilowatt-Hour
Consumed per litre of Sewage” basis.
During Operation and Maintenance (O&M), damages payable by Contractor to Employer on reduction in Power Generation
from STP/WWTP shall be equal to the value of the Power Generation Deficiency, based on the Guaranteed Power Generation
provided by the Contractor for STP/WWTP and the current rates charged to the Employer for electricity consumed. Such
94
payable by Contractor will be assessed for each month during the O&M Period in which the actual power generation is less
than the guaranteed power generation calculated on a “Kilowatt-Hour generated per litre of sewage treated” basis.
After the Completion Test, the guarantees would come into effect for power generation, consumption and generation.
Condition-E:
Residual Handling & Disposal
The Plant Residuals shall conform to the following specifications:
Screenings
The screenings shall comprise of all particles of an effective size in excess of 5 mm and be “free of dripping water “i.e.
the screenings on collection does not contain any dripping water when disposed from the plant
Grit
The grit removed shall contain less than 3% organic matter on dry basis of an average particle size between of more
than 100 microns but less than 1000 microns and be free of dripping water
Excess Bio Solids (Sludge)
The excess Bio Solids (Sludge) produced shall contain approximately 20-22% of Solid Content Concentration with
VSS/TSS ratio of not less than 48%, for “spadeable” or “open body truck able” consistency for easy transportation and
disposal.
The Waste Water Treatment Residuals i.e. Screenings / Grit and Dewatered Bio Solids shall be handled and transported
by the Bidder in a nuisance free manner following environmental guidelines. If the performance of the Bidder is not found
satisfactory in respect of processing, handling and transportation of the sludge, the Employer shall have the liberty to
recover from Bidder two (2) times the cost incurred for handling and transportation of the residuals. The residuals shall
be disposed by the bidders as per the guidelines provided by the Employer
Screenings & Grit: Disposal to the Sanitary Land fill (the tipping charges shall be borne by the Contractor)
Dewatered Sludge: Ultimate Disposal of dewatered sludge shall be the responsibility of the Contractor. Sludge shall be
disposed within the battery limit of plant area.
95
Annexure ‘E’
Specifications for Sewage Related Jobs
Table of Contents
S.No. Chapters Page No.
1.0 General 95
2.0 Pipeline 99
3.0 RCC Sump 109
4.0 Sewage Treatment plant 112
5.0 Pumps for sewage pumping
Part I Non Clog Submersible pumps 121
Part II Specifications for 415 V induction motors 123
Part III Cabling and motor control panel 125
Part IV Non Return valves 126
Part V Delivery Pipes 127
Part VI Rating and Name Plates 128
-6.0 Electric Sub-Station 129
7.0 Specifications of Road 135
8.0 Suggested Brands of Equipment 136

96
97
Chapter 1
General:
The specifications for this project & various components thereof shall be as follows:
1.0 The specifications for various material to be used for the project shall confirm to BIS/IS/ISO
standards with uptodate amendments as given below:
BIS/BS/ISO CODE No.

S. No. Title
(YEAR)
1 IS 5 (2007) Colour for Ready Mixed Paints and Enamels
2 IS 210 (2009) Grey Iron Castings
3 IS 269 (1989) Specification for Ordinary Portland Cement (33 Grade)
Specification for Coarse and Fine Aggregates From Natural
4 IS 383 (1970)
Sources For Concrete
Mild Steel and Medium Tensile steel bars and hard steel wire for
5 IS 432-1 (1982) concrete Reinforcement part-01 Mild Steel And Medium Tensile
Steel Bars
Mild Steel and Medium Tanium Tensile Steel Bars and Hard Drawn
6 IS 432-2 (1982) Steel Wire for Concrete Reinforcement part-02 Hard Drawn Steel
Wire
7 IS 438 (2006) Aluminium power for explosive and pyrotechnic compositions
8 IS 455 (1989) Portland Slag Cement
9 IS 456 (2000) Plain and Reinforced Concrete
Code Of Practice For General Construction Of Plain And Reinforced
10 IS 457 (1957)
Concrete For Dams and Other Massive Structure
11 IS 458 (2003) Precast Concrete Pipes (With And Without Rein For Cement
12 IS 516 (1959) Method Of Tests For Strength OF Concrete
13 IS 779 (1994) Water Meters
14 IS 783 (1985) Code of Practice for Laying of Concrete Pipes
15 IS 875-1 (1987) Code of Practice for Design loads for Buildings and Structures
Code of Practice for Design loads for Buildings and Structures
16 IS 875-2 (1987)
Imposed Loads
Code of Practise for Design Loads for building and Structures Wind
17 IS 875-3 (1987)
Loads
18 IS 875-4 (1987) Code of Practice for Design Loads
19 IS 875-5 (1987) Code of Practice for Design Loads
20 IS 1199 (1959) Methods of sampling and analysis of concrete
21 IS 1239 Part 1 (2004) Steel Tubes, Tubulars And other Wrought Steel Fitting
22 IS 1239 Part 2 (2011) Steel Tubes, Tubulars And other Steel Fittings
23 IS 1343 (1980) Code of practice for Pre-stressed Concrete
24 IS 1489-1 (1991) specification for Portland -Pozzolana Cement
specification for Portland Pozzolana Cement, Part 2 (Calcined Clay
25 IS 1489-2 (1991)
Based)
26 IS 1538 (1993) Cast iron fittings for pressure pipes for water, Gas and sewage
27 IS 1786 (2008) High strength deformed steel bars and wires for concrete
28 IS 1834 (1984) Hot applied sealing compounds for joints in Concrete specification
29 IS 1834 (1984) Hot applied sealing compounds for joints in Concrete specification
30 IS 1865 (1991) Iron Castings with Spheroidal or nodular Graphite
31 IS 1893-1 (2002) Criteria for Earthquake Resistant Design of Structures
32 IS 1893-4 (2005) Criteria for Earthquake Resistant Design of Structures
33 IS 2386-1 (1963) Methods of test for aggregates for concrete
Methods of test for aggregates for concrete Part 4 (Mechanical
36 IS 2386-4 (1963)
properties)
98
Method Of Tests For Polyethylene moulding materials and

37 IS 2530 (1963)
polyethylene compounds
Method Of Tests For Soils, Part 1( Preparation of Dry soil samples
38 IS 2720-1 (1983)
for various test )
Method Of Tests For Soils, Part 7 (Determination of Water Content-
39 IS 2720-7 (1980)
Dry density relation using light compaction )
Method Of Tests For Soils, Part 8 (Determination of Water Content-
40 IS 2720-8 (1983)
Dry density relation using heavy compaction )
Method Of Tests For Soils, Part XV (Determination of Consolidation
41 IS 2720-15 (1965)
Properties)
Code Of Practice Concrete Structure For The Storage of Liquids,
42 IS 3370-1 (2009)
Part 1 (General Requirements)
43 IS 3370-2 (2009)
Part 2 (Reinforced Concrete Structures )
44 IS 3370-3 (1967)
Part 3 (Pre stressed Concrete Structures )
45 IS 3370-4 (1967)
Part 4 (design tables )
46 IS 3389 (2001) Steel pipe for water and sewerage
47 IS 3597 (1998) Concrete pipe (methods of test)
Specification for polarized fuel Ash, part 1 for use as pozzolana in
48 IS 3812-1 (2003)
cement (Cement Mortar and Concrete )
specification for pulverized Fuel Ash Part 2 For use as Admixture in
49 IS 3812-2 (2033)
Cement Mortar and Concrete)
50 IS 3913 (2005) Suspended sediment load samplers
51 IS 3917 (2003) Scoop Type Bed Material Samplers
ISO 4064 -1 (2014) Fourth Water meters for cold potable water and hot water
52
Edition Part -1: Matrological and technical requirements
53
Edition Part -2:Test methods
54
Edition Part -3:Test Report format
Measurem ent of water flow in fully charged closed conduits - Meters
ISO 4064 -1 (2005 ) Third
55 for cod potable water and hot water
Edition
Part :1 Specifications
ISO 4064 -2 (2014) Third
Edition
Part 2 : Installation requirements
ISO 4064 -3 (2014) Third
Edition
Part 3: Test methods and equipment
Pipes and fittings made of un plasticized polyvinyl chloride (PVC-U)
58 ISO 4422-4 for Water Supply
Part -4 Valves and ancillary equipm ent
General – Plastic Piping Systems for Polyethylene (PE) Pipes and
59 BS ISO 4427- Part 1 (2007)
Fittings for Water Supply
Pipes - Plastic Piping Systems for Polyethylene (PE) Pipes and
60 ISO 4427- Part 2 (2007)
Fittings - Plastic Piping Systems for Polyethylene (PE) Pipes and
61 ISO 4427- Part 3 (2007)
Fitness for the purpose of the system - Plastic Piping Systems for
62 ISO 4427- Part 5 (2007)
Polyethylene (PE) Pipes and Fittings for Water Supply
Methods for Measurem ent of Suspended Sediment in open
63 IS 4890 (1968)
channels
64 IS 4905 (1968) Methods for random sampling
65 IS 4926 (2003) Code of Practise Ready Mixed Concrete
66 IS 4984 (1995) High Density Polyethylene Pipe For Water Supply
67 IS 5120 (1977) Technical Requirements for roto dynamic Special Purpose
Criteria for design of Anchor Block for penstock with joints (First
68 IS 5330 (1984)
Revision)
69 IS 5382 (1985) Rubber Sealing Rings for Gas Mains, Water Mains and Sewers
99
70 IS 5477-1 (1999) Fixing the capacities of Reservoirs methods ,part 1

71 IS 5477-2 (1994) Fixing the capacities of Reservoirs methods ,part 2
72 IS 5477-3 (2002) Methods for fixing the capacities of Reservoirs methods ,part 3
73 IS 5477-4 (1971) Methods for fixing the capacities of Reservoirs methods ,part 4
74 IS 5600 (2002) Sewage and Drainage
code of Practice for water supply and drainage in high altitudes and
75 IS 6295 (1986)
/or sub –zero temperature regions
76 IS 6518 (1992) Code of practice for control of Sediment in reservoirs
77 IS 7328 (1992) High Density Polyethylene Materials for Moulding and Extrusion
78 IS 7357 (1974) Code of Practice for Structural design of surge tanks
79 IS 7634-1 (1975) Code of Practise for plastic pipes work for potable water supplies
Plastics Pipe Selection Handling Storage and Installation for
80 IS 7634-2 (2012)
Potable Water supplied
Plastics Pipe Selection Handling Storage and Installation for
81 IS 7634-3 (2003)
Potable Water supplies
82 IS 8008-1 (2003) Code of practice for control of sediment in reservoirs
IS 8062-1 (1976) Code of Practice for Cathodic protection of steel Structure :General
83
principles
IS 8062-2 (1976) Code of Practice for Cathodic protection of steel Structure :
84
Underground pipelines
85 IS 8062-3 (1977) Code of Practice for Cathodic protection of steel Structure
86 IS 8062-4 (1979) Code of Practice for Cathodic protection of steel Structure
87 IS 8112 (1989) Specification for 43 grade ordinary Portland cement
Centrifugally cast ductile iron Pressure Pipes for water, Gas and
88 IS 8329 (2000)
Sewage
Code for Acceptance test for centrifugal, maxed flow and axial
89 IS 9137 (1978)
pumps class c
90 IS 9523 (2000) Ductile Iron Fittings for Pressure Pipes for water, Gas and Sewage
Code of practice for Provision and Maintenance of water supplies
91 IS 9668 (1990)
and fire fighting
Determination of overall Migration of Constituents of Plastics
92 IS 9845 (1998)
Materials and articles intended to come in contract with foodstuffs
Positive List of constituents of polyethylene in Contact with
93 IS 10141 (2001)
Foodstuffs, Pharmaceuticals and Drinking Water
Polyethylene for its safe use in Contact with Foodstuffs
94 IS 10146 (1982)
Pharmaceuticals and Drinking Water
95 IS 10221 (2008) Casting and wrapping of underground mild steel pipelines
Specification for one part gun- grade polysulphide based joints
96 IS 11433-1 (1985)
sealants
Speciation for one part gun- grade polysulphide based joints
97 IS 11433-2 (1986)
sealants
98 IS 11682 (1985) Criteria for Design for Overhead Water Tanks
Recommendations for cement mortar lining for cast iron mild steel
99 IS 11906 (1986)
and ductile iron pipes and fittings for Transportation of water
Plastics piping systems for Water Supply and for Drainage and
100 EN 12201-2 (2011)
Sewerage under pressure- Polyethylene (PE)-Part 2 : Pipes
Plastics piping systems for Water Supply Polyethylene (PE) Part 3:
101 BS EN 12201 -3:2003
Fittings
102 IS 12330 (1988) Specification for sulphate resisting Portland
103 IS 12235-1 TO 19 (2004) Thermoplastics Pipes and Fittings
104 IS 12269 (1987) 53 Grade Ordinary Portland cement
105 IS 12288 (1987) Code of Practise for use and Laying of Ductile iron Pipes
106 IS 12592 (2002) Precast Concrete Manhole Cover And Frame
Ductile detailing of reinforcem ent concrete structures subjected to
107 IS 13920:1993
seismic forces
108 IS 14333 (1996) High Density Polyethylene Pipe For Sewerage
109 IS 14846 (2000) Sluice Valve For Works Purposes
110 IS 15388 (2003) Specifications for Silica Fume
100
Structured -Wall Plastics Pipe Systems For pressure drainage and

111 IS 16098-1 (2013)
sewerage
Structured -Wall Plastics Pipe Systems For Non-Drainage And
112 IS 16098-2 (2013)
sewerage
Structured -Wall Plastics Pipe Systems For Non-Drainage And
113 IS 16098 PART 2 (2013)
sewerage
NOTE:- Any other BIS/IS/ISO standards as may be required will also be applicable. Quality assurance program of
the manufacturer shall have to be enclosed with the detailed design and drawings.
2.0 The other part of the specifications for various components of the project shall be as per
provisions of clauses and sub clauses of chapters of Manual on Sewerage and Sewage
Treatment (Second Edition), CPHEEO Ministry of Urban Development Govt. of India
Design of Sewer Chapter 3

Sewer Appurtenances Chapter 4
Construction of Sewers Chapter 7
Maintenance of Sewerage System Chapter 8
Sewage and storm water pumping stations Chapter 9
Basic Design Considerations Chapter 10
Pre-treatment Screening and Grit Removal Chapter 11
Sedimentation Chapter 12
Aerobic Suspended Growth system Chapter 13
Aerobic attached growth system Chapter 14
Sludge Thickening, Dewatering, Digestion and Disposal Chapter 17
Sludge Pumping Chapter 18
Tertiary treatment of sewage for reuse Chapter 19
Effluent disposal and utilisation Chapter 20
Treatment plant operation and maintenance Chapter 23
Plant Control Laboratory Chapter 24
Disclaimer : Any specifications not covered above shall be as per best Engineering practice
or as directed by Engineer In Charge. In the event of any disparity between the
written specifications and BIS/IS/ISO provisions, the provisions in BIS/IS/ISO
shall prevail.
The item wise specifications to be followed by the Contractor are given in the subsequent Chapters.
101
Chapter 2
Providing, Laying and Jointing of Pipelines
1.0 Laying of Pipe Line

1.1. Excavation for Pipe Line Trenches/ Horizontal drilling
The pipe shall be laid by horizontal drilling. However where it is not possible open excavation will have to
be carried out. Tendered rate is supposed to cover cost of all such means i.e, either drilling or excavation
(soil, rock) by manual, mechanical or blasting.
1.2. Site Clearance
The pipe line alignment shall be cleared of all bushes, shrubs, roots, grass, weeds and if required trees,
coming in the alignment of pipe line in the trench width portion. The rates for excavation shall cover all
such site clearance work and no extra payment will be allowed on this account.
1.3. Alignment marking
After the work site is cleared as above, pipe line alignment with required trench width shall be marked on
the ground with apex points, curves etc, as shown on the drawings or as directed by the Engineer-in-
Charge in charge for the stretch where the work is to be started. The contractor shall provide all labour,
survey instruments, and materials such as strings, pegs, nails, bamboos, stones, mortar, concrete etc.
required for setting out and establishment of bench marks. The contractor shall be responsible for the
maintenance of bench marks and other marks and stakes as long as they are required for the work in the
opinion of the Engineer-in-Charge.
1.4. Working survey
Working survey of the pipeline alignment shall be carried out by the contractor before start of the
excavation work. The contractor shall provide all the instruments such as levelling instruments, steel
tape, ranging rods, strings, pegs etc. for carrying out the survey. Based on the working survey, the
alignments, L-section (depth of laying), grade, and location of manholes and inspection chambers shall
be finalized and got approved from the Engineer-in-charge.
1.5. Use of Machinery:
All excavations shall be carried out by Mechanical Equipment/Machinery unless, in the opinion of the
Engineer-in-Charge, the work involved and time schedule permit manual excavation.
1.6 Trench Width and Depth:
All buried pipelines shall be minimum 1 metre +/- 0.2 metre below ground level to maintain proper grade
unless other depths are approved by the engineer in charge. The trench width for respective pipe
diameters permissible as required under respective IS code for Pipeline laying and installation.
The trench width shall be constant throughout the trench depth, which will provide a clearance of about
0.30 m on either side of the pipe line.
The contractor may, for the facility of work or similar other reasons, excavate and also backfill later, if so
approved by the Engineer-in-Charges, at his own cost, outside the allowable trench width specified
above. Should any excavation be taken below the specified trench bottom, contractor shall fill it up to
required level, at his own cost, with the same material available at the trench bottom including watering
and compaction.
The excavation shall be taken down to such depths as shown in drawings. Excavation for extra depth
equal to the thickness of proposed pipe bedding shall be done below pipe soffit level for providing
bedding below pipe line wherever bedding is required. The trench bottom shall be excavated to proper
grade as shown on drawings. The contractor shall provide site rails and levelling instruments required for
checking the grade during excavation, bottom bedding and pipe laying Projections in rock excavation
shall be removed by chipping.
The contractor shall carryout extra excavation at the pipeline joints to be welded in the trench, as
required (minimum 0.6 m deep and 0.9 m lengthwise, all around the pipe), for facilitating proper welding of
the bottom joint from outside. The work of trench excavation should be commensurate with laying and
jointing of the pipe line. It should not be dug in advance for a length greater than 500 m ahead of work of
laying and jointing of pipeline unless otherwise permitted by the Engineer-in-Charge.
The minimum cover on pipe is to be maintained 1 metre+/- 0.2 metre. However the cover on pipe may be
modified to suitgradients and site conditions as per direction of Engineer-in-Charge.
102
1.7 Barricading and Guarding:

To protect persons from injury and to avoid damage to property, adequate barricades, construction signs,
red lanterns and guards as required shall be placed and maintained
During the progress of work, till filling of the trenches after pipes are laid and jointed. The lighting,
barricading, guarding of the trenches and the maintenance of watchman shall be done by the contractor
at his cost.
All precautions shall be taken during excavation and laying operation to guard against possible damage
to any existing structures, underground cables, pipe lines of water, gas, sewage etc. Any damage done to
such properties will have to be repaired / rectified by the contractor at his cost. The Contractor has to
ensure the following:
• Safety protections as mentioned above have to be incorporated in the work process.
• Hindrances to the public have to be minimized.
• The trench must not be eroded before the pipes are laid.
• The trench must not be filled with water when the pipes are laid.
• The trench must not be refilled before laying of the pipes.
The bed for the laying of the pipes has to be prepared according to the L-Section immediately before
laying of the pipes.
1.8. Re-use of Surface Material
All surface materials, which in the opinion of the Engineer-in-Charge, suitable for reuse in restoring the
surface shall be kept separate from the general excavation material, as directed by the Engineer-in-
Charge.
1.9. Stacking of Excavated Material
All excavated materials shall be stacked in such a manner that it does not endanger the work and avoids
obstructing foot paths and roads. Hydrants under pressure, surface boxes, fire and other utility controls
shall be left unobstructed and accessible until the work is completed. Gutters shall be kept clean or other
necessary provisions made for street drainage and natural water courses shall not be obstructed. All the
excavated material shall be the property of the Employer and shall be stacked or disposed of as directed
by the Engineer-in-Charge.
1.10. Maintenance of Traffic
The work of excavation and pipe laying shall be carried in such a manner that it causes the least
interruption to traffic and the road / street may be closed in such a manner that it causes the least
interruption to the traffic. Where it is necessary for traffic to cross open trenches, suitable bridging
arrangement shall be provided. When the street is closed for traffic, suitable signs indicating that street is
closed shall be placed and necessary detour signs for proper maintenance of traffic shall be provided.
1.11. Structure Protection
Temporary support, adequate protection and maintenance of all underground and surface structures,
drains, sewers and other obstructions encountered in the progress of work shall be furnished under the
direction of the Engineer-in-Charge. The structures which have been disturbed shall be restored upon
completion of work.
1.12. Protection of Property
Trees, shrubbery fences, poles and all other property shall be protected unless their removal is allowed
by the Engineer-in-Charge. When it is necessary to cut roots and tree branches, such cutting shall be
done under the supervision and direction of the Engineer-in-Charge.
1.13. Avoidance of Existing Services
As far as possible, the pipeline shall be laid below existing services, such as water and gas pipes,
cables, cable ducts and drains but not below sewers. Excavation of the trenches shall be carried out to
the required depth accordingly. If it is unavoidable, the pipeline shall be suitably protected and lesser
trench depth in such cases can be allowed. A minimum clearance of 150 mm shall be provided between
the pipeline and such other services. When thrust or auger boring is proposed for laying pipeline across
roads, railway or other utilities, larger clearance as required shall be provided. Adequate arrangements
shall be made to protect and support the other services during excavation and pipe laying operations. The
work shall be so carried out as not to obstruct access to the other services for inspection, repair and
replacement. When such utilities are met with during excavation, the authority concerned shall be
intimated and arrangements made to support the utilities in consultation with them.
1.14. Bailing out of Water/Open and Close Timbering
1.14.1 Bailing out of Water
During the excavation if subsoil water is met with, contractor shall provide necessary equipment and
labour for dewatering the trenches. If pumping out subsoil water is found necessary, contractor shall
provide sufficient number of pumps for the same. The tendered rate shall cover all costs for bailing out of
103
water including hire charges of pumps, cost of diesel and labour etc. and hence, no extra payment shall
be allowed.
1.14.2 Open and Close Timbering

Contractor shall provide necessary materials labour& equipment’s for open timbering/close timbering/
steel or any other protection work required to be done during excavation. In case of open areas, shafts,
wells, cesspits, manhole including strutting, shoring and packing cavities(wherever required). The tender
rate shall cover all cost of materials, labour and equipments required and hence no extra payment shall
be allowed even timbering material is left permanent at site.
1.15. Disposal of loose boulders etc.
All loose boulders, Semidetached rocks, (along with earthy stuff which might move therewith), not directly
in the excavation but close to the area to be excavated, as to be liable, in the opinion of the Engineer-in-
Charge, to fall or otherwise endanger the workman equipment, or the work etc. shall be stripped off and
removed away from the area of the excavation. The method used shall be such as not to shatter or
render unstable or unsafe the portion which was originally sound and safe. The tendered rate is
supposed to cover this job and no extra payment will be allowed on this account.
1.16. Disposal of Excavated Material
All the excavated surplus material shall be disposed of on low lying Government land or as directed by
the Engineer-in-charge.
1.17. Moorum / Sand Bedding below Pipeline
In case of hard rock and black cotton soil, before lowering of the pipes in trenches, a layer of selected
moorum, available from excavated material under the same contract shall be provided below the pipe line
to act as bedding. The bedding shall be compacted properly including required watering and the
thickness of well compacted layer shall not be less than 150 mm. The bedding shall be provided for full
trench width with proper grade as shown on drawings.
2.0 Refilling the trenches
2.1. Use of selected excavated material
Filling of excavated material in trenches shall be commenced as soon as the joints of pipes and specials
have been tested and passed. The backfilling material shall be properly consolidated by watering and
ramming, taking due care that no damage is caused to the pipes and the outer coating.
Selected surplus spoils from excavated material shall be used as backfill. Fill material shall be free from
clods, salts, sulphate, organic or other foreign material. All clods of earth shall be broken or removed.
Where excavated material is mostly rock, the boulders shall be broken into pieces not larger than 150
mm size, mixed with properly graded fine material consisting of moorum or earth to fill up the voids and
the mixture used for filling.
2.2. Filling zones
For the purpose of back-filling, the depth of the trench shall be considered as divided in to the following
three zones from the bottom of the trench to its top:
Zone A:From the bottom of the Back-filling by hand with selected approved material available from
pipe (top of bedding) to the level of excavation, placed in layers of 150 mm and compacted by tamping.
the centre line of the pipe The back-filling material shall be deposited in the trench for its full
width on each side of the pipe, specials and appurtenances
simultaneously. Special care shall be taken to avoid damage of the
pipe and the coating or moving of the pipe.
Zone B:From the level of the Back-filling and compaction shall be done by hand or approved
centre line of the pipe to a level mechanical methods in layers of 150 mm; special care shall be
300 mm above the top of the pipe taken to avoid damage of the pipe and the coating or moving of the
pipe.
Zone C: Back-filling shall be done by mechanical methods in 150 mm.
2.3. All excavations shall be backfilled to the level of the original ground surfaces unless otherwise shown on
the drawings or ordered by the Engineer-in-Charge, and in accordance with the requirements of the
specification. The material used for backfill, the amount thereof, and the manner of depositing and
compacting shall be subject to the approval of the Engineer-in-Charge, but the Contractor will be held
responsible for any displacement of pipe or other structures, any damage to their surfaces, or any
instability of pipes and structures caused by improper depositing of backfill materials.
104
The back filled layers shall be wetted and compacted to a density of not less than 90 percent of the
maximum dry density at optimum moisture content of the surrounding material. Any deficiency in
the quantity of material for backfilling the trenches shall be supplied by the Contractor at his expense.
The Contractor shall at his own expense make good any settlement of the trench backfill occurring after
backfilling and until the expiry of the defects liability period.
On completion of pressure and leakage tests exposed joints shall be covered with approved selected
backfill placed above the top of the pipe and joints in accordance with the requirements of the above
specifications. The Contractor shall not use backfilling for disposal as refuse or unsuitable soil.
2.4. Fillings of the trench excavated in rock
In case of excavation of trenches in rock, the filling up to a level of 300 mm above the top of the pipe
shall be done with fine materials, such as soft soil, moorum etc. The filling up of the level of the centre
line of the pipe shall be done by hand compaction in layers not exceeding 150 mm, whereas the filing
above the centre line of the pipe shall be done by hand compaction or mechanical means in layers not
exceeding 150 mm. The filling from a level of 300 mm above the top of the pipe to the top of the trench
shall be done by mechanical methods with broken rock filing of size not exceeding 150 mm mixed with
fine material as available to fill up the voids.
2.5. Consolidation
The consolidation of the filled material shall be done to attain 95 % proctor density. The density of the
filled and compacted material shall be tested regularly and record maintained accordingly.
3.0 Ductile Iron PIPES (Pipes shall be procured only from the Manufacturers.)
3.1Supply, laying and jointing of DI Pipesand fittings.
The ductile iron pipe to be supplied and laid shall be DI K-7/K-9 as per IS 8329-2000, fittings for
the pipe shall conform to the provisions of IS 5382-1985, DI fittings confirming to IS 9523:1980
complete.
3.2 The laying of pipe shall be as per IS 12288:1987 with up to date amendments.
3.3The manufacturer and their associates(if any) should have the facility to carry out the internal coating / lining
and external coating / painting at factory for pipes and specials confirming to IS 11906:1986.
3.4 The DI pipe manufacturer should have valid BIS license from last 5 years (or valid BIS license from last 2
years with an experience of manufacturing and supplying at least 500 kms of various diameters of DI
pipe to any State/Central Govt. / board/organization of repute in last 3 years) and the pipes should be
manufactured conforming to IS 8329-2000 specification and further amendment to the code as on date
and duty ISI marked.
3.5 The DI pipe manufacturer should have in-house facility for carry out the following test for size DN 80-
DN1000:-
a) C -value determination arrangement
b) Type test for leak tightness as per ISO 2531:2009/BS EN 545/IS 8329:200.
3.6 DI pipe manufacturer should have the ISO 9001:2008 & ISO 2531:2009 certification for manufacture of
DI pipe.
3.7 A certificate for having supplied DI pipe of size proposed in the project for quantity 1/3 of the TENDER
requirement during last 3 years to any state/central Govt. department /board to be submitted by pipe
manufacturer.
The manufacturer should be able to demonstrate the conformity of the product to the requirement by
controlling the manufacturing process and by carrying out the various tests as specified in IS wherever
possible, statistical sampling techniques should be used to control the process so that the product is
produced within the specified limit. The successful bidder is required to submit the Quality Assurance
Program (QAP) of the manufacturer along with the documentary evidence of the production
capacity, BIS & ISO Certification as mentioned above for obtaining the approval of Employer &
Engineer-in-charge before production of pipes.
3.8 Each pipe or Fittings shall be marked with the standard mark, Lot/ Batch No., Period of
Manufacturing and as per the employer/purchasers requirement.
4.0 Supply, laying and jointing of Double Wall (Non-Smooth External Surface) Corrugated (DWC) wall
& Smooth Internal wall) Polyethylene Class SN 8 /High Density Poly Ethylene (HDPE) Pipe PN 2.5
PE 100 for Piping System for Non-Pressure underground Sewerage & Drainage Applications.
4.1 Scope
105
The specification for manufacturing, supplying, transportation, handling, stacking, installation, jointing, and
testing of Piping System for non-pressure underground Sewerage & Drainage Applications shall be as
below,
4.2 Applicable Codes
The manufacturing, testing at factory, supplying, transportation, handling, stacking, installation, jointing,
and testing at sites shall comply with all currently applicable National statutes, standards & codes. If
requirements of these specifications are at variance with any other standards, this particular document
shall be governed by the proceedings of:
IS16098 (Part-1) : Structured Wall Plastics piping Systems for non-pressure drainage and
2013 sewerage- Specification
Part 1: Pipes and fittings with smooth external surface, Type A
IS16098(Part-2) : Structured Wall Plastics piping Systems for non-pressure drainage and
2013 sewerage- Specification
Part 2: Pipes and fittings with non-smooth external surface, Type B
ISO 9001: 2008 Quality Management Systems
The testing, supplying, laying, jointing and testing at work sites of DWC/HDPE pipes shall be as per
standards and Codes. If requirements of this Specification conflict with the requirements of the standards
/ Codes, this Specification shall govern.
Code No. Title/Specification
IS 14333 High Density Polyethylene Pipes for sewerage

IS 2530 Methods of test for polyethylene moulding materials and polyethylene compounds DI K7
Pipes, Joints and Fittings for use for Potable Water Supply
IS 5382 Rubber sealing rings for gas mains, water mains and sewers.
IS 4905 Methods for random sampling
IS 7328 High density polyethylene materials for moulding and extrusion
IS 7634 Laying & Jointing of Polyethylene (PE) Pipes
Other Indian standards which are integral part of above standard as normative references form a
significant portion of this specification document.
4.3 Inspection
The Contractor shall be responsible for the performance tests at the Manufacturer’s place in presence of
the Engineer-in-charge or the authorized representative(s) of the client and/or by the authorized
representative of PDMC, AMRUT.
The Pipe Manufacturer shall produce all necessary test certificates related to relevant Material
Characteristics of PE Material in Granular Form for each lot of Pipes as specified in the IS code. At the
time of inspection, before supply of the designated lot to the contractor, such certificates from the
manufacturer, duly supported by the purchaser’s invoices shall be made available to the employer with
proper endorsement from the inspecting agency.
The employer reserves the right to inspect the Pipe Manufacturer’s unit if required to evaluate the capacity/
capability/ Quality Assurance before extending their clearance to the contractor towards procurement of
pipes.
The Employer reserves the right to test Pipe samples of Pipe & Fittings picked up at random from project
site stack yard/storage for performance test at any Govt. authorized National Testing Laboratories or
NABL Accredited laboratory.
4.4 Transportation
While loading the pipes onto the truck, care should be taken that the coupler- end should be arranged
alternatively in the corresponding layers so as to avoid the damage to the coupler/ socket ends.
106
4.5 Handling
Following Recommendations shall be followed while handling the pipes:
 Adherence to National Safety requirements
 Pipes to be smoothly lowered to the ground
 Pipes should not be dragged against the ground to avoid the damages to the Coupler/pipes.
 900mm and larger diameter pipes are carried with Slings at two points spaced approximately at 3
Meters apart.
 For smaller diameters (450 mm to 900 mm, both exclusive) one lift point shall besufficient& can be
handled either manually or mechanically.
 For diameters smaller than or equal to450 mm, manual labour can be used.
 Do not use a loading Boom or Fork Lift directly on or inside pipe.
4.6 Pipe Storage at Site

 Stockpiling shall be done temporarily on a Flat Clear Area as per IS 16098 (Part- 2).
 For avoiding collapse of Stacks, use Wooden Posts or Blocks
 Stacking shall not be higher than 2.5 Meters
 While stacking, alternate the socket/coupler ends at each row of stacked pipes.
5.0 Lowering, Laying & jointing of Pipes

The width of a Sewer Trench depends on the soil condition, type of side protection needed and the
working space required at the bottom of Trench for smooth installations. The Minimum Trench Width is
specified as per Table below:
**
Indicative Trench Widths
Pipe Diameter (mm) Trench Width (M)
75-200 0.6
250 0.7
300 0.8
400 0.9
600 1.2
800 1.3
1000 1.8
The pipe segment between two manholes shall be laid approximately in straight line without any vertical
undulations (at prescribed Gradient) only in case of curve if found necessary. The piping system shall rest
on the carefully prepared bedding portion of the Backfill Envelope as per IS-16098 (Part- 2) (Annexure –
A) and at appropriate jointing locations the trenches shall be excavated deeper to accommodate the
bulges of coupler-spigot joints. However, special care shall be ensured as mentioned below:-
 Excavation of trenches shall be carried out in accordance with the approved drawing & specifications
and as directed by the engineer-in-charge as well.
 The piping system shall be laid and jointed in true to gradient with the help of sight rails and boning
rods as detailed in Manual on Sewerage and sewerage treatment CPHEEO, MoUD, GoI, New Delhi.
The levels need be checked with calibrated modern Levelling Instrument. Specific care shall be taken
to prevent entry of sand / mud /slush/ any other foreign material etc into the system during the
installation operation.
A minimum cover of 600 mm should be maintained or as directed by the Engineer-in-Charge.
The bedding area (ref. Annexure A) is an essential portion of Back fill Envelope and shall be constructed
with proper bedding material as computed in accordance with appropriate national code of practice for
structural bedding design mentioned in the list of normative references under IS 16098-2.The bedding
shall be laid to specified thickness and gradient with proper manual compaction of the aggregate.Indicative
installation details with suggestive ‘Backfill Envelop’ have been shown in Annexure Aas per IS-16098
(Part- 2).
107
The moulded on-line coupler (or separate coupler integrated to the pipe in case of lower sizes) will have a
suitable internal surface to push-fit the said end over the spigot end of the next pipe. On first valley of the
corrugation of said spigot end (destined to receive the pushed coupler), the sealing rubber ring of standard
quality shall be placed so that the coupler end of the pipe smoothly but tightly slides over the sealing ring
for making an absolute watertight joint. Similar system is also used for fabricated accessories or moulded
fittings requiredReducer end caps for the purpose of installation of the system related to
drainage/sewerage.
For quality connections following steps are to be ensured, failing which the performance aspects are to be
severely compromised:-
 The non-coupler (socket) end needs to be thoroughly cleared and shall be free from any foreign
material
 Clean and lubricate the coupler end of the pipe, if required.
 Lubricate the exposed Gasket in the same manner, if required.
 Keep the non-coupler end free from dirt, backfill material, and foreign matter so that the joint integrity
is not compromised.
 Push the coupler onto the non-coupler end and align properly. Always push coupler end onto non-
coupler end.
For smaller diameter pipes simple manual insertion shall be sufficient. It should be ensured that the
coupler end is adequately ‘homed’ on non-coupler end to ensure installation and tight joining seal.
Therefore prior to insertion always place a ‘Homing Mark’ on appropriate corrugation of the ‘Non-Coupler
End’.
6.0 Construction of backfill envelope and final backfilling of the trenches
DWC Piping System with well compacted Backfill Envelope along with the bottom and sides of trench
(native soil) work together to support soil overburden and superimposed (traffic) loads. The carefully
constructed Backfill Envelop has three distinct but non-isolated stages (ref. Annexure A of IS-16098 Part-
2).The construction need to be done stage by stage as per the sequence stated below:
 Bedding portion
 Up to Haunch level
 Remaining portion
The material for backfill envelop shall be in accordance with the structural design of flexible buried conduit
as per relevant National code in meticulous consultation with ISO 21138-1 &3 :2007 and all other referred
International Codes such as BS EN 1295-1 that forms an integral part of the said ISO Specifications. It can
be the same material that were removed in the course of excavation or it can be fine sand/course
sand/gravel / moorum /other form of course / fine aggregates depending on the effected Design Load
[Overburden + Superimposed (Live) load]. However, in no circumstances, the flexible pipe should be
embedded in cement concrete (un- reinforced or reinforced) which invariably induces undesired rigidity in
the system.The Manufacturer may also be consulted to provide for the necessary module for the Structural
Design of the ‘Backfill Envelope’.
 The remaining portion of backfilling which do not contribute to the structural integrity of the system
may be the materials that were removed in the course of excavation or any other foreign material as
may be required to suit the particular site condition. These materials shall consist of at least clean
earth and shall be free from large clod or stone above 75 mm, ashes, refuse and other injurious
materials.
 After completion of bedding portion of the Backfill envelop and subsequent lying of pipes, etc, first the
haunch portion & then upper portion of Backfill Envelope shall be constructed as per design around
the pipe. Voids must be eliminated by knifing under and around pipe or by some other indigenous
tools.
 The compaction, by hand rammers or compactors with necessary watering to a possible maximum
level of proctor density shall be ensured.
 Remaining portion of the Construction of ‘Backfill Envelope’ (above the Bedding Portion) &
subsequent final Backfilling of the Trench shall start only after ensuring the water tightness test of
joints for the concerned sewer segments. However, partial filling may be done keeping the joints
open.
108
 Precautions shall be taken against floatation (if at all necessary) as per the specified methodology
and the minimum required cover.
7.0 Continuity Test /Hydraulic Testing
Since the entire application pertains to Non-pressure (gravity flow) domain, on-field pressure testing of the
installed system is not necessary. As per the relevant IS Code, each of the supplied pipe assembly need
to be pressure tested at manufacturer’s end for ensuring its leakage proof status as per the IS 16098 (Part
2):2013. However, for on-field acceptability, a segment wise continuity test shall be performed by the
contractor in the same methodology as depicted in the CPHEEO, MoUD, GoI Manual on Sewerage and
Sewage Treatment to the fullest satisfaction of the Employer/Department/PDMC, AMRUT. The contractor
shall arrange the water at his own cost for testing and other requirements.
Notwithstanding the satisfactory completion of the continuity test, if there is any discernible leakage of
water from any pipe or joint, the Contractor shall, at his own cost, replace/repair the pipe or re-make the
joint and repeat the hydraulic test again.
8.0 Flow measuring devices:
Electromagnetic Flow Meter as per ISO 6817-1992 of appropriate size shall be provided along with 8 hour
Battery back-up, at inlet and outlet of the Raw water and Clear water pipeline and Feeder pipeline outlet at
RCC Sumpwells; to check losses and measure the quantity of water. Reading display of all the Flow
meters, alongwith data logging instruments should be made available at single point, wherever decided by
All the Electromagnetic Flow meters shall have the same make and salient features as under.
Coil housing of the Electromagnetic flow meters of fully welded SS-316 and Flow-tube lining of PTFE /
EPDM / Neoprene.
Recommended make:Krohne-Marshall / Yokogawa / Emerson- Rosemount.
9.0 Technical Qualifications of Manufacturer of DWC pipes:
9.1 The Pipe manufacturer should have an annual installed production capacity of quantity equal to this TENDER. The
manufacturer should have manufactured and suppliedpipesto any state/central Govt. department /board
having minimum DN/ID 150mm or above, a minimum length of 500 Km.; out of which atleast 10% length
(50Km.) should be of minimum DN/ID 250mm or above.
9.2 The manufacture should have valid BIS License as per IS 16098:2013 Part-2 / IS 14333:1996 and
accreditation of ISO 9001: 2008/2015 for Manufacture and supply of DWC / Structured wall PE Pipe and
fittings.
9.3 The manufacturer should be able to demonstrate the conformity of the product to the requirement by
controlling the manufacturing process and by carrying out the various tests as specified in IS wherever
possible, statistical sampling techniques should be used to control the process so that the product is
produced within the specified limit. The successful bidder is required to submit the Quality Assurance
Program (QAP) of the manufacturer along with the documentary evidence of the production
capacity, Valid BIS & ISO Certification as mentioned above for obtaining the approval of
Employer & Engineer-in-charge before production of pipes.
10.0 DWC Pipe Manufacturer In-House Facility for Testing:

10.1 The manufacturer should have required Plant, machinery and equipment for size DN/ID 150mm or
above for the following vital test:
 Ring Flexibility Test,
 Ring Stiffness Test,
 Creep Ratio Test,
 Water Tightness Test,
 Tensile Strength Test,
 Melt Flow Index Test,
 Impact Test,
 Environmental Stress Cracking Resistance Test,
 Oxidation Induction Time Test Etc.
10.2If the manufacturer does not have required Plant, machinery and equipment for size DN/ID 150mm or
above for the above vital test, the required tests to be carried out in any National Test House or
NABL accredited Test Laboratory. The cost of such tests shall be borne by the manufacturer.
Manufacturing and as per the employer/purchasers requirement.
109
11.0 Supply, Laying, Jointing, Installation, Testing and Commissioning of pipes

a. Supplying, laying, jointing, testing and commissioning of pipes shall conform to relevant IS codes, as
applicable.
b. The alignment of pipelines shown in drawings of the TENDER documents is only indicative and the exact
alignment will be as per approved drawings and/or as directed by the Engineer-in-charge or his
representative.
c. The HDPE/DWC/DI/RCC Pipes shall be laid in accordance with the latest BIS/EN/ISO specifications.
12.0 Field Hydraulic Test

a. The Sectional Hydraulic Test shall be carried out after the pipeline section to be tested has been laid
jointed and backfilled to a depth sufficient to prevent floatation
b. Each length of the pipeline to be tested shall be capped or blanked off at each end and securely strutted or
restrained to withstand the forces which will be exerted when the test pressure is applied.
c. The proper method of filling the pipeline with water shall be used. The length under test shall be filled
making certain that all air is displaced through an air valve or any other appropriate mechanism. The test
length shall then remain under constant moderate pressure as per testing method given in the IS 7634.
d. As per IS code water required to built-up allowable drop in pressure during test will be treated as a make-
up water.
e. The maximum allowable test pressure shall be as per CPHEEO manual and or IS codes specified.
f. Notwithstanding the satisfactory completion of the hydraulic test, if there is any discernible leakage of
water from any pipe or joint, the Contractor shall, at his own cost, replace the pipe, repair the pipe or re-
make the joint and repeat the hydraulic test at his risk and cost including the cost of water.
2
g. Test pressures are to be measured in kg/cm at the centre of the blank flange situated at the lowest end of
the pipeline under test. Unless otherwise specified the test pressure shall be as stated in Clause 12(f).
13. Supply, Laying & Jointing of RCC Pipes

13.1 The Pipe manufacturer should have an annual installed production capacity of quantity equal to this
TENDER. The manufacturer should have manufactured and supplied pipes to any state/central Govt.
department /board quantity equal to this TENDER in last 3 years.
13.2 The manufacture should have valid BIS License as per IS 458:2003 and accreditation of ISO 9001:
2008/2015 for Manufacture and supply of RCC Pipes.
13.3 The manufacturer should have manufactured and supplied pipes quantity equal to this TENDER.
13.4 The manufacturer should have required Plant, machinery and equipment for the following vital test:
 Hydraulic Test,
 Three-edge Bearing Test,
 Permeability Test,
13.5 If the manufacturer does not have required Plant, machinery and equipment for the above vital test,
the required tests to be carried out in any National Test House or NABL accredited Test Laboratory.
The cost of such tests shall be borne by the manufacturer.
Manufacturing,Source of Manufacture and as per the employer/purchasers requirement.
14. Precast Concrete Manhole Cover and Frame

14.1 The manufacturer should have an annual installed production capacity of quantity equal to this TENDER.
The manufacturer should have manufactured and supplied different grades of to any state/central Govt.
department /board quantity equal to this TENDER in last 3 years.
14.2 The manufacture should have valid BIS License as per IS 12592:2002 and accreditation of ISO 9001:
2008/2015 for Manufacture and supply of SFRC, Manhole Frame and Cover.
14.3 All the covers and frames shall be sound and free from cracks and other defects which interferes with
the proper placing of the unit. The underside of the cover and protective mild steel sheet of minimum 2
mm thick around the periphery of cover and frame especially 25mm x 3mm mild steel flat used to protect
the frame shall be given suitable treatment with anti-corrosive paint or coating. Lifting hooks of dia 12mm
mild steel for light and medium duty and 16mm dia. mild steel for heavy and extra heavy duty covers
shall be protected from corrosion by hot dip galvanizing or any other suitable means as approved by the
Employer. The top surface of the cover shall given a chequered finish.
110
The manufacturer should have required Plant, machinery and equipment for the following vital test:
 Load Test,
14.4If the manufacturer does not have required Plant, machinery and equipment for the above vital test,
the required tests to be carried out in any Government, National Test House or NABL accredited Test
Laboratory. The cos of such tests shall be borne by the manufacturer.
14.5 Each cover & frame shall be marked with the standard mark, Lot/ Batch No., Grade Designation
LD2.5, MD10, HD20, EHD35, Period of Manufacturing, Source of Manufacture and as per the
employer/purchasers requirement.
15 SAFETY FOOT REST

Orange/ Black colour safety foot rest of minimum 6mm thick plastic and capsulated on 12 mm dia. Steel
bars having minimum cross-section as 23mm x 25mm and overall minimum length 263mm and width as
165mm with minimum 112mm space between protruded legs having 2mm tread on top surface by ribbing
or chequering besides necessary adequate anchoring projection on tail length on 138mm suitable to
withstand the bend test and as per specification and manufacturers’ permanent identification mark to be
visible even after fixing, including fixing in manholes with 30x20x15 cm cement concrete blocks 1:3:6
complete as per the direction of Engineer-in-Charge.
16 THRUST BLOCKS
The thrust blocks shall be of plain/reinforced cement concrete on site as per design and drawings to be
given by the Contractor and approved by the Engineer In Charge. The thrust blocks shall be cast directly
against the undisturbed soil.
111
Chapter 3
SPECIFICATION FOR CONSTRUCTION OF R.C.C. SUMP AND SEWAGE TRAETMENT PLANT(
STP)
1.0 PREAMBLE:
The work comprises of construction of Sump well at various locations and at Sewage
treatment plant
2.0 Scope of work:
Three RCC sump well as mentioned in Description of work is to be designed and tested on
Lump sum contract.
The work includes the following sub work:
i. Investigation and testing for foundation.
ii. Design and drawing of the structure.
iii. Construction as per approved design and drawing.
iv. Providing and fixing of pipes, valves and other appurtenances wherever required.
v. Testing of the structure for the water tightness and stability.
All materials required for satisfactory completion of the work such as cement, steel, pipes,
specials and valves shall be procured by the contractor himself. The water required for
construction shall be arranged by the contractor but that required for testing and handed over
to the department within the time period specified in the Notice inviting TENDER.
3.0 LOCATION OF WORK:
Sump well site: One number of sump well of required capacity at the land identified by
UJJAIN municipal corporation.
4.0 GENERAL REQUIREMENT:
4.1 The foundation of the structure should be taken down sufficiently below the average ground
level for safe transfer of load to undisturbed formation. Suitable Soil test should be carried out
by the contractor through Govt. Engineering college or any other recognized laboratory to
ascertain safe bearing capacity of the soil for design purpose.
4.2 The specification laid down in the letter TC No. 236 dated 21.05.97 issued by Engineer-in-
Chief PHED M.P. Ujjain be strictly followed. Applicable for Over Head Tanks.
4.3 The type of foundation should be suiting to the determined safe bearing capacity of the soil
and shall be designed accordingly. The excavation shall be done in all sort of strata and if
blasting is required, the contractor shall obtain permission from the competent authority and
all rules regarding safety shall be followed.
4.4 The tanks can either be rectangular or circular is shaped supported over column staging but
the location plan of the columns should permit utilization of spacing underneath fully for
construction of office/staff building.
4.5 The capacity of the tanks specified in para 2.0 above shall be between the outlet level and
the full tank level. The maximum depth of water in the tanks should not be more than 4.0 m.
The outlet level should be kept minimum 0.15m above the tank floor level. A free board of
0,5m should be provided below the lowest surface of the roof slab or beam. The inlet level
should be 0.10m above the full tank level. The scour level should be kept flush with the floor
slab.
4.6 A RCC doglegged staircase 1.2m wide shall be provided from ground level to upto the top of
the tank. The staircase should have straight flights with intermediate landing at bracing levels.
The rise of the stairs shall not be more than 25cm. The staircase should have railing on both
sides comprising of 1.2m high GI medium class pipe of 80 mm dia posts, 1.5 to 1.6m apart
and medium class 20mm dia I pipes in three rows. The GI pipes posts and the railing pipes
(class medium) should be secured adequately.
4.7 A RCC gallery 1.2m wide all around the tank at vertical wall ring beam level should be
provided to facilitate inspection, cleaning and painting of the tank. A railing comprising of
medium class 80m dia GI pipes posts 1.2m high rigidly fixed in the gallery slab at 1.5m
maximum spacing with 3 rows of 20mm GI pipes (Class medium) should be provided. The
112
gallery should have access from the staircase, A steel door shall be provided at the entrance
to the gallery or at the far end of the RCC staircase to prevent unauthorized entry.
4.8 RCC ladder properly supported from tank wall with hand rails 0.45m in width should be
provided outside of the tank from gallery of top of roof slab. The RCC ladder shall have at
least one landing in between gallery and roof top and. Mild steel ladder, from the manhole in
the roof slab to floor slab, inside of the tank to facilitate inspection and cleaning. These
ladders should be of MS plates 65mmx10mm size with 20mm dia round bars fixed at 0.25
centers by holding and welding to MS plates. The insides ladder should be properly
supported in the mid span for rigidity.
4.9 An apron of cement concrete 1:2:4 i.e. M-15 mix should be provided for an area which is 1.5
metre more the dimension of the tank of all sides having 100x100 mm drain in cement
concrete 1:2:4 all around shall be constructed and water will be led to the proper disposal
point through the drain to be constructed for the purpose. The top of the drain around the
apron shall be 100mm above the ground level. Outer edge will be covered with sloping earth
the apron will have a slope of 1.60 from centre towards the drawl. The edge of the drain will
be flush with the top surface of the apron. The apron will be 100mm thick in cement concrete
1:2:4 laid on sub base of 100mm thick 1:4:8 cement concrete in case of black
cotton/cohesive soil the soil will be removed up to 500mm below the ground level and refilled
with rammed moorum up to 400mm in case of hard strata like moorum, kopra etc. moorum
filling will not be required.
5.0 PIPES AND FITTINGS:

The inlet, outlet, over flow and scour pipes for the tanks shall be cast iron double flanged
class A as per IS : 7181-186 all these pipes shall be independent of each other and shall be
fixed in vertical position rigidly by bolting and clamping properly.
The size of these pipes in SUMPWELL shall be as given below
Inletdia of pipe 250 mm
Outlet dia of pipe 300 mm
Overflow dia of pipe 350 mm
Scour dia of pipe 200 mm
Cast iron bell mouths as per Appendix 10.2 of CPHEEO manual conforming to IS 1538-1976
shall be provide on the top end of all pipes. These pipes shall have CI puddle collars properly
embedded in the floor slab at the time of concerting to provide monolithic joint. Cast iron
strainer shall be provided don the top of outlet and scour pipes,. Cast iron duck foot bends
shall be fixed over cement concrete bed block, to support vertical pipes. The bed blocks shall
be designed to take the load of pipes and the water column indecently. The double flanged
Duck foot shall be provided. 1.2m below average ground level at site.
Cast Iron Double flanged sluice valves with spur gear and hand wheel class PN 1.0
confirming to IS : 14846 with all revision up to date issued of NIT shall be provided and fixed
minimum 3.0 m away from the ground level bracing, along with necessary C.I.D.F. pipes. The
size of the valves shall be as given below:
Inlet valve Dia (150 mm)
Outlet valve Dia (150 mm)
Scour valve Dia (80 mm)
The overflow pipe shall be left open at minimum 3.00 m distance from bracing CIDF pipes
shall be provided between Duck foot bends and D.F. sluice. The contract will limit up to fixing
of DF values.
6.0 APPURTENANCES:
6.1 Water level indicator:
A float operated level indicator comprising of stainless steel float pulleys, steel wire rope and
enameled indicator plate calibrated to read depth of water in metre, shall be provided.
113
The pulleys should provide free movement of rope and they should be easily accessible for
repair and maintenance. The indicate plate should be fixed at about 5m. Above ground level
on the front side of tank.
Additionally the following arrangement may be provided as optional
(a) Water level indicator, working on physical characteristics.
(b) Pressure gauge, calibrated, to read water depth directly.
6.2 Ventilators :
Mosquito proof ventilators, of suitable design shall be provide on the roof slab of tank to
facilitate discharge of dissolved gases of water and to keep the inside of tank odour free.
6.3 Manhole:
An opening of 0.75x0.75m or 0.9m dia. size shall be provided in the roof slab fo tank for
access inside the tank for inspection and cleaning. The opening shall have CI/MS cover with
locking arrangement.
Lightening Arrestor:
Aluminum lightening arrester as per relevant B.I.S. shall be above highest point and 30
mmx4mm size strip connected to earth electrode shall be provided. The earth strip shall be
secured rigidly to concrete surface.
7.0 FINISHING AND PAINTING
7.1 Form finish:
All external surfaces on the structure shall have form finish. However all uneven surface and
small defects shall be made even immediately after removal of forms with 1:1 cement mortar.
The inside surface of the tank shall be rendered even and water proof by cement plaster in
1:2 portion.
7.2 Painting of Concrete:
The outside surface of the Sump shall be painting with 2 coats of IS marked cement colour of
approved make. The colour shade shall be decided by the Engineer-in-Charge.
7.3 Painting of pipes etc.
Cast iron pipes, valves and fittings, shall be painted with 2 coats of black bituminous paint.
7.4 Painting of MS Ladders and MH Cover:
As the MS ladder inside of the tank and manhole cover shall be subjected to corrosive action
of chlorinates water they shall be coated with epoxy paint
8.0 TESTING OF SUMPWELL:-
In addition to the structural test as given in IS 456-1978 revised and amended up to date the
Sumpwell shall also be tested for water tightness at maximum water level in accordance with
clause 10.1.1 of IS 3370 (part-I) 1965. The tanks shall be filled more than 0.25m per day and
the settlement of foundation of foundation shall be measured accurately before each filling.
Any defect of any sort affecting the strength, durability, appearance of usefulness of the
structure noticed during testing shall be completely removed to the satisfaction of Engineer-
in-charge with in the specified time for completion of work.
9.0 COMMISSOINING & HANDING OVER:-
On completion of all works and the successful of the Sumpwell, it shall be handed over to the
department for commissioning as required on completion of work and testing. The contractor
shall submit completion drawing in six sets along with foundation investigation, concrete
strength water tightness test reports at the time of handing over of work.
114
Chapter 4
SPECIFICATIONS FOR SEWAGE TREATMENT PLANT
All the work shall be carried out as per relevant provisions of clauses and sub clauses
of chapters of Manual on Sewerage and Sewage Treatment (Second Edition), CPHEEO
Ministry of Urban Development Govt. of India
(1) Construction of Sewage Treatment Plant. The Job includes the construction of one number
of STP of capacity 92.5 MLD in SurasaVillage .
(2) TREATMENT:
Specifications of all the treatment units shall be as per CPHEEO Manual and relevant
IS/BIS/ISO standards. Bidder shall require to submit a brief write up on the Sewage
treatment plant along with the TENDER. On acceptance of TENDER the successful
Bidder shall submit a detailed design and drawings of the Sewage treatment plant
based on CPHEEO Manual and relevant IS/BIS/ISO specifications for the approval of
competent authority.
The Sewage treatment plants shall be for Primary and Secondary treatment of MUNICIPAL
SEWAGE. Typical composition of untreated domestic waste water, is as follows:
Parameters Concentration
Contaminants unit Weak Medium Strong
Suspended mg/l 100 220 350
Solids
BOD5 mg/l 110 220 400
COD mg/l 250 500 1000
Total Nitrogen mg/l 20 40 85
Free Ammonia mg/l 12 25 50
Nitrates mg/l 0 0 0
Total mg/l 4 8 15
Phosphorous
Chlorides mg/l 30 50 100
Sulfate mg/l 20 30 50
Grease mg/l 50 100 150
The Effluent Characteristics should meet the MP Pollution Control Board norms and MOEF
Norms for discharging water in inland water ways or to be used for community purpose as per
Pollution Control Authorities with up to date amendments. The effluent discharge limits are
described below.
115
Contaminants unit Inland surface water discharge limits

Ph 5.5-9
0
Temperature C Shall not exceed 50C above receiving water bodies
Oil and grease mg/l 10
Total residual mg/l 1
chlorine
Suspended mg/l 100
Solids
Ammonical mg/l 50
Nitrogen
Total Kjeldal mg/l 100
Nitrogen
Free ammonia mg/l 5
BOD5 mg/l 30
Fluoride mg/l 2
COD mg/l 250
Dissolved mg/l 5
phosphate
Sulphide mg/l 2
Phenolic mg/l 1
compounds
Bio-assay test - 90% survival of fish after 96 hours in 1005 effluent
Manganese mg/l 2
Nitrate Nitrogen mg/l 10
All the treatment units shall be as per CPHEEO Manual and relevant IS standards.
Bidder shall require to submit a brief write up on the Sewage treatment plant along
with the TENDER. On acceptance of TENDER the successful Bidder shall submit a
detailed design and drawings of the Sewage treatment plant for the approval of
competent authority. The general specifications and guidelines for STP are as below,
1.0 General Guidelines for level of STP and proposed Trunk Main Sewer.
The contractor is advised to have a site visit and verify the site levels.The STP should be
designed, such that the complete process is completed with least of power consumption, also
STP should be at sufficient height to avoid flooding during monsoon. It is the responsibility of
contractor to match the outfall chamber level with proposed by pass channel meant for
excess flow and discharge of treated sewage.
2.0 Raw Sewage Intake System & Raw Sewage Sump & Pump
The raw sewage shall be intercepted from the last manhole and shall be taken to the raw
sewage intake and pump sump via gravity. A minimum self-cleaning velocity shall be
maintained throughout the sewer line in order to avoid the settling of the particles. The raw
water sewage pumping station shall comprise of the following system:-(i) Inlet chamber,
(ii)mechanically cleaned coarse bar screen,(iii) pump sump and (iv) raw sewage pumps.
116
A bypass line to the Pumping station shall be provided which shall discharge Sewage to the
drain, in case of overflow or raw sewage pump failure. This Pipe line shall be designed to
maximum hydraulic capacity.
3.0 Sewage Treatment Plant
3.1 Inlet chamber cum distribution chamber
The raw sewage shall be pumped to the inlet chamber before the fine screens.
3.2 Fine Screen Chamber.
One no. mechanical and one no. manually operated fine screen of 6 mm openings shall be
installed in a reinforced concrete chambers for fine screens. These two chambers shall be in
parallel with common wall construction. Manual bar screen shall be standby in case the
mechanical fine screen is out of service. The screen channels shall be designed for peak
flow. The bar screens shall be of Stainless Steel (SS-304) flats. Conveyor Belt and chute
arrangement shall be provided to take the screenings to the screenings dropped from chute
will be collected in a trolley positioned below of approx. 0.5 m3 capacity. Manually operated
gates are provided at the upstream and downstream ends to regulate the flow and for
isolation. The Sluice gates shall be thimble mounted and confirm to IS: 13349. RCC
Platforms shall be provided at the upper level to enable operation. Railings shall be provided
around the entire periphery of the Chamber as well as for the platform. The entire structure is
as per relevant IS code including the platform for the gates. RCC staircase 900 mm wide
shall be provided for access from the ground level to the top of the unit & to the operating
platforms.
All other accessories, whether specified or not, but required for completeness of the contract
shall be in contractor’s scope.
A level switch shall be provided in the channel upstream of screen chambers to start/stop the
screen drive mechanism. Signal for Tripping of mechanical screen due to heavy blockage
shall be announced through alarm for corrective action. ON-OFF and trip indication shall also
be sensed and indicated in the panel room. Level increase in the channel from the upstream
of screens due to clogging of screens including manual screen shall be sensed and alarm
annunciation shall be initiated in the panel room for corrective action. ON-OFF trip indication
of conveyor belt due to fault of overload shall be sensed in panel room for corrective action.
The screened sewage shall flow by gravity to the grit chambers, through suitably branched
and sized channels.
3.3Grit Separator Units
Grit Separators are to be provided after the screening and before the biological treatment.
There shall be one number mechanically operated detritor type grit separator designed for
Peak flow. Another parallel manually cleaned grit channel shall also be designed and
provided for peak flow and will work as a standby unit. The grit chamber should have a low
head loss. All equipment and components (including but not limited to scrapper, classifier,
and organic return pump) necessary for a fully functional system shall be provided regardless
of whether or not such items are specifically listed or described in the Tender Document.
Washed grit shall be collected in a trolley positioned at ground level below the Grit Classifier
discharge. De-gritted sewage shall exit the Grit Basins over the outlet weir. Liquid streams
from grit classifier shall be returned to the de-gritted sewage stream.
The bidders are to note that the silt & grit removed from grit chamber, does not form a part of
the TSS in the incoming wastewater quality indicated in the tender document. Accordingly
sludge calculations shall be done by bidders.
The grit separator should preferably have a scrapper and suitable grit lifting screw/rake
transferring the settled grit to a grit classifier with an integral grit washer.
3.4 Flow Measurement
Flow measurement in the common outlet channel after screening and grit removal shall be in
the form of a Parshall flume housed in the RCC channel. There shall be a straight length of at
117
least 10 times the throat width of the channel housing the flume in both upstream and
downstream of the flume. The flume shall be constructed in RCC and finished in cement
mortar. An ultrasonic level measurement device shall measure sewage depth in the flume
and the flow computation shall be through the dedicated digital display with integrator near
the flume. The readings of this meter shall be transmitted to the control room. Parshall flume
channel shall lead to the distribution chamber of Biological treatment.
3.5Distribution chamber
Sewerage from the Parshall flume shall be fed to the distribution chamber which will distribute
the Sewerage into separate streams for the Biological treatment.
3.6 Biological treatment of sewage
Process Design
Sewerage from the distribution chamber shall enter process basins as per relevant IS code.
Screened and De-gritted sewage shall be fed for biological treatment to remove BOD, COD,
Suspended Solids, Nitrogen and Phosphorous.
It shall perform biological organic removal, Nitrification, De-nitrification and Biological
Phosphorous removal. It shall be capable of simultaneous sludge stabilization. Complete
operation including decanting rate, sludge recirculation and wasting of excess sludge shall be
controlled by PLC. Treated Sewage shall be disposed in the adjacent drain through
Sewerage Pipe after chlorination.
The Biological and Tertiary Treatment shall be based on technology based on which at least
one Municipal Sewage Treatment Plant running successfully at present in India having
capacity 30% or more of the capacity of Sewage Treatment plant proposed in the project on
the same technology. The effluent characteristics should meet the CPCB and MoEF norms for
disposal on land or water resource. Also the sludge should be digested ad stabilized before
disposal by the Contractor.
The basic continuous signal instrumentation system

It shall include flow measurement and the necessary water level readings from a pressure
transducer device installed in each reactor. The measuring elements for all instruments
including floats shall be located together on the side of the reactor in a well-mixed area easily
accessible for maintenance.
 Level transducers
One level transducer shall be used in each reactor and in any other basin where water level
is to be monitored to assure the automation of the operation. One spare pressure transducer
shall be supplied to enable a quick replacement of a faulty part. The pressure transducers
shall be maintenance-free with a maximum deviation of less than 2% over a period of 6-
month operation.
 Dissolved oxygen (DO) transducer
One DO transducer shall be supplied for each reactor. This instrument is meant to control
the aerobic environment in the reactor by controlling the blower operation (start/stop). Proper
logic control is to be established by the bidder. One spare sensor shall be supplied to enable
a quick replacement of a faulty part.
 Sequence control strategy
The TECHNOLOGY PROVIDER shall be responsible of providing all the logic control
programming and related hardware into an enclosure panel described further complete with
all the equipment specified herein.
The contractor shall be responsible to install the Logic Control Panel and to provide and
install separate MCC and power distribution panels as specified in the electrical section of
this specification. The contractor shall also be responsible to interconnect electrically all the
118
instrumentation and float signals specified herein with the logic control and the MCC panels
as needed for a Complete Automated Operation.
 Logic Control Hardware and Panel
The program controller shall be provided with key pad and display to enable the operator to
easily re-adjust all cycle time and sequence. The programmable logic controller (PLC) shall
have sufficient memory to perform automatic control of the process described herein and
shall be sized to provide an additional number of input/output capacity of 10%.
All control equipment installed in the control panel shall be accessible for operation of
mounted on the front face of the panel. This panel shall control the operation of the various
process equipment including:
 influent valves or gate weirs
 air blowers
 decant equipment
 waste sludge pumps (or valves)
 any additional process equipment specified herein
The PLC shall receive all input signals or described and take the necessary decisional action
in regards to the operation of the above process equipment.
The panel for the logic control shall be NEMA (National Electrical Manufacturers Association)
enclosure and shall be provided with necessary Control Breaker, Transformers and
Supplementary Contacts as noted herein.
The panel wiring shall be sized per applicable codes using SWG 16 gauge minimum wire
size. Wiring terminal blocks shall be rail mount control terminal type thermoplastic rated at
600 Volts. Not more than two wires shall be allowed to terminate in anyone terminal.
The panel face shall be provided with an individual 3-position selector switch (HOR) for each
automated valve, blower (4-position selector if dual-speed blower), pump, decanter or
auxiliary equipment and instrumentation specified herein. It shall be equipped with one pilot
light dedicated to each equipment.
The pilot light shall be wired in parallel with the related motor starter auxiliary contact or relay
other limit Switch contact to indicate that the equipment is activated or deactivated. Pilot
lights shall be 415V AC direct types or led type.
All internal devices shall be clearly marked and identified as to its application, including
selector switches, pilot lights, pushbuttons and other devices exposed in front of the panel.
Identification nameplates shall be with black letters or numbers in white, carved in plastic.
For all automated valves and decanter operation, feedback signal shall be also provided and
connected to the logic controls to acknowledge and confirm the good operation. In the event
of one equipment failure, the reactor shall be temporarily bypassed and an alarm shall be
activated to notify the operator. In the meantime, the flow shall be managed by the other
reactor(s) in accordance with the programming.
The control panel shall be equipped with circuitry to shutdown automatically the pump motor
when required, to protect this equipment from damages caused by excessive humidity,
temperature, or current overload. The contractor shall be responsible for connecting these
pumps and motor sensors to the appropriate circuit in the control panel to protect the pumps
in accordance with the pump manufacturer instructions. One pilot light shall be mounted on
the control panel surface to indicate an alarm condition; all alarms shall appear on the
operator interface. In both cases, these alarm conditions shall open the circuit of the pump
starter to prevent it from starting.
The control panel shall be shipped completely factory wired, assembled and factory tested.
119
 Programmable Logic Controller (PLC)

The Programmable Logic Controller (PLC) shall be from the suggested makes.
 Operator Interface Unit
The Operator Interface Unit shall be from the suggested makes ABB Panel View or approved
equivalent.
3.7 Disinfection System
Chlorine Contact Tank
For Chlorination of final treated sewage a provision shall be made so that no harm is caused
to the receiving water body. Decanted treated water from Biological treatment Process shall
be taken to chlorine contact tank by RCC channel/pipe.
Tank shall be provided for dosing of chlorine from the chlorination system to the sewage from
Biological Process. The tank shall be constructed as per the relevant IS code. RCC platform
1000 mm wide as per specifications shall be provided. RCC staircase 900 mm wide shall be
provided for access from the ground level to the top of the unit and to the operating platforms.
Baffle walls shall be provided to achieve proper disinfection. The baffle walls shall be
constructed in concrete and 20 cm thick plaster in CM 1:3 on either side.
The inlet and outlet pipe shall be designed for peak flow.
No. of Units : 1 no.
Detention Time : 30 minutes of average flow (minimum)
Freeboard : 0.5 m
Chlorination System:
Number of Units : 2 nos. (1W + 1S)
Type : Vacuum Chlorination system
Chlorine Dosing : 5 mg/l
Residual chlorine : 0.2 mg/l
Capacity of system : Rounded to the upper Kg/hr.
Chlorine house of adequate plinth area shall be provided. It shall have sufficient ventilation as
per the latest norms for safety purpose with necessary lifting arrangement and EOT etc.
complete. All other accessories, whether specified or not, but required for Chlorination shall
form part of contractors scope.
3.8 Outlet Pipe
Treated sewage after chlorine contact tank shall be taken to disposal to the discharge point.
The length of the Pipe shall be as per site condition. Capacity of the pipe should be such that
it can carry peak flow.
3.9 By-Pass Arrangements
Adequate by-pass arrangement shall be provided from Raw Sewage pump sump & inlet
chamber at the entry of STP, to the outfall of the drain in case of necessity.
4.0 Solids and sludge handling
4.1 Sludge Holding tank
A tank shall be provided to store sludge from the WAS (Waste Activated Sludge) pumps and
to act as a sump for sludge transfer to centrifuge.
Sludge sump will have mixing using coarse bubble aeration through PVC piping with
openings. Separate dedicated air blowers will be provided for sludge mixing.
120
All other accessories, whether specified or not, but required for completeness shall form part
of contractors scope.
4.2 Sludge Pump House

Screw pumps for sludge transfer from sludge holding tank to centrifuges, polyelectrolyte
dosing system and air blowers for mixing of sludge in sludge holding tank will be housed in
the sludge pump house. It shall be RCC framed structure with sufficient openings in the form
of doors, windows, ventilators etc. and 1 MT capacity chain pulley block will be provided in it,
for material handling purposes. Minimum carpet area of this building will be 20 square metre.
4.3 Polyelectrolyte Dosing
The polyelectrolyte will be dosed and blended with the sludge in the sludge sump. Minimum
dose of polyelectrolyte shall be 1.5 kg/T of dry solids in sludge. There shall be one poly-
dosing tank. Minimum volume of each dosing tank shall be suitable for 8 hours requirement of
dosing. Each tank shall be equipped with slow speed mixer (100 RPM) to prepare
polyelectrolyte solution, to feed the solution into sludge sump by dosing pumps.
4.4 Centrifuge Feed Pump
The sludge pumps will be positive progressive cavity displacement types. There shall be two
pumps (One Working + One Standby) for pumping this sludge to the centrifuge. The minimum
capacity of the pump shall be 1 m3/hr. Pumps will have solid handling capacity of not less
than 40 mm sphere. M.O.C.(Materials of Construction) of pump shall generally be C.I.
Pump and motor will be mounted on a common MS fabricated base frame. The coupling will
be flexible coupling. The motor will be Totally Enclosed Fan-Cooled (TEFC) and driven
through belt drive.
4.5 Centrifuge
Thickened sludge shall be pumped to the centrifuge unit for dewatering. It shall be provided
at suitable elevation for the dried sludge from centrifuge to be collected in a trailer/container
situated below it.
Centrifuge shall be operated for 16 hours in a day and floor mounted. It shall be suitable to
handle thickened sludge from thickener. The minimum solid contents in the sludge at
centrifuge inlet shall be 3 %.
The material of construction of all parts coming in contact with the liquid shall be in CS.
Number of Units : 2 (1Working+ 1Standby)
Operation : 16 hours running per day
Dry solids in dried sludge : 15 – 18 percent
All other accessories, whether specified or not, but required for completeness shall form part
of contractors scope.
4.6 Centrifuge Shed
Sludge dewatering system shall comprise of centrifuge shed of appropriate size, which
includes thickened sludge pumps, poly dosing tank with mixers, centrifuge unit.
Filtrate from the sludge shall be taken to plant drainage system by gravity.
4.7 Disposal of Solid Waste
Disposal of all solid wastes except wet cake as generated from the STP during construction,
commissioning, and O & M shall be responsibility of the contractor. The solid wastes shall be
disposed of in accordance with and as per instructions of the Employer/ Engineer or the
representative of the employer. The Sludge Land Fill (SLF) identified for disposal may be
assumed maximum at a distance of 10 kms from the proposed new STP site for bidding
purposes. Loading, transportation, unloading shall be to Contractor’s account.
121
Grit & Screenings

The evacuated grit and screenings are to be disposed off from the site by the Contractor at
landfill site identified by the Employer’s representative from time to time
Wet cake
The contractor can sell wet cake generated from STP during O & M period at his own level. If
it is not possible to sale then wet cake shall be disposed off at land fill site identified by the
Employer’s representative from time to time considering at least 10 KM from STP site (for
bidding purpose)
5.0 Ancillary Structures
5.1 D.G. Room (area as per DG manufacturer’s requirements)
5.2 Outdoor Transformer Yard
5.3Admin Bldg, MCC Room, Blower Room, Operator Room, SCADA Room, Laboratory
Sub-station/Transformer yard (outdoor), Master Control Rooms, Operator Room, D.G.
Room/Yard, SCADA Room and Laboratory shall be constructed at suitable location. The
buildings shall be designed as per requirement.
The building shall have RCC frame work of minimum not less than M25 consisting of RCC
columns, RCC roof and beams with brick panels and foundation, suitably designed to take
the load of the walls. Rolling shutters of adequate size shall be provided for the above rooms
on the external walls. At the entrance of the transformer yard, M.S. gate shall be provided of
adequate size.
The floor of the MCC rooms and D.G. room shall consist of 40 mm thick cement concrete laid
over 1:2:4 including 15 mm thick ironed finish 150 mm thick 1:3:6 cement concrete. The floor
of other rooms shall bewith 20mm thick mosaic laid over 150mm thick 1:4:8 cement concrete.
The above floors shall be laid over well consolidate sand with rammed earth filling below
floor. The walls shall be provided with 150 mm high skirting with 20 mm thick mosaic finish as
per direction of the Engineer.
The brick walls of the buildings shall be plastered internally and externally with cement mortar
1:2:4 (1 cement : 2 coarse sand : 4 fine sand) and provided with oil bound distemper inside
and water proof cement paint outside as approved by the Engineer. Ceiling shall be plastered
with 1:4 cement mortar (1 cement and 4 fine sand) and three coats of white wash. All steel
work in the doors/windows/ventilators, rolling shutters etc. shall be provided with a superior
class paint/primer etc. approved by the Engineer to give a smooth finish.
The buildings shall be provided with plinth protection all around, 750 mm wide as specified.
Necessary slopes shall be given in the plinth protection so as to drain away the rain water
from the building. The roof shall be provided with water proofing as per DEPARTMENT
specifications. A RCC stair case of required width shall be provided to access different floor
levels.
The plinth level of the buildings shall be 600 mm above formation level. Suitable ramps shall
also be provided wherever required as desired by the Engineer.
The offer shall include for internal electric wiring of the buildings with light/fan, Switch and
regulator fittings.
The buildings shall be of sufficient size to accommodate all machineries / equipments and
controls and an office for operation, toilet, store etc. The tenderer shall verify and provide the
required size from the practical point of view and ease of operation.
5.4 Interconnecting Piping and Valves
All piping including valves, specials and other appurtenances, auxiliaries and accessories
required as per process design and scope of work. All the piping, valves, specials shall be
designed for peak flow.
122
In case of pumping mains thrust blocks with PCC/RCC shall be provided whenever required.
In case of buried pipes warning tapes shall be provided of the appropriate colors.
5.5 Security Room
The security room at entry of road shall be provided. This shall be a ground floor construction
with3m x 5m carpet area and be of RCC frame structure building with in filled rock faced
stone masonry and shall be provided with glass panels on three sides and an air cooler.
Necessary fans and lights shall be provided as directed by the Employer’s representative.
Toilet and bathroom shall be attached with security room. There shall be a working platform
made of Granite stone.
5.6 Landscaping
Landscaping involves beautification of Sewage Treatment Plant site by cultivating plants,
shrubs and trees of environmental value and suitably modifying the appearance of STP site.
It shall add scenic value to the STP site to obtain maximum visual impact. Contractor has to
develop proper landscaping in the STP site as per guidance from the Engineer in charge.
Area for future expansion shall also be considered for landscaping.
5.7 Compound Wall and Retaining wall of STP site and its Main Gates
R.R Masonry Compound wall of not less than 2.4 m above the finished ground level, 34 cm
thickness with suitable foundation, for covering the entire plot boundary around the proposed
site.
5.8 Earth Filling Cutting and Dressing
Area shall have to be filled up, consolidated, levelled and nearly dressed upto required
formation levels. In case earth is required over and above the surplus excavated for the
same, the tenderer shall have to arrange good sheet earth from its own resources and
provide for same in their offer. Filling of such earth in layers with proper consolidation as per
specifications shall be done.
5.9 Walkway and Pathway/Footpath
All Elevated RCC walkway 1.2 m wide shall be of RCC with M-20 grade concrete. The floor of
the walkway shall be finished smooth with 40 mm thick cement concrete. It shall be provided
with one meter high GI pipe railing on both sides of the walkway with connecting platforms.
All pathway and footpath over ground connecting individual units to bituminous road shall be
1.2 m wide and be 100 mm thick cement concrete (1:3:6) finished with 40 m thick (including
base mortar 1:4) checkered cement concrete tiles. The base concrete to be laid on 150 mm
thick hard core with 40 mm down stone ballast and morrum rammed and consolidated
properly as per direction of Engineer.
5.10 Roadway
Roads as per lay out shall be provided around all units as directed.
5.11 Parking Space
Adequate parking space should be provided .The area shall be paved as per WBM
specification.
5.12 D. G. Set
D. G. Set shall be provided to cater for the power failures. Capacity of D.G. set shall be
minimum 50% total connected electrical load (STP + RSPS)). D.G. Set will be placed in DG
Room, to be provided in the STP premises.
123
6.0
Chapter 5
PART – 1.0 PUMPS FOR SEWAGE PUMPING
1.1-GENERAL DESIGN CONDITION SUBMERSIBLE NONCLOG PUMPS FOR SEWAGE
PUMPING
The pumps shall be of non-clogging equipped to operate satisfactorily in UJJAIN for pumping sewage
from sump well to STP. Lean Flow, Mean Flow to be managed. Accordingly, pump configuration with
100% standby should be provided.
MPS: For pumping of 92.5 MLD sewage from sump well to STP
The configuration of Pumps are as per BOQ.
The pump shall be submersible with the suction and delivery branches cast inline on the bottom half
of the casing, the top half should be constructed to allow easy dismantling there by providing the
facility of inspection and repair to the equipment without any difficulty. The rotating elements of
pumps will be dynamically balanced and over stressing should not occur due to sudden failure of
power & reverse rotation should not damage the pump.
The pump shall be so designed as to have a maximum flow capacity of not less than 110%
1.2 CODES AND STANDARDS

The designed performance requirement, material requirements, manufacturer, inspection and testing
of the pumps shall generally comply with the requirements of all applicable
Indian/British/American/DIN/ISO standard, in particular the following:
IS 5120 : Technical requirements – Ro to dynamic special purpose pumps
IS 5600 : Sewage and drainage pumps
IS 9137 : Code for acceptance for centrifugal, mixed flow and axial flow pumps
1.3 DESIGN AND CONSTRUCTION
a) Each pump shall be a mono unit, equipped with a motor on single shaft, with rating so
selected as to have at least 15% margin over the maximum power required by the pump
throughout its range of operation.
b) Motor shall be of submersible squirrel cage induction motor type, F class, Oil filled, suitable
for 415 volts (+6%-15%) & 50Hzs (+/-3%).
1.4 PUMP CASING

a) Casing shall be so designed to allow free passage of specified maximum size of solid.
b) Casing shall be designed to withstand the maximum shut off pressure developed by the
pump
c) The casings shall be cast, free from blow hole, sand holes, other detrimental defects. The
casing shall be complete with suction and discharge connections.
d) For pumps adequate seal arrangement shall be made to keep leakage of liquid from
casing to column assembly to minimum and adequate drain shall be provided in column
assembly to permit escape of the leakage flow. The casing shall also include the bearing
housing of the bottom pump shaft bearing.
1.5IMPELLER
a) The impeller shall be non-clog type, cast in one piece and specially designed to pass large
solids or unscreened liquids. The clearance between stationary and moving parts should
be such as to allow sustained performance without excessive maintenance.
1.6 PUMP SHAFT

a) Shaft size selected shall be such that critical speed is at least 20% away from the
operating speed and the runway speed.
b) The shaft shall be ground and polished to final dimension and of ample size to withstand
all stresses resulting from rotor weight, hydraulic loads and across the line starting.
1.7 BEARINGS
124
a) Adequate nos. of properly designed bearings shall be furnished. Bearing for fixed type
sump pumps shall be oil lubricated and bearings shall be antifriction type.
b) Thrust bearing of adequate design shall be furnished for taking the entire pump thrust
arising from all probable condition of continues operation throughout its “Range of
operation” and also the shut off condition life of thrust bearing shall be 20,000 working
hour minimum for the load corresponding to the duty point.
1.8 WEARING RING/ PLATE (As required)

a) Renewable wearing rings/ plates shall be provided either on impeller or on the casing or
on both impeller and casing.
1.9 BOLTS NUTS AND WASHERS

All bolts, nuts and washers shall be of SS-304.
1.10 PRESSURE INDICATION DEVICE

Each installation shall be equipped with pressure gauges of good quality make to give indication of
delivery pressure. The pump pressure gauges should be designed in such a way that the readings
shall not be affected due to mechanical vibration. The connections sizes shall be 12mm and diameter
size 150mm in addition to above each pump shall be fitted with electronic pressure transducer with
electronic digital display type indicator in control panel to indicate the delivery pressure of the pump.
1.11 MATERIAL AND CONSTRUCTION

MATERIAL OF CONSTRUCTION OF PUMP SHALL BE SUCH AS TO RESIST EROSION &
CORROSION. MATERIAL OF CONSTRUCTION OF VARIOUS COMPONENTS SHALL BE
AS UNDER
Pump casing : CI
Impellers : CI
Pump shaft : AISI -410
Nuts, Bolts & Washers : SS-304
1.12 INSPECTION AND TESTING

All the inspection, examination and testing shall be carried out in accordance with relevant
IS/BIS/ISO and standard specification.
1.13LABORATORY TEST
Laboratory pump test shall be carried out as per IS: 9137, with latest amendment each pump to
assess the pump discharge Vs head, Horse Power (hp) and efficiency figure. The pump casing shall
be subjected to a pressure test of 1.5 times the working pressure at duty point
1.14 FIELD TEST

If need be the field test be carried out as per IS: 9137, with latest amendment these test may be
witnessed by the Engineer-In-Charge or his authorized representative. If they desire the tolerance as
specified in relevant IS code of practice shall not be quoted efficiency of pump during the testing.
1.15 GUARANTEES PERFORMANCE & TECHNICAL PARTICULARS

The contractor shall submit the details of guaranteed performance and technical particulars as
required and the preliminary out line drawing indicating principal dimension and weight of pumping
equipment and cross section drawing indicating the assembly of pumps & major parts thereof with
materials of construction and special features, complete descriptive and illustrated literature on the
equipment and accessories offered& proposed to be used before initiation of procurement and
approval of QAP.
125
PART – 2.0 SPECIFICATION FOR 415 V INDUCTION MOTORS

2.1 TYPE
The motor shall be horizontal SOLID shaft squirrel cage type for clear water pumps suitable to
operate on 415 V, 3 phase, 50 Hz. AC supply (with allowable variation of 10%) directly coupled with
pumps. The rotations of clear water pumps shall be 1500 RPM. The motor rating generally conform to
latest revision of IS 325-1996 and other relevant BS/IS/ISO.
2.2 VARIATION IN SUPPLY VOLTAGE
The motors shall be capable of delivering integrated output and rated power factor with following
variations:
VOLTAGE : +10%
FREQUENCY : +5%
COMBINED : +10%
PHASE IN BALANCE : +5%
2.3 RATED CAPACITY
The minimum continuous rated capacity of motors shall be such that it meets the power requirements
of pumps in the complete range of its operations. It shall also provide additional power requirement in
the motor by 5% at the maximum power requirement or by 10% at the duty point of operation
whichever is maximum. The contractor shall ascertain the KW requirement and provide the motors of
suitable capacity.
2.4 ACCELARATION CHARACTERISTICS
The accelerating characteristics of motor shall be matched with the driven equipment so that
acceleration is obtained without over heating of motors.
2.5 METHOD OF STARTING
The motors shall be designed for star/delta/soft/starting at full voltage with starting current not
exceeding 2 times the rated full load current. The motor shall also be designed for a minimum pull out
torque of 200%.
2.6 NUMBER OF START
Motors when started with the drive imposing its full starting torque under the specified supply voltage
variation shall be capable of withstanding at least two successive starts from hot condition and one
start from cold condition without damage to the winding.
2.7 CLASS OF INSULATION
The motor winding shall be provided with insulation conforming to thermal class F. The maximum
temperature rise of the winding shall not exceed the limits specified for class 'B' insulation. The
insulation shall be given tropical and fungicidal treatment for successful operation of motor in hot,
humid tropical climate. It shall be of thermo-setting type and shall remain unaffected by heat. The
coils shall be highly uniform with uniform insulation strength and uniform dielectric losses. The
dielectric losses shall be low and the star delta measurement should not exceed 1% at 440V.
MAKE OF MOTOR CROMPTON, KEC, ABB AND SEIMENS ONLY.
2.8 MOTOR CONSTRUCTION
The motor construction shall be suitable for easy dismantling and reassembly at site with the help of
simple overhead crane. The motor shall be of core pack construction attached to the stator frame to
facilitate easy removal and replacement of the winding for maintenance purpose. The overhead for
winding at both ends of the core shall be accessible for usual inspection without resorting to major
dismantling.
2.9 MOTOR FRAME
Motor frame shall be of rigid cast steel. They shall be suitably annealed to eliminate up any residual
stresses introduced during process of fabrication and machining.
2.10 STATOR LAMINATIONS
Stator laminations shall be made of suitable grade sheet varnished on either side and shall be
adequately designed to avoid over heating during the starting and running conditions stipulated
above.
126
2.11 ROTOR
Rotor should be desisted dynamically balanced and having carbon steel shaft hydraulically fitted.
2.12 LOCKED ROTOR WITH STAND TIME
Locked rotor with stand time under hot conditions at 110% voltage shall be more than starting time at
minimum permissible voltage by at least two seconds.
2.13 TYPE OF ENCLOSURE & DEGREE OF PROTECTIONS
The degree of protection provided by the enclosures of motor shall conform to IS : 4691(1985). The
enclosure for the motors shall be Closed Air Circuit Air Cooled (CUIDSSMT) type, having of
protection I.P. 55.
2.14 SHAFT INSULATION
Suitable insulation shall be provided on shaft bearing housing to prevent shaft current. The insulation
provided shall be such that it shall retain its dialectical properties even after its handling for number of
times during dismantling and reassembly.
2.15 BEARING ASSEMBLY
Bearing assembly shall be such that it prevents dust and water from getting into the bearing. Further,
bearing lubricant shall not find access to the motor winding. The bearing assembly shall be provided
with proper lubricating nipples.
2.16 EARTHING
The motor body shall have two separate earthing terminals for earthing in compliance with I.E.
RULES.
2.17 TERMINAL BOXES
Separate terminal boxes shall be provided for main-Terminals of the motors and for R.T.D. and for
space heaters. The terminals box for main terminals of motor shall be segregated type suitable for 3
core. 440 V. Aluminum conductor PVC insulated armored cables. The terminal boxes shall be
spacious, dust & house proof designed and properly insulated. Adequate clearance should be given
between live motor terminals and covers.
2.18 TEMPERATURE DETECTORS
Motors shall be provided with embedded temperature detectors, two for each phase winding at the
location where the high temperatures may be expected in the stator winding. The temperature
detectors shall also be provided in bearing assembly for monitoring the bearing temperature. The
temperature detectors shall be connected with digital temperature scanners with alarm and trip points
in the control panel.
2.19 ANTI - CONDENSATION HEATERS
Motors shall be have space heaters suitable for 240 V. single phase 50 Hz. A.C. supply, space
heaters shall have adequate capacity to maintain motor internal temperature above due point to
prevent moisture condensation on insulation during shut down periods.
2.20 DIMENSIONS OF MOTORS
Motors shall be properly dimensioned to have greater stability and low vibration limits. Mounting
dimensions should confirm to IS : 2254(1985).
2.21 COUPLING TO PUMPS
The motors shall be coupled to the pumps by means of polished steel shaft and flexible coupling. The
size of line shaft and flexible coupling shall be calculated on the basis of maximum combined shear
stress as per the relevant IS and shall not exceed 30% of the elastic limit in tension or 10% of
ultimate tensile stress, shaft shall be designed taking into consideration that critical speed of the shaft
which shall be higher than the operating or runaway speed.
2.22 DETAILS OF MOTORS TO BE FURNISHED
The successful TENDERER shall furnish, the details of efficiency, total losses and power at different
loads etc. as required in the form of guaranteed performance and technical particulars of motors in
before procurement and approval of QAP.
2.23 TESTING
All the motors shall be tested at the manufacturer’s workshop in the presence of Engineer-in-charge
of work or his authorized representative or a third party inspection directed by Employer.
127
PART-3.0 CABLING AND MOTOR CONTROL PANNEL

3.1 CABLE SEWAGE PUMP HOUSE
In case of sewerage pump house, the soft starter panel of each motor of sewage centrifugal
pump shall be connected in L.T. panel in the pump house, through 300sqmm 3-1/2 core
armored cable. Thus in all 2 Nos. of 300sqmm 3-1/2 core armored cable shall be laid in suitable
duct and as per I.E.RULE and a loop of about 1m should be given in each cable.
3.2REACTOR TYPE MOTOR SOFTSTARTER [MOTOR CONTROL PANEL]
TECHNICAL SPECIFICATIONS:
TYPE OF SOFT STARTER NEUTRAL/LINE REACTOR SOFT STARTER
PRINCIPAL SRSS[SERIES REACTOR SOFT STARTER]
APPLICABLE STANDARD IS 3914(1967) [MOTOR STARTER STANDARD
GUIDELINE]
REACTOR AIR CORE TYPE 100% COPPER WINDING
REACTOR CONNECTION REACTOR TO BE IN SERIES ON LINE OF
MOTORS
STARTING CURRENT LIMIT 2-3 TIMES OF FLSC IN STEPS [DEPENDING
UPON LOAD TORQUE REQUIREMENT AND
SETTABLE AT SITE]
HARMONIC REACTORS USED IN SOFT STARTERS
CIRCUITS OF AIR CORE SHOULD NOT
DEVELOP HARMONIES IN THE CIRCUITS
DUTY CYCLE 6 NO EQUAL SPACED STARTS /PER HOUR
METHOD OF COOLING AIR COOLED
SPECIFICATIONS FOR OTHER ITEMS SHOULD BE EQUIPPED WITH REQUIRED
SWITCH GEAR PROTECTIONS AND INDICATIONS
3.3 PUMP WELL WATER LEVEL INDICATOR
One No. electrical water level indicator with alarming system shall be provided for the pump
well near which the pump house of sewage has been constructed.
3.4 CIVIL WORK
3.4.1 Construction of covered cable trenches / cable tray from L.T. panel to panel board in pump
house. The cable trenches should be covered with sand and type should be broken type
connected to bridge with bolts etc. by suitable civil work and shall be covered with chequered
plates of 7 mm (minimum) thickness.
3.4.2 Construction of all other allied civil works required for erection of pump and motor with all
foundation, bolts, nuts and washers including all work pertaining to it.
128
PART – 4.0 NON RETURN VALVE

4.1 GENERAL
The non-return valves shall be single door type, free acting quick opening, giving rapid non-clam
closure & with low head loss characteristics when in open position. The valves shall be provided with
by passes and isolating valves conforming to relevant Indian Standard.
Specification ofthe valves shall generally conform to IS : 5312(1986) (Part-II)
4.2 MATERIALS OF CONSTRUCTION
Body, Cover, Door and Hinges : Cast steel construction
Hinge pins, Door pins & Door : 12% Chromium steel conforming to IS:1570
Suspension pins
Bearing Bushes : Leaded Gun Metal Gr. 2, Conforming to
IS: 318
Body rings and door faces : Leaded Gun Metal Gr.2, conforming to
IS: 318
4.3 TESTING
The valves shall be subjected to closed ends tests as per relevant IS standard. Test certificate in
triplicate shall be furnished. If necessary, test shall be witnessed by the Engineer's representative.
WORKING PRESSURE : 20 KG/SQ.CM.
TEST PRESSURE BODY : 40 KG/SQ.CM.
SEATING : 20 KG/SQ.CM.
129
PART – 5.0 DELIVERY PIPES

5.1 GENERAL
The scope of the work is providing, laying & jointing of all delivery pipes, specials valves of all
the pump and their connection to the common manifold as shown in drawing inclusive of the
jointing of the manifolds to the respective conveyance mains.
5.1.1 The contractor shall design and fabricate the common manifold which would be made out of
6mm thick MS plates conforming to IS : 2026(2011)in such a way that it gives minimum
frictional loss of head to the flow of water and also avoid cavitations or vortices in the
manifold. The manifolds should be in line and coated with suitable material to protect it from
corrosion in case of sewage.
5.1.2 The contractor shall provide an expansion joint of his own design duly
approved by the Engineer-in-charge.
5.1.3 Flanged joints shall be adopted for valves and butt welding joints or flanged joints in jointing of
delivery pipe with dismantling joints.
5.1.4 Concrete saddles for valves and thrust blocks shall be provided by the contractor as per the
design and drawings to be furnished by the contractor and subsequently approved by
Engineer-in-charge.
5.2 MATERIAL OF CONSTRUCTION
All the pipes of works shall be fabricated out of steel plates conforming to IS:2026-2011. The
fabrication of pipes shall generally conform to IS: 3589-2001.
5.3 TESTING
The pipes and common manifold shall be hydraulically tested to a pressure of 2 times the
working pressure. Test certificate to that effect shall be furnished by the contractor.
The Engineer-in-charge witness the above test if so desired, the contractor shall arrange for
such test in presence of Engineer-in-charge.
130
PART –6.0 RATING AND NAME PLATES

6.1 RATING PLATE
Each main and auxiliary item of plate shall have permanently attached to it a rating plates in a
conspicuous position. This shall be a non-corrodible material preferably chromium plates
steel. The inscription shall be engraved in black on the plate.
6.2 NAME PLATE
6.2.1 Each item of plant shall be provided with a name plate or label designating the service of the
particular equipment. The shape and size of the plate and inscription shall be approved by
6.2.2 Such name plate shall be non-corrodible material preferably chromium plated steel having
engraved black lettering.
6.2.3 In case of indoor equipment like circuit breakers, starters etc. the plate shall be of transparent
plastic material with black lettering engraved on the back.
6.2.4 The name plate shall be screwed to the body of the equipment.
131
Chapter 6
DETAILED TECHNICAL SPECIFICATION FOR SUITABLE ELECTRIC SUB STATION (for
each STP)
1.0 LOCATION OF WORK:-
Providing, supplying, erection and commissioning of Transformer of 100 KVA, or suitable
rating to be installed in an electric sub-station of 33KV/0.44 KV located at STP.
2.0 SCOPE OF WORK
The Scope of works includes design, supply erection construction commissioning and testing
of 100 KVA, electric substation (as per I.E. rules and specification) which mainly includes
supply of transformer, outdoor, substation structure, cables, other electrical equipment,
accessories, and other allied required civil work etc. complete.
The details specifications of the proposed work are given below. However specifications laid
down in relevant standards shall be strictly followed.
2.1 SUB STATION STRUCTURE AND ASESSORIES. :-
33/0.44KV outdoor substation comprising of 2 pole substation structure made of Double M.S.
Girders & channels of adequate section (not less than ISHC 200x10 and ISMB 100x50) and
length, with provision of 33 KV lightening arrester, A.B. switch, D.I. set, disc and post
insulators with hardware substation premises as per I.e. rules. Structure shall be complete
with necessary painting of primary red oxide and finished with two coat of aluminium paint.
2.2 TRANSFORMER
One number transformer each of rating 100 KVA, at STPs,
Double earthing of entire electrical system connected to earthing plates buried in ground and
surrounded in charcoal and salt up to adequate depth. The contractor shall have to carry out
earth continuity tests earth resistance measurement and all other required test in the
presence of Engineer-in-charge, which are necessary to prove that complete job of earthing
system is already in working conditions. Rectifications, if any, is also to be done.
2.4 CIVIL WORK:
All related civil works such as construction of transformer plinth, foundation of substation
structure, partition wall between transformer, earth pits, cable trenches/cable trays, cable
markers, foundation of Fencing pole structure, providing and spreading 40mm B.T. metal as
per I.E. Rules complete job.
2.5 FENCING FOR 33 KV SUBSTATION YARD.
Industrial yard fencing arrangement using 65 mm x 6mm angle iron post complete as per I.E.
rules complete job if require at site
2.6 LIGHTING:-
Substation yard lighting provision in panel.
2.7 SUPPLY OF SAFETY DEVICES:-
Supply of safety devices like rubber mating, hand gloves, first Aid box, danger boards, first
Aid, charts, 0.5 Kg. Capacity Co2 type fire extinguishers and sand buckets etc. complete
required as per specification and I.E. rules One set.
2.8 OPERATION OF SUB STATION:
The contract include as Operation and Maintenance (O&M) of the contract includes
substation after commissioning and training to departmental staff for 7days complete job.
2.9 ANY WORKS Equipment not specified in particular but considered necessary to complete
the work as per specification and I.E. Rules are also included in this TENDER and scope of
works.
2.10 PANEL INSTLATIONS;
Panel is to be installed in substation or at place specified by the Employer/Engineer-in-
Charge.
3.0 IMPORTANT CONDITIONS:-
132
3.1 The BIDDER shall submit the brand names, & efficiencies at various at various points and
design calculation for each and every equipment so as to assess and decide suitable offer.
3.2 A licensed class A electrical contractor authorized under I.E. Rules shall only carry out the
work.
3.3 The Successful BIDDER on award of contract shall have to prepare and submit the detailed
drawing of the work duly approved by the Chief Electrical Inspector and Electrical Adviser,
Govt. of M.P. After completion of work the representative of the Chief Electrical Inspector
and Electrical Adviser shall inspect the same. The inspection fee shall be borne by the
contractor and electrical substation shall be charged only after approval and permission of
the competent authority as per I.E. Rules.
3.4 Supply and inspection of all the equipment shall be as per relevant BIS/IS/ISO Specification
and latest I.E. Rules.
3.5 Make, Materials, Technical specification, Circuit diagrams and connection details of each
and every equipment and its major parts offered should be as specified in the TENDER.
3.6 Test certificates guarantee, certificate and operation manual shall be submitted along with
the supply of equipment.
3.7 After commissioning of all the equipment successful trial will have to be given for at least 72
Hours.
3.8 Maintenance and training of department staff:-
After installation, commission and official testing of electric substation and other equipment
satisfactorily, the contractor shall have to run and maintain and electric substation to the
complete satisfaction of the Engineer in charge for a period of at least 7 days round the clock
through his experienced and competent staff under supervision of his experienced and
qualified engineer.
3.9 Any work equipment not specified in particular but considered necessary to complete the
works as per specification and I.E. Rules are also included in this TENDER.
4.0 DESIGN DATA:-
4.1 All the equipment shall be designed for operation in tropical humid climate subject to heavy
rainfall and frequent thunderstorms with ambient air temperature of 50 deg. 0c (max)
4.2 The single line diagram of proposed 33 KV/0.44 KV substation, main electric panel board,
bus bar is shown in separate drawing which can be seen in the office. The proposed site
plan showing the relative location of substation with respect to pump house are shown in
separate drawing, which can be seen in office. The above drawing is only for the guidance of
the BIDDER.
4.3 The rating and specification of transformers and other electrical equipment shown in the
drawing and specification are indicative only The BIDDER shall check-up the rating of the
equipment and satisfy thoroughly regarding their adequacy.
4.4 All the materials used in this work must be strictly in accordance with the relevant BIS/IS/ISO
specification and I.E. rulers.
4.5 On completion of work, the contractor shall submit the completion drawing. Circuit diagram
and detailed electrical mechanical drawing of the equipment and the maintenance manuals in
form as desired by the Engineer-In-Charge.
5.0 DETAILED TECHNICAL SPECIFICATION:

5.1 TRANSFORMER:-
(a) 100 KVA,33/ 0.44 KV,3 phase, 50 Hz Oil immersed, Natural selfcooled type Onan, core type
with class "A" insulation, double wound with off load tape changer outdoor distribution
transformer with accessories designed and manufactured with particular reference to tropical
condition conforming to IS 1026: 1981 as per IE rules and as per detailed specification.
133
Rating 100 KVA, OR OF SUITABLE RATING

No load voltage ratio (HV/LV 33 KVA/0.44 KV
Winding materials Copper
No of phases Three
Vector Dy 11
Connection On (HV/LV) Delta Star
Frequency 50 Hz
Installation Outdoor
Type of cooling Onan
Temperature rise in oil by thermometer 45 Deg. C
In winding of resistance 55 Deg. C
Terminal Arrangement
*(a) Primary Bare
(b) Secondary Weather proof bare bushing
Type of tap changer Off load top changer
Tapes step on HV +5% - 5% in steps of 2.50%
Fitting and accessories shall be provided as per IS 2026: 1981
5. 2 CONSTRUCTION:
5.2.1 CORE:-
The core shall be of C.R.G.O. annealed steel materials having low losses and good grain properties,
bolted, together to the frames firmly to prevent vibration and noise,
5.2.2 WINDING:-
Winding shall be made out of electrolytic grade copper paper covered wire strips. Generally H.V.
winding shall be cross order of disc type with paper covered conductor and the L.V. winding, shall be
cylindrical type disc or helical type depending upon the voltage currents.
5.2.3 TANK:-
Transformer tank shall be robust construction and shall be fabricated with M.S. plate proper
enforcement shall be provided so as to ensure that no building occurs during service.
5.2.4 FITTING AND ACCESSORIES:-
All the fitting and accessories as mentioned below shall be of the good quality and confirming to
Relevant IS/BIS/ISO specification.
1. Rating and diameter gram plate.
2. Earthing terminals
3. Lifting lugs
4. Off load tape changing switch
5. Drain cum sampling valve wit plug.
6. Conservator with oil level gauge
7. Thermometer
8. Air release plug.
9. Silica gel breather.
10. Bucholes relay
11. Radiametertor.
134
5.2.5 PAINTING:-
Tank and core clamp and other fitting exposed to the oil shall be painted by heat and oil resistant
paint. the exterior of the transformer and other ferrous fitting shall be first thoroughly cleaned,
scraped and ten given two coats of zinc chromate, red oxide, primer following by two finishing coats
of synthetic enamel paints as per shade No.631, of IS 5/1978.
5.2.6 DRAWING:-
Three copies of GA drawing showing details dimension and position of fitting and accessories
shall be submitted with equipment.
i. Indicating lamps for breaker ON/OFF Spring charge trip circuit healthy.
ii. Alarm Bell for S/C and E/F indication.
iii. Push button for test /reset/acknowledge.
6.0 PANEL BOARD
The LT AC Switch Board shall be of 3 phase and neutral 50 Hz Distribution board, indoor
type, sheet clad by 1.5mm thick CRC sheet over S channel structure frame, floor mounted
free standing type, cubical pattern, dust & vermin proof having protection group IP 53, and
shall comprise of following.
1 Nos. of incoming ACB OF suitable rating make L&T Siemens, Alstom
C&S and Schneider
1Nos. SFU OF suitable rating
- 1Nos. off 144 sq. mm flush tie ampere meter with selector switch.
- 1Nos. set of Indication Lamps for all three phase, On OFF auto Trip.
- 1 Nos. set of CT for protection and metering.
- 1 Nos. of solid state Triple pole on directional IDMTL over load and earth fault relay.
- The bus bar shall be suitable for 3 Phase and applicable amps. The bus bar shall be with
colored insulated sleeves. The supports shall be suitable spaced to give mechanical rigidity
for with standing stress due to system fault. The panel compartments shall have adequate
space for termination of incoming and outgoing feeder cables equipped with gland, lugs etc.
7.0 CABLES:-
Power cable of PVC, aluminum armored cable of size 3x400mm with require lugs gland.
Total to be considered for lump sum offer is 20 meter each from transformer to panel.
Control cable of PVC, copper cable of size 1 x 2.5 sq.mm x 3 and 6 core with required lugs,
glands. Total length to be considered for lump sum offer is 50mtr, for various connections.
Unit’s rates of cable to be quoted for any addition as required at time of execution.
8.0 SUB STATION STRUCTURE ADN ACCESSORIES.
8.1 33/0.44 KVA outdoor substation comprising of suitable substation structure and other
required substation material as given below:
8.2 SUB STATION STRUCTURE:-
Substation structure extension made of 1 Nos. of two pole structure made out Two Nos. of
200xc 100mm M.S. channels fabricated and welded using 33 x 5 mm. M.S flat to make one
pole of substation total substructure have our poles MS channels shall be not less than 100x
50mm and length as required to complete the substation structure, clamps, nut bolts and
other necessary MS Material as required for construction of substation structure. These
structures shall be made as per detailed drawing enclosed.
8.3 33 KV LIGHTNING ARRESTERS:
Station class 1- KA rating, single pole lightning arrester for use of 33 KV solidly ground
natural system and suitable for pedestal mounting complete with bolts and nuts. One SET of
three numbers.
135
8.4 AIR BREAK SWITCHES:-

Air break switches 33 KV 400 amp. Triple pole with earth blades, gang operated, double
break isolators suitable for horizontal mounting, complete with locking arrangement in both
On/Off position post type insulators operating pipe arcing horns, hand operated machismo.
The isolators will be complete with fixing bolts and nuts and all hardware parts shall be hot
dip Galvanized.
8.5 DROP OUT FUSES:-
Drop out fuses 33 KV outdoors drop out fuse cut out of expulsion type compete with
insulators mounted on bas channels and suitable for cross arm mounting for a working
current up to 400 amps. Complete with fuse holders, fuse elements and operating rod. All
hardware pa5rts shall be hot dip galvanized each set comprise for 3 Mps single pole drops
fuses. The drop out fuse set shall be for control of 500 KVA Transformer Primary One set.
8.6 POST PIN AND DISC INSULATORS:-
33KV disc insulator complete with hardware.
33 KV pin post complete with GI pin
8.7 ALUMINUM TUBULAR BUSBAR.-
Aluminum tabular bus bar required for internal connection of 33 KV equipment such as
transformer Isolator, DO fuse etc. Jumpers, Terminal connectors connection supports.
Insulators bolts nuts etc complete
8.8 PAINTING
Structure shall be complete with necessary painting of primary red oxide and finished with
two coat of aluminum paint.
9.0 SHIFTING OF TRANSFORMER
There is no work of shifting of old transformer.
10.0 CIVIL WORK
All related civil work such as construction of transformer plinth foundation of substation
structure earth pits cable trenches/ cable trays, cable markers, providing and spreading 40
mm BT metal as per IE rules complete job.
11.0 EARTING SYSTEM:-
Double earthing of entire electrical system connected to earthing plates buried in ground and
surrounded in charcoal and salt up to adequate depth, where damaged earth is encountered
at a distance of 2 meters from any permanent structure shall be provided. It shall also include
digging of pits earth plates as per latest IS, watering pipe with funnel of required length and
diameter earth strip per without kinks lugs and clamps, salt and charcoal earth chamber etc
as per EI rules the contractor shall have to carry out earth continuity tests, earth resistance
measurement and all other required test in the presence of the Engineer in charge which in
his opinion are necessary to prove that the system is in accordance with design specification
and as per IE rules complete.
11.1 EARTHING MATERIAL
Copper earthing plate of size 3.15 x 600x 600mm 6 nos
Copper earthing strip 50x 5 mm as required
GI earthing plate of size 6.3 x 600x600mm
GI earthing strip 50 x 5mm as required for earthing arrangement
CI main hole cover for earthing pits.
GI pipe for earthing pits 50 mm diameter of length 1.5 meter
Funnel and other required earthing materials as per IE rules & IS
12 FENCING FOR 33 KV SUBSTATION YARD

Industrial type fencing arrangement using 65 mm x 6mm angle iron post each of 3 meter
height fixed as required at a spacing of 2 meter with 2 meter high GI chain link wire mesh
136
fencing of minimum opening of 75mm x 75mm 2 meter wide main gate with locking
arrangement and etc complete as per IE rules complete job.
13 LIGHTING
Substation lighting provision in panel is to be done.
14 SUPPLY OF SPARES
Supply of essential spares like DO fuses, HRC fuses indication lamps cable lugs for
maintenance one set
15 Supply of essential tools
Supply of essential tools and equipment like DO operating rod earthing rod sets, required for
operation of substation helmet HD one set of each item.
16 SUPPLY OF SAFETY DEVICES:
Supply of safety devices like rubber mating gloves, first Aid box leather apron danger boards,
first and charge 0.5 kg capacity CO2 type fire extinguisher and sand buckets etc complete
required as per specification and IE rules one set.
137
Chapter 7
Specification Road Work
The specification for road work shall be governed by “Specifications for Road and
Bridge works, (5th Revision, 2013) Ministry of Road Transport and Highways, Govt. of
India”.
The Sections- 200,400,500 and 600 of specifications for Road and Bridge works,
(5th Revision, 2013) Ministry of Road Transport and Highways, Govt. of India and
relevant IRC codes shall also apply.
138
Chapter 8
Suggested Brands of Equipment
The equipment of following brand shall be required & accepted.

S. No. Equipment Acceptable makes
1. Transformer NGEF, Crompton, Alstom, Kirloskar,Voltemp, btcl,
TESLA
2. 33 KV VCB CROMPTON, ALSTHOM, ABB, JYOTI, SIEMENS,
BHEL, NIEPE-BANGLORE
3. AIR CIRCUIT BREAKER L & T, SIEMENS, ABB, JYOTI, CROMPTON, C & S
4. CTS PTS CROMPTON, ALSTHOM, UNIVERSAL, JYOTI,
C&S
5. 33 KV LIGHTING ARRESTER IGE, OBLUM ALPRO, CROMPTON
6. RELAYS L & T, SIEMENS, ABB, JYOTI, C&S
7. AIR BREAKS SWITCHES SIL, WSL, KIRON TEXTILE
8. POST AND DIS INSULATORS SIL, WSI, KIRON TEXTILE, ATLAS JAIPURIA,
JYOTI
9. ALUMINUM TUBULAER BUSBAR AS PER IE RULE AND AS PER RELATIVE
STANDARD
10. CABLES FINOLEX UNIVERSAL HAVELLS NICCO CCI
11. DROP OUT FUSES SIL, WSI, KRON TEXTILE, ATLAS, JAIPURIA
12. EARTHING MATERIAL AS PER IE RULES AND AS PER RELATIVE
STANDARD D
13. SAFETY DEVICE AS PER IE RULE AND AS PER RELATIVE
STANDARD
14. METERS AE, MECO, Secure meters,Genius
139
The following manufacturers are recommended to be used for the proposed work. The Bidders may substitute
alternative equivalent brand names with prior approval of Engineer in charge.
Item / Component Recommended makes
VT and Centrifugal Pump Kirloskar / Jyoti / Mather+Platt / WPIL/ Darling /Aqua
Pump motor
KEC/Kirloskar/ Jyoti / Crompton / ABB / Alstom / Siemens
Krohne-Marshall / Yokogawa / Emerson- Rosemount.

Electro Magnetic Flow Meter
Sluice Valve / Scour Valve/Butterfly Kirloskar / IVC / VAG / IVI / MARCK/ FOURESS
Non-return / Check Valve Kirloskar / IVC / VAG / IVI / MARCK
Kinetic Air Valve Kirloskar / IVC / VAG / IVI / MARCK
Valve Actuator Auma / Rotork / Limitork
Single faced Sluice Gate / Stop-log Kirloskar / JASH / VAG
Flow & Pressure regulating Valve Darling Muesco / VAG / Keystone
Electro-magnetic Flow meters – Battery operated Emerson / Krohne Marshall / Yokogawa
Water Hammer Control Sureseal or equivalent
D.I. pipe Specials & Fittings Electrosteel / KISWOK / Jindal / Kejariwal
Electro-fusion & Compression fittings Glynwed / Georg Fisher/Astore/Magnum
Power Transformers ABB / Crompton / Emco / Siemens / Alstom
HT Switch Gear Alstom / Jyoti / Crompton / Siemens
Vacuum Circuit Breaker (VCB) Siemens / Schneider M.G. / Jyoti / L & T
Air Circuit Breaker (ACB) Siemens / Schneider M.G. / Jyoti / L & T
Moulded Case Circuit Breaker MCCB Siemens / Schneider M.G. / Jyoti / L & T
Soft starters Siemens / Alstom / Jyoti / ABB
Relay and Contactors Siemens / Alstom / Jyoti / ABB / L&T
Tropodur / Finolex / Asian / Gloster / Incab / Universal /

Cables
Polycab
EOT crane
Hitech / Indef / Hiking / Ambika
140
FOR INSTRUMENTATION, AUTOMATION AND SCADA SYSTEM :

Programmable Logic Controllers (PLC) Rockwell (Allen Bradly) / Siemens / Honeywell
Panel Enclosures and Consoles Rittal / President / Cutler Hammer
Ultrasonic Type Level Measurement Device Endress+Hauser / Krohne Marshall / Hycontrol UK.
Float & Board Type Level Measuring system Nivo (Toshniwal), Endress + Hauser, Pune Techtrol
Switch fuse Disconnector L & T, FN Type, Siemens, GEPC
Multi-Function Energy Meters Enercon, L & T, SOCOMEC
Capacitor bank Crompton Greaves, Khatau Junker, Malde, L &T
Cable Termination kit Raychem, Denson, M-Seal
Battery HBL NIFE, Exide, Amco
Battery Charger Chaabi Electrical, Masstech
Tacho Meter on line Kana Electric, Proton, Jay Shree Electronics
Pressure switch Indfoss, Switzer,Tag Process Instruments
Flow switch Switzer, General Instrument,Forbes Marshall
Pressure gauge WAREE, WIKA, AN Instruments, Guru, Hitek
Emerson, Foxbro, Druck, Endress – Hauser, ABB, Honeywell
Pressure Transmitter
Automation
Engineering cum Operator work Station IBM, Compaq, Dell
Printer EPSON, HP, CANNON, WIPRO
Local Supervisory Station IBM, Compaq, Dell
HMI Software Wincc, Rs View, Monitorpro, Intellution, Indusoft
Alarm Annunciator Minilec, Peacon, ICA, APLAB
Uninterruptible Power Supply HI-Real, Pulse, Tata Libert, APC, APLAB
Instruments & Control Cables Delton, Asian, Servel, TCL, Thermopad
Receiver Indicator/Digital panel meter Masibus, Yokogawa, Lectrotek, NISHKO, SaiTech, MTL INSTS
Intercom system Betel, Samsung, Tata, Panasonic, Matrix
Conductivity level switch Pune techtrol, Krohne Marshall, E+H
Multifunction power monitor MASIBUS, L&T, ENERCON, SOCOMECH, SECURE, DAE
Temperature Scanner SaiTech, Masibus, Nishko, Lectrotek
Analog Signal Multiplier MASIBUS, Sai Tech, MTL INSTS, NISHKO
Portable vibration measuring equipment Shrenk Every, IRD, STM Instrument, TIME
Portable sound measuring equipment CENTER, MECORD, CYNGET

Ujjain Sewera

Uploaded by

Copyright:

Available Formats

Ujjain Sewera

Uploaded by

Document Information

Original Description:

Original Title

Copyright

Available Formats

Share this document

Share or Embed Document

Sharing Options

Did you find this document useful?

Is this content inappropriate?

Copyright:

Available Formats

Ujjain Sewera

Uploaded by

Copyright:

Available Formats

1

OFFICE OF THE UJJAIN MUNICIPAL CORPORATION, UJJAIN, DIST. - UJJAIN

NIT Number and Date :-----------

Name of the Contractor : ______________________________________

Probable Amount of Contract

(Rs. In Figure) : Rs 36752.57Lacs

(Rs. In Figure) : ________________________________________

(Rs. In Words) : ________________________________________

Stipulated Period of Completion: 36 months including rainy season

OFFICE OF THE UJJAIN MUNICIPAL CORPORATION, UJJAIN, DIST- UJJAIN

Notice Inviting e-Tenders

NIT No. 3407/e-tendering Date: 19-04-2017

Survey, Investigation, Design, Construction, Testing and

1. Interested Bidder can view the NIT on website http://www.mpeproc.gov.in.and www.mpurban.gov.in

Notice Inviting e-Tenders

NIT No. 3407/e-tendering Date: 19-04-2017

S.No. Name of the work Probable Earnest Cost of Category of Time of

The essence of this sewerage project shall be,

a) Providing 100% coverage to un-sewered area of Ujjain town.

2. General Quality of Work:

10. Any other document(s), as specified.

Bid Data Sheet

For Section 2 - ITB

Clause Particulars Data

Performance security & Additional Valid contract period plus 3 months

(See clause 1, 7 of Section 1 NIT)

Financial Bid Open

Signature with Seal of the Deponent (bidder)

Signature with Seal of the Deponent (bidder)

i. Providing, laying, jointing of sewer pipeline of any material or nature

Minimum Physical Requirement

SPECIAL ELIGIBILITY CRITERIA

Enclosed after Annexure – Y

3.0 RCC Sump 109

4.0 Sewage Treatment plant 112

5.0 Pumps for sewage pumping

Part I Non Clog Submersible pumps 121

Part II Specifications for 415 V induction motors 123

Part III Cabling and motor control panel 125

Part IV Non Return valves 126

Part V Delivery Pipes 127

Part VI Rating and Name Plates 128

6.0 Electric Sub-Station 129

7.0 Specifications of Road 135

8.0 Suggested Brands of Equipment 136

Procedure for participation in e-Tendering

1. Registration of Bidders on e-Tendering System

3. Set Up of Bidder’s Computer System:

5. Preparation and Submission of Bids

6. Purchase of Bid Document

7. Withdrawal, Substitution and Modification of Bids

7. The partners of J.V. should satisfy the qualification criteria as below,

Signature of Bidder with Seal

Envelope – B, Technical Proposal

Annexure – I (Format: I-1)

FINANCIAL & PHYSICAL EXPERIENCE DETAILS

To be filled in by the contractor:

Agreement Name of Date of Date of Amount of Employer's