BOARD OF ARCHITECTURE

Board Resolution No. ____ Series of 2009

REPEAL OF THE 1979 STANDARD OF PROFESSIONAL PRACTICE (SPP) DOCUMENTS COVERING PROFESSIONAL ARCHITECTURAL SERVICES

WHEREAS, the Professional Regulation Commission (the Commission) approved and promulgated on 24 September 1979 the Board of Architecture Resolution No. 9-A, Series of 1979 adopting the United Architects of the Philippines (UAP) Document Nos. 200 through 208 as the National Code for Architects and as part of the rules and regulations of the repealed architecture laws (R.A. No. 1581 of 1956, amending R.A. No. 545 of 1950);

WHEREAS, the said 1979 Standards of Professional Practice (the SPP) as published IRR to the repealed architecture laws are public documents for which no copyrights apply;

WHEREAS, since the SPP documents are specifically mentioned under several provisions of R.A. No. 9266 (The Architecture Act of 2004), which took effect on 10 April 2004, the Professional Regulatory Board of Architecture (the Board), in collaboration with the Integrated and Accredited Professional Organization of Architects (IAPoA) and other architectural organizations, have taken steps in recent years to amend or repeal the 1979 SPP documents;

WHEREAS, the Board, the IAPoA and various architectural organizations have completed the repeal version of the SPP documents on 23 October 2009;

NOW, THEREFORE, the Board hereby RESOLVES, as it is hereby RESOLVED, to promulgate the repeal version of the SPP documents, as part of the Implementing Rules and Regulations (IRR) of R.A. No. 9266, which all Philippine registered and licensed architects (RLAs) must continually study, observe, fully comply with and uphold.

This Resolution shall take effect after fifteen (15) days following its full and complete publication thereof in the Official Gazette or in a newspaper of general circulation in the Philippines.

Done in the City of Manila this )_23rd day of October 2009.

ARMANDO N. ALL
Chairman

ANGELINE T. CHUA CHIACO

MARIETTA B. SEGOVIA

Member

Member

ATTESTED TO:

CARLOS G. ALMELOR
Secretary, Professional Regulatory Boards

APPROVED:

NICOLAS P. LAPEA, JR.

RUTH RAA PADILLA

NILO L. ROSAS
Commissioner

09oct23_SPPdocuments

STANDARD OF PROFESSIONAL PRACTICE (SPP) (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004)

STANDARDS OF PROFESSIONAL PRACTICE (SPP)

Document No.

201 202 203 204 205 206 207 208 209 210

PRE-DESIGN SERVICES DESIGN SERVICES SPECIALIZED AND ALLIED SERVICES CONSTRUCTION SERVICES POST-CONSTRUCTION SERVICES COMPREHENSIVE ARCHITECTURAL SERVICES DESIGN-BUILD SERVICES SELECTION OF THE ARCHITECT AND METHODS OF COMPENSATION COMPETITION CODE STANDARD GUIDELINES ON CONSULTING SERVICES

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 201 : PRE-DESIGN SERVICES (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004) 1. INTRODUCTION 1.1The basic services provided by the registered and licensed architect or RLA (hereinafter referred to as the Architect) have remained relatively unchanged over the years. However, the Architect must expand his services in response to the increasing demands of his/her Clients, the evolution of new standards of regulated professional practice, the advancement of technology and the enactment of new laws. 1.2 It will be most advantageous to the Client to involve the Architect in the earliest stages of the project since the Architect, if suitably experienced, can provide the Client with objective project analysis and can establish parameters to optimize building needs vis--vis available resources and attendant constraints.

2. SCOPE OF PRE-DESIGN SERVICES The Pre-Design Services cover a broad line of architectural services ranging from initial problem identification through activities that would allow the Architect to initially conceptualize an array of architectural and allied solutions. The Pre-Design Services nominally include consultation, pre-feasibility study, feasibility study, site selection and analysis, site utilization and land-use studies, architectural research, architectural programming, space planning, space management studies, value management, design brief preparation, promotional services and other related activities. 2.1 Consultation When a Client calls upon the Architect to give oral or written advice and direction, to attend conferences, to make evaluations and appraisals regarding a contemplated project and similar activities, the Architect renders valuable inputs whether or not the Client pursues the project. 2.2 Pre-Feasibility Study This preliminary study involves the procurement, analysis and use of information gathered for the project to aid the Client in early decision-making. This study represents the Architects initial assessment of a projects soundness, allowing the Client to promptly explore available/ readily identifiable directions/ options. Researched/ processed/ validated secondary data are generally used for such studies, e .g. electronic, print, etc. 2.3 Feasibility Study This detailed analysis of the project based on the pre-feasibility study will determine the viability of a proposed development. The study will set the project against present and future trends to forecast how it will perform over time. 2.4 Site Selection and Analysis This entails the formulation of site criteria and assistance to the Client in site evaluation and analysis to determine the most appropriate site/s for a proposed project or building program. 2.5 Site Utilization and Land-Use Studies The detailed analysis of the site involves the development of potentials through the proper utilization of land. The analysis covers the context of the site as well as that of the environment immediately outside.

2.6 Architectural Research Architectural research entails the conduct of primary and secondary researches and assembled facts used as basis for conclusion. 2.7 Architectural Programming This analytical problem-seeking process will lead to the statement and identification of both horizontal and vertical requirements in offering a solution. 2.8 Space Planning The Architect determines the adequate size and appropriate shape for a proposed project in consideration of the use, allocation and interface of spaces for given activities. 2.9 Space Management Studies An analysis of the space requirements of the project based on organizational structure and functional set-up pinpoints linkages and interaction of spaces. This will be adopted in the formulation of the space program and will serve as basis for the development of the architectural design. 2.10 Value Management This technique is applied in the cost management process to minimize the negative effect of simplified operations associated with many cost-reduction programs. The goal of value management is to achieve an unimpaired program at minimum cost. Thus, a plan, design or system that has been successfully value-managed will still satisfy the same performance criteria as the costlier alternatives. 2.11 Design Brief Preparation Under design brief preparation, the Architect states the project terms of reference (ToR) including the concept, objectives and other necessary requirements to bid an architectural project. 2.12 Promotional Services Projects may require promotional activities in order to develop and generate financial support and acceptance from governing agencies or from the general public. In such cases, the Architect can act as the agent of the Owner by producing and coordinating the additional activities necessary to complete the services. In all such activities, the Architect must maintain his professional status as the agent of the Owner. 3. MANNER OF PROVIDING SERVICES 3.1 After the initial meeting/ conversation/ correspondence with the Client, the Architect must submit his proposal on pre-design services, stating the following: 3.1.1 3.1.2 3.1.3 3.1.4 Scope of Works Manner of Payment Owners Responsibilities Other Conditions of Services

3.2 The Architect can render the services in the following manner: 3.2.1 3.2.2 As an individual Architect he must have special training and be knowledgeable in different fields to supplement his skills. Architects Own Staff It is possible for Architects (as natural persons) working in a single firm to specialize in a variety of ways. Many Architects and firms (juridical

persons) specialize without losing the generalist approach of the Architect or firm. 3.2.3 By Association, Consultation or Networking

Another common practice is consultation between an Architect and a firm of other disciplines, under the extended terms of the OwnerArchitect Agreement. 4. METHOD OF COMPENSATION 4.1 The criteria for computing the Architects compensation should be based on mutual evaluation of the amount of the Architects/ architectural firms talents, skill, experience, imagination, effort and time available for the project. 4.2 The amount of payment depends on the types and levels of professional services provided. More extensive services or a more complex or experimental project will require more effort from the Architect and add more value to the project. 4.3 Compensation on Pre-Design Services may be based on one or more of the following: 4.3.1 Multiple of Direct Personnel Expenses

This cost-based method of compensation is applicable only to noncreative work such as accounting, secretarial, research, data gathering, preparation of reports and the like. This method of compensation is based on technical hours spent and does not account for creative work since the value of creative design cannot be measured by the length of time the designer has spent on his work. The computation is made by adding all costs of technical services (man hours x rate) and then multiplying it by a multiplier to cover overhead and profit. The multiplier ranges from 1.5 to 2.5 depending on the office set-up, overhead and experience of the Architect and the complexity of the Project. Other items such as cost of transportation, living and housing allowances of foreign consultants, out-of-town living and housing allowances of the local consultants and the like, are all to be charged to the Client and reimbursed to the Architect. At the start of the commission, the Architect shall make known to the Client the rate of professionals and personnel who will be assigned to the Project and the multiplier that has to be applied before agreeing on this method of compensation. FORMULA Assume: A= C= T= Architects rate / hour Consultants rate / hour Rate per hour of Technical Staff, Researchers and others involved in the Project

AN, CN, TN = No. of hours spent by Architect,. Consultants and Technical Staff M= Multiplier to account for overhead and reasonable profit. The value may range from 1.5 to 2.5 depending on the set-up of the Architects office and the complexity of the Project. Reimbursable expenses such as transportation, housing and living allowance of Consultant, transportation, per diem, housing and living allowance of local consultants and technical staff if assigned to places over 100km. from area of operation of the Architect.

R=

Cost of printing of extra set of drawings, reports, maps, contract documents, etc. over the five (5) copies submitted to the Client, overseas and long distance calls, technical and laboratory tests, licenses, fees and taxes needed by the Project. Direct cost = AN + CN + TN Fee = Direct Cost x Multiplier Total Cost = Fee + R of Service charged to Client 4.3.2 Professional Fee Plus Expenses

This method of compensation is frequently used where there is continuing relationship on a series of Projects. It establishes a fixed sum over and above the reimbursement for the Architects technical time and overhead. An agreement on the general scope of the work is necessary in order to set an equitable fee. 4.3.3 Lump Sum or Fixed Fee This method may be applied to government projects since they entail more paper work and time-consuming efforts. 4.3.4. Per Diem, Honorarium Plus Reimbursable Expenses

In some cases a Client may request an Architect to do work which will require his personal time such as: a. attending board meetings or conferences; b. conducting ocular inspection of possible sites; c. conferring with others regarding prospective investments or ventures and the like For these particular activities, the Architect as agent of the Owner may be paid on a per diem and honorarium basis plus out-of-pocket expenses such as travel, accommodations and subsistence. 4.3.5. Mixed Methods of Compensation

The UAP Documents provide for more than one method of compensation on a project. Each project should be examined to determine the most appropriate method of establishing an equitable method of compensation between the Architect and the Owner. Sub-Committee: Norberto M. Nuke, fuap Amado E. Tandoc, Jr., uap Diogenes A. Barredo, fuap Potenciano C. Estanislao, fuap Maria Lisa V. Santos, fuap

Approved in the City of Davao this 23 rd day of October 2008. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL

Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 202 : ARCHITECTS DESIGN SERVICES (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004)

While these implementing rules and regulations (the IRR) specifically refer to the individual professional practice of the Architect as a natural person, the same may also apply to the Architects group practice as part of a juridical entity i.e. as a DTIregistered sole proprietorship or as a SEC-registered partnership or corporation, subject to full compliances with Sec. 37 of R.A. No. 9266 (The Architecture Act of 2004) and its 2004 IRR and of derivative regulations including Board Resolution No. 5, series of 2007 and other periodic issuances of the Professional Regulatory Board of Architecture (PRBoA or the Board) and of the Professional Regulation Commission (PRC or the Commission) as well as the DTI and the SEC (presently under the DTI). The offering or undertaking of these Architects professional services (the APS) by Foreign Architects (the FAs) are subject to full compliances with Sec. 38 of R.A. No. 9266 and its 2004 IRR and of derivative regulations including including Board Resolution No. 3, series of 2008 which calls for a local counterpart Architect for any FA and other periodic issuances of the Board and the Commission, as well as procedures/ requirements of the DoLE and the Bureau of Immigration and Deportation (BID) governing such FAs. The professional practice of the state-regulated profession of architecture in the Philippines, specifically for Projects on Philippine soil is only for RLAs whether practicing as a natural person or as part of a juridical entity. FAs practicing architecture in the Philippines for Projects on Philippine soil must first secure a temporary/special permit (TSP) and must work with a local counterpart Architect, who is a RLA. Business process outsourcing (BPO) firms which have been DTI- or SEC-registered in the Philippines to provide services for overseas clients are not authorized to provide architectural services for Projects located on Philippine soil unless they are PRCregistered architectural firms (RAFs) satisfying Sec. 37 of R.A. No. 9266 and its 2004 IRR and of derivative regulations including Board Resolution No. 5, series of 2007 and other periodic issuances of the Board and the Commission. 1. REGULAR SERVICES 1.1 The registered and licensed architect (the Architect), as a natural person in regular professional practice, normally acts as the Client/ Project Owner/ Project Proponent (the Owner)s adviser. The Architect translates the Owners needs and requirements into spaces and forms in the best manner of professional service he/she can render. 1.2 The Architects work starts at the very inception of the project when the Owner outlines the requirements for plan/ design translation. It ranges through his study and analysis of the various aspects of the Project (reference the SPP IAPOA Doc. 201 on Pre-Design Services), goes through the preparation of the necessary instruments of service and through the multitude of construction problems and does not terminate until the Project is completed and properly turned over to the Owner by the General Constructor (GC). 1.3 After the conduct and successful delivery of the Pre-Design Services, the Architect then renders services sequenced in four phases as follows: a. Schematic Plan/Design (SPD) Phase; b. Plan/Design Development (PDD) Phase; c. Detailed Design & Contract Documents (DDCD) Phase; and d. Project Implementation and/or Construction (PIC) Phase. 1.4 Schematic Plan/Design (SPD) Phase a. The Architect consults with the Owner and target end-users to ascertain the requirements of the Project and confirms such requirements with the said entities as needed. b. The Architect prepares the concept-level or schematic plan and design studies leading to a recommended solution including a general description of the Project for approval by the Owner. c. Submits to the Owner a Statement of Probable Project Construction Cost (SPPCC) based on current cost parameters. The Architect cannot guarantee the SPPCC since he/she does not control the many factors that go into competitive bidding nor the market prices of construction labor and materials. 1.5 Plan/Design Development (PDD) Phase a. The Architect prepares from the Owner-approved Schematic Design (SD) studies, the Plan/Design Development (PDD) consisting of exterior and interior

perspectives, preliminary site development/ floor/ reflected ceiling/ roof plans, sections and elevations, preliminary architectural designs and other drawings, together with the Outline Specifications i.e. collectively the preliminary architectural documents (PAD), to fix and illustrate the size and character of the entire Project in its essentials as to kinds of architectural elements and materials. While the types of structure, mechanical, electrical, electronics, communications, plumbing and sanitary systems, allied architectural works and such other work may be required for preparation in sync with the PAD, the same are best undertaken by other state-regulated professionals rather than by the Architect. Unless such separate state-regulated professionals are clearly under the Architects employ, the Architect shall not assume nor partake of their respective professional responsibilities nor civil liability. Moreover, R.A. No. 9266 (The Architecture Act of 2004) does not state that Architects can offer nor undertake such professional services. b. The Architect submits to the Owner an Updated Statement of Probable Project Construction Cost (USPPCC). Again, the Architect cannot guarantee the USPPCC since he/she does not control bidding/ market conditions. 1.6 Detailed Design & Contract Documents (DD&CD) Phase a. The Architect prepares from approved Design Development (DD) documents, the complete Contract Documents (CD) consisting of detailed designs and construction drawings, together with the Technical Specifications setting forth in detail the required architectural works. Similarly, the structural, electrical, electronics/ communications, plumbing/ sanitary, mechanical and other service-connected equipment as well as allied architectural works are best prepared by independent state-regulated professionals different from the Architect. b. The Architect prepares the Technical Specifications describing type and quality of materials, finish, manner of construction, instructions to bidders and the general and specific conditions under which the project is to be constructed. Again, the Architect cannot guarantee the DPCC since he/she does not control bidding/ market conditions. c. The Architect furnishes the Owner not more than seven (7) complete sets of the selected portions of the construction drawings,Technical Specifications and the DPCC or similar instruments i.e. abridged documents for the purpose of securing a building permit under P.D. No. 1096 (the 1977 National Building Code of the Philippines/ NBCP or its successor law/s). The Architect prepares the Tender Documents including but not limited to forms for contract letting, documents for construction, forms for invitation and instruction to bidders, forms for bidders proposals, general/specific conditions of contract, etc. The Architect separately furnishes a complete set of the said documents for purposes of bidding in as many complete sets as shall be required to conduct a successful bidding. The costs attendant to the preparation, packaging, reproduction and delivery of the said documents shall all be for the account of the Owner. While the Architect shall not be required to advance or in any way assume the costs of these documents, the Architect may loan the same to bidders at an amount sufficient to cover direct and indirect costs. Copies of the Contract and Tender Documents are only loaned to bidders and never sold to them. Per R.A. No. 8293 (Intellectual Property Code of the Philippines), the Contract and/or Tender documents issued to bidders remain the common property of the Architect and the Owner. Per the same law and likewise under R.A. No. 9266 (The Architecture Act of 2004), the Architect retains the sole copyright to the said documents. As such, the bidders must not reproduce nor use for unrelated purposes the said documents entrusted to them. The said documents shall be returned to the Architect together with the submitted bids. In the event of a bidders non-submission of bids, the said documents shall still be returned to the Architect. d. Similarly, the Architect submits to the Owner the Detailed Project Construction Cost (DPCC). based on possible changes in scope, requirements or market conditions.

e. The Architect assists the Owner in filing the required documents to secure approval of government authorities having jurisdiction over the plan and design of the Project. 1.7 Project Implementation and/or Construction (PIC) Phase a. The Architect assists the Owner in obtaining proposals from Constructors, in assisting in the preparation of the abstract of bids and in preparing and/or reviewing the general construction contract/s (GCC). b. When required in the Professional Service Agreement (PSA), the Architect shall make decisions on all claims of the Owner and the General Constructor (GC) and on all other matters relating to the execution and progress of work or the interpretation of the Contract Documents, prepares change orders, gathers and turns over the Owner written guarantees required of the GC or sub-constructors (SC). c. The Architect makes periodic construction supervision (PCS) visits i.e. at least twice (2x) a month to the Project during the PIC Phase to familiarize him/herself with the general progress and quality of the work and to determine whether the work is proceeding in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous 8-hour on-site supervision to check on the quality of the work involved and he shall not be held responsible for the Constructors failure to carry out the works in full accordance with the Contract Documents. During such PCS visits and on the basis of the Architects observations, he/she shall report to the Owner the defects and deficiencies noted in the work of Constructors, and shall reject and/or condemn work found failing to conform to the Contract Documents. e. Based on the Architects observations and the Constructors Applications for Payment, he/she shall help determine the amount owing and due the Constructor and shall issue corresponding Certificates for Payment for such amounts. These Certificates will constitute a certification to the Owner that the work has progressed to the state indicated and that to his best knowledge, the quality of work performed by the Constructor is in accordance with the Contract Documents. The Architect shall conduct the necessary inspection to determine the date of substantial and final completion and issue the final Certificate for Payment to the Constructor. f. Should more extensive inspection or fulltime construction supervision (FCS) services i.e. at least 8 hours on-site daily, be required by the Owner, a separate full-time supervisor shall be hired and agreed upon by the Owner and the Architect subject to the conditions provided in the Standard of Professional Practice (SPP) on Fulltime Construction Supervision (FCS). When the Architect is requested by the Owner to do FCS work, his/her services and fees shall conform to the same SPP. 2. PROJECT CLASSIFICATION 2.1 Professional architectural work varies in complexities and in the creative skill required to successfully meet the requirements of the Owner within the constraints of the technical, functional, economic, aesthetic and other considerations. 2.2 These considerations imply that each design Project can be appreciated and ultimately determined only on its own merits. 2.3 The following groupings of buildings are attempts to classify the same in accordance with each ones degree or complexity.. 2.4 Based on these groupings, the corresponding gradated scale of professional architectural fees (PAFs) is prescribed to be able to determine the fair remuneration for the Architect. 2.5 Unless the separate state-regulated professionals concerned are clearly employees of the Architect, the Architects fee must exclude the normal structural, electrical, electronic/ communications, plumbing/sanitary, mechanical engineering and allied architectural services and shall be determined by multiplying the percentage (%) indicated in the Schedule of RecommendedProfessional Architectural Fee (RPAF) for a specific group with the Statement of Probable Project Construction Cost (SPPCC). 2.6 The RPAF schedule herein indicated only contains recommended fees inasmuch as the Architectshall still take into consideration his professional standing in the architectural community and his professional experience to arrive at an equitable professional fee.

3. SCHEDULE OF THE RECOMMENDED PROFESSIONAL ARCHITECTURAL (RPAF)

FEE

3.1 GROUP-1 Buildings of the simplest utilization and character, which are without complication of plan/ design or detail and which only require a minimum of architectural finishes, engineering and allied architectural elements.. Armories Parking Buildings Bakeries Printing Plants Habitable Agricultural Buildings Public Markets Service Garages Freight Facilities Simple Loft-type Buildings Hangars Industrial Buildings Warehouses Manufacturing/ Industrial Plants Packaging and Processing Plants and other similar utilization type buildings STATEMENT OF PROBABLE MINIMUM BASIC FEE PROJECT CONSTRUCTION COST (SPPCC) (Architectural Services Only) P 50.0 Million and less........................................ 3.6 percent (%) Over P 50.0 Million to P 1,800,000 plus 3.0% P100.0 Million ..................................................... of excess of P 50.0 Million Over P 100.0 Million to P 3,300,000 plus 2.4% P200.0 Million ..................................................... of excess of P 100.0 Million Over P 200.0 Million to P 5,700,000 plus 1.8% P500.0 Million ..................................................... of excess of P 200.0 Million Over P 500.0 Million to P 11,100,000 plus 1.2% P1.0 Billion .......................................................... of excess of P 500.0 Million Over P 1.0 Billion ............................................... P 17,100,000 plus 0.6% of excess of P 1.0 Billion 3.2 GROUP-2 Buildings of moderate complexity of plan/design, requiring a moderate amount of research and of engineering and allied architecturaldesign. Art galleries Nursing Homes Banks, Exchanges and other Office/ Office Condominium Buildings Financial Institutions Parks, Playgrounds and Open-air Bowlodromes Recreational Facilities Call Centers Residential Condominiums Churches and Religious Facilities Police Stations City/ Town Halls and Civic Centers Postal Facilities College Buildings Private Clubs Convents, Monasteries and Seminaries Publishing Plants Correctional and Detention Facilities Race Tracks Court Houses/ Halls of Justice Restaurants/ Fastfoods Dormitories Retail/ Wholesale Stores Exhibition Halls and Display Structures Schools Fire Stations Shopping Centers Laundries & Cleaning Facilities Specialty shops Libraries Supermarkets/ Hypermarts Malls/ Mall Complexes Serviced Apartments Motels and Apartels Welfare Buildings Multi-storey Apartments Mixed Use Buildings and other structures of similar nature or use Showrooms/ Service Centers STATEMENT OF PROBABLE MINIMUM BASIC FEE PROJECT CONSTRUCTION COST (SPPCC) (Architectural Services Only) P 50.0 Million and less........................................ 4.2 percent (%) Over P 50.0 Million to P 2,100,000 plus 3.6% P100.0 Million .....................................................of excess of P 50.0 Million Over P 100.0 Million to P 3,900,000 plus 3.0% P200.0 Million .....................................................of excess of P 100.0 Million Over P 200.0 Million to P 6,900,000 plus 2.4%

P500.0 Million .....................................................of excess of P 200.0 Million Over P 500.0 Million to P 14,100,000 plus 1.9% P1.0 Billion ..........................................................of excess of P 500.0 Million Over P 1.0 Billion ............................................... P 23,100,000 plus 1.2% of excess of P 1.0 Billion 3.3 GROUP-3 Buildings of exceptional character and complexity of plan/design or requiring comparatively large amounts of research and of engineering and allied architectural design. Aquariums Laboratories/ Testing Facilities Nuclear Facilities Marinas and Resort Complexes Auditoriums Medical Arts Offices & Clinics Airports/ Wet and Dry Ports & Terminals Mental Institutions Breweries Mortuaries Cold Storage Facilities Observatories Telecommunication Buildings Public Health Centers Convention Facilities Research Facilities Gymnasiums Stadiums Hospitals and Medical Buildings Theaters and Similar Facilities Hotels Veterinary Hospitals Transportation Facilities and Systems and other structures of similar nature or use STATEMENT OF PROBABLE MINIMUM BASIC FEE PROJECT CONSTRUCTION COST (SPPCC) (Architectural Services Only) P 50.0 Million and less........................................ 4.8 percent (%) Over P 50.0 Million to P 2,400,000 plus 4.2 % P100.0 Million .....................................................of excess of P 50.0 Million Over P 100.0 Million to P 4,500,000 plus 3.6 % P200.0 Million .....................................................of excess of P 100.0 Million Over P 200.0 Million to P 8,100,000 plus 3.0 % P500.0 Million .....................................................of excess of P 200.0 Million Over P 500.0 Million to P 17,100,000 plus 2.4 % P1.0 Billion ..........................................................of excess of P 500.0 Million Over P 1.0 Billion ............................................... P 29,100,000 plus 1.8 % of excess of P 1.0 Billion 3.4 GROUP-4 Residences (Single-Detached, Single-Attached or Duplex, Rowhouses, Shop-houses), small apartments and townhouses. Minimum Basic Fee......................................... 10.0 percent (%) of the Statement of Probable Project Construction Cost (SPPCC) 3.5 GROUP-5 Monumental buildings and other facilities requiring consummate design skill and much precise detailing. Exposition and Fair Buildings Specialized decorative buildings Mausoleums, Memorials, Monuments and structures of similar nature or use Museums Minimum Basic Fee............................................. 10.0 percent (%) of the Statement of Probable Project Construction Cost 3.6 GROUP-6 Repetitive Construction of Buildings When the plan/design and related architectural documents of the Architect is reused for the repetitive construction of similar buildins, without amending the drawing and the specifications, the Architects fee is computed as follows: First (1st) structure................................................RecommendedProfessional Architectural Fee (RPAF) Second (2nd) structure .................................................80.0 % of RPAF Third (3rd) structure......................................................60.0% of RPAF Succeeding structures...........................................40.0% of RPAF

3.7 GROUP-7 Housing Projects When the Architect is engaged to undertake a HOUSING PROJECT involving the construction of several residential units on a single site with the use of one (1) set of architectural plan/ design, specifications and related architectural documents, the Recommended Professional Architectural Fee (RPAF) chargeable thereunder shall conform with the following: First (1st) Unit....................................................10.0 percent (%) of the Statement of Probable Project Construction Cost (SPPCC) of one (1) unit as RPAF From two to ten (2-10) units.................................RPAF of one (1) unit plus 36.0% of the RPAF for each additional unit Eleven (11) units and above...............................Fee for ten (10) units plus 18.0% of the RPAFfor each additional unit 3.8 GROUP-8 Projects involving extensive detail such as designs for built-in components or elements, built-in equipment, special fittings, screens, counters, architectural interiors (AI) and other detailed parts of appurtenances of buildings or structures and detailed site development planning (SDP) and/or design. Minimum Basic Fee............................................. 15.0 percent (%) of the Statement of Probable Project Construction Cost (SPPCC) 3.9 GROUP-9 For alterations, renovations, rehabilitations, retrofit and expansions/ additions to existing structures belonging to Groups 1 to 5 enumerated above, the compensation of services should be increased by 50.0 percent (%) or a total of 150.0% of the Recommended Professional ArchitecturalFee (RPAF). 3.10 GROUP-10 Where the Architect is engaged to render opinion or give advice, clarifications or explanation on technical matters pertaining to his/her profession, the Recommended Professional Architectural Fee (RPAF) chargeable thereunder shall not be less than Two Hundred and Fifty Pesos (P250.00*) per hour subject to increase depending on the extent and coverage of service required and the location where the Architect shall render his/her service/s. When rendering service as an expert witness, the Architects fee shall not be less than Seven Hundred and Fifty Pesos (P750.00*) per appearance regardlessas to whether the scheduled hearing took place or not. * All references to fixed amount shall refer to the value of the Philippine Peso as of August2009. Adjustment of the price shall be made at the time of the signing of the Architects contract of service. The amount excludes the cost of transportation and accommodations when and where required. Sixty percent (60.0%) of the amount shall be charged for the travel period in case of locations that are in excess of 50.0 kilometers of the Architects office (as stated in his/her letterhead). 4. PAYMENT SCHEDULE 4.1 Payments on account of the Architects basic services shall be as follows: a. Upon the signing of the Contract of Service (or Service Agreement), a minimum payment equivalent to five percent (5.0%) of the compensation for basic services. b. Upon the completion of the Schematic Plan/Design (SPD) Phase Services, but not more than fifteen (15) calendar days after submission of the SPD architectural documents to the Owner, a sum equal to fifteen percent (15.0%) of the Recommended Professional Architectural Fee (RPAF), based on the Statement of Probable Project Construction Cost (SPPCC) of the proposed building. c. Upon the completion of the Plan/Design Development (PDD) Phase Services, but not more than fifteen (15) calendar days after submission of the PDD architectural documents to the Owner, a sum sufficient to increase the total payments on the RPAF to thirtyfive percent (35.0%) of the RPAF computed upon the same SPPCC of the building as in (b). d. Upon the completion of the Detailed Design & Contract Documents (DD&CD) Phase Services but not more than fifteen (15) calendar days after submission of the DD&CD architectural documents to the Owner, a sum sufficient to increase the total payments on the RPAF to eighty-five percent (85.0%) of the RPAF, computed upon a reasonable SPPCC of the building as in (b).

e. Within fifteen (15) calendar days after the award/s of the Bid/s for the implementation/ construction of the proposed Project, the payment to the Architect shall be adjusted so that it will amount to a sum equivalent to eighty-five percent (85.0%) of the RPAF, computed upon/ adjusted to the winning Bid Price. f. Upon completion of the construction work, the balance of the Architects fee, computed on the Final Project Construction Cost (FPCC) of the completed building shall be paid. Should the building not be completed, the prorated amount shall be paid to the Architect by the Owner based on the agreed computation. 4.2 The Owner shall make partial payments during each of the various stages of the Architects work, upon request of the Architect, provided that such payments are within the framework of the manner of payments outlined above. 5. OWNERS RESPONSIBILITIES 5.1 Provide full information as to his/her/their requirements for the Project. 5.2 Designate when necessary, the representative authorized to act on the Owners behalf. Promptly examine documents submitted by the Architect and render decisions pertaining thereto promptly, to avoid reasonable delay in the progress of the Architects work. If there is no Project/ Construction Manager (PCM), observe the procedure of issuing orders to General Contractors only through the Architect. If a PCM entity is present, the Owner must instruct the PCM entity to promptly furnish a copy of the order/s to the Architect. 5.3 Furnish or direct the Architect to obtain at the Owners expense, a certified survey of the site, giving, as may be required, topographical and/or relocation surveys, grades and lines of streets, alleys, easements, encroachments, zoning, and deed/s of restrictions, boundaries, with dimensions and complete data pertaining to existing buildings, and other improvements and full information as to the available utility/service lines both public and private; and soil investigations/tests, borings and pits necessary for determining soil and sub-soil conditions. 5.4 Pay for all professional engineering services (PES) required for the Project apart form the structural, acoustical, chemical, mechanical, soil mechanics or other tests and reports as may be required for the Project. 5.5 Pay for design and consulting services on acoustic, communication, electronic, and other specialty systems which may be required for the Project. 5.6 Arrange and pay for such legal, auditing, and insurance counselling services as may be required for the Project. 5.7 Pay for all reimbursible expenses incurred in the Project as called for in Section 6 Other Conditions on Services and all taxes (not including income tax) that the government may impose on the Architect as a result of the services rendered by the Architect on the Project whether the services were performed as a natural person i.e. an individual practitioner or as a juridical entity i.e. as a sole proprietorship, partnership or corporation. 5.8 If the Owner observes or otherwise becomes aware of anything that may impair the successful implementation of the Project, he/she/they shall give prompt written notice thereof to the Architect. 6.0 OTHER CONDITIONS ON SERVICES 6.1 Conditions for the Recommended Professional Architectural Fee (RPAF) The RPAF referred to in Section 3.0 applies to construction work done by a General Contsructor on the basis of a Lump Sum Contract. Construction works that are let on cost-plus-fee basis, or on any basis other than the Lump Sum Contract, where the Architect has to render additional services shall be subject to additional compensation commensurate with the additional services required. Such additional compensation shall be in addition to the RPAF. 6.2 Other Professional Services The Architects fee excludes normal structural, electrical, electronics/communications, plumbing/sanitary and mechanical engineering services. Other services that may be needed in order to complete the Project such as services of acoustic and illumination engineers/specialists, mural painters, sculptors, interior decorators and landscape architects are to be recommended by the Architect for the owners approval and costs for the services are to be paid for separately by the Owner. 6.3 Scale Models, 3D Models and Animation (Walk-Through Presentation) The Architect may make and include scale and/or three-dimensional (3D) models of his plan/design as part of his preliminary work if he/she so deems the same to be necessary but no extra charge for such scale models shall be made by the Architect. However, if the Owner desires to have a scale and/or 3D model/ animation (walk-through presentation) of the final and approved plan/design for exhibition and display purposes, the Owner shall pay for the cost of said scale and/or 3D model or animations. 6.4 Per Diem and Traveling Expenses

A per diem of not less than P750.00* plus traveling and living expenses shall be chargeable to the Owner on any occasion where the Architect or his duly authorized representative shall be required to perform services at a locality beyond the radius of 50.0 kilometers from his established office (as appearing in the Architects letterhead). 6.5 Extra Sets of Detailed Designs and Contract Documents (DD&CD) The Architect shall furnish the Owner seven (7) complete sets of Detailed Designs and Contract Documents (DD&CD), Technical Specifications and related architectural documents. The cost of printing or reproduction of extra sets of DD&CD when required by the Owner or his/her/their representative/s is to be charged to and paid for by the Owner. 6.6 Changes Ordered by the Owner If the Architect is caused additional professional services, extra drafting or other office expenses due to changes ordered by the Owner after approval of the Plan/Design Development (PDD) architectural documents, the Architect shall be paid for such expenses and services involved. The amount of compensation and the extension of time for the completion of the changes to the PDD architectural documents shall be upon mutual agreement of both parties. ____________ *All references to fixed amount shall refer to the value of the Philippine Peso as of August 2009. Adjustment of the price shall be made at the time of the signing of the Architects contract of service. 6.7 Work Suspended or Abandoned If the work of the Architect is abandoned or suspended, in whole or in part, the Architect is to be paid by the Owner for the services rendered corresponding to the RPAF component due at the stage of suspension or abandonment of the work. The primary service of the Architect is the preparation of architectural plans/designs, specifications and other building construction documents which are actually sets of detailed instructions that shall serve as the basis for the General Constructor to implement/build the Project. Once the Architect has prepared all these documents, the Architect has completed the Detailed Design and Contract Documents (DD&CD) Phase of his services, which is equivalent to EIGHTY FIVE PERCENT (85.0%) of his/her work. The remaining FIFTEEN PERCENT (15.0%) of his work is broken down as follows: TEN PERCENT (10.0%) for the Architects liability under Article 1723 of the Civil Code -andFIVE PERCENT (5.0%) for the construction phase services which includes preparation of contract document forms and periodic construction supervision (PCS) visits during the Project implementation period.. When the OWNER therefore fails to implement the plans and documents for construction as prepared by the Architect, the Architect is entitled to receive as compensation the sum corresponding to EIGHTY FIVE (85%) PERCENT of his contracted RPAF. 6.8 Different Periods of Construction If portions of the building/s are erected at different periods of time, thus increasing the Architects construction phase period and burden of services, charges pertaining to services rendered during the construction phase shall be doubled. A suspension of construction for a period not exceeding three (3) months shall not be covered by this provision. 6.9 Services of Specialist Consultants If the Owner desires to engage specialist consultants, such consultants shall be with the consent of the Architect and the cost of their services shall be paid for separately by the Owner and shall not be deducted from the RPAF due the Architect. 6.10 Separate Services Should the Owner require the Architect to plan/design movable or fixed pieces of cabinets and other architectural interior (AI) elements, site development elements and other items of similar nature, the Owner shall pay the Architect in addition to the RPAF, a compensation in the amount of the Construction Cost of the above work. 6.11 Fulltime Construction Supervision (FCS) Upon recommendation of the Architect and with the approval of the Owner, fulltime construction inspectors as will be deemed necessary shall be engaged and paid for by the Owner. If no Project/ Construction Management (PCM) entity is present, the full-time construction inspectors shall be under the technical control and supervision of the Architect and shall make periodic reports to the Owner and to the Architect as to the progress and quality of the work done. 6.12 Estimates Any Statements of Probable Project Construction Cost (SPPCC), or any Semi-Detailed or Detailed Cost Estimates submitted by the Architect is accurate only up to a certain

degree. This is so because the Architect has no control over the cost of labor and materials, or the many factors that go into competitive bidding. 6.13 Government Taxes on Services The Architects Fee as stipulated in Section 3 Recommended Professional Architectural Fee (RPAF) is net to the Architect. Any tax that the national and/or local government/s may impose on the Architect as a consequence of the services performed for the Project (exclusive of income tax) shall be paid by the Owner. 6.14Ownership of Documents All designs, drawings, models specifications and copies thereof, prepared and furnished by the Architect in connection with any project are instruments of professional service. As instruments of service they are the property of the Architect whether the work for which they were made may be executed or not, and are not to be reproduced or used on other work except with a written agreement with the Architect. This is in pursuance with the pertinent provisions of Republic Act No. 9266 (The Architecture Act of 2004), promulgated on March 17, 2004 and of R.A. No. 8293 otherwise known as the 1977 Intellectual Property Code of the Philippines.. 6.15 Cost Records During the progress of work, the Owner shall furnish the Architect two (2) copies of records of expenses being incurred on the construction. Upon completion of the Project, the Owner shall furnish the Architect two (2) copies of the summary of all cost of labor, services, materials, equipment, fixtures and all items used at and for the completion of the construction. 6.16 Design and Placement of Signs All signboards of the General Constructor, sub-constructors, jobbers and dealers that shall be placed at the Project site during the progress of construction shall be approved by the Architect as to size, design and contents. After the completion of the Project, the Owner or his building lessee shall consult the Architect for the design and size of all signboards, letterings, directories and display boards that will be placed on the exterior or public areas attached to the building, in order to safeguard the Owners interest that nothing will be installed inside or outside of the building that would compromise its safety and aesthetics. 6.17 Project Construction Cost (PCC) Project Construction Cost (PCC) as herein referred to, means the cost of the completed structure to the Owner including the structure, plumbing/sanitary and electrical fixtures, mechanical equipment, elevators, escalators, air-conditioning system, fire protection systems, alarm and clock system, communications and electronic system, elements attached to the building and all items indicated in the drawings designed by or specified by the Architect and his/her consultants. Other items if designed and planned by the Architect, such as architectural interior (AI) and site development (SD) elements and other items of similar nature are to be paid for separately by the Owner to the Architect as stipulated in Section 6.10 (Separate Services). The PCC does not include any of the fees for the Architect, the Engineer, the Specialist Consultants or the salaries of the construction inspectors. When labor or materials are furnished by the Owner below its market cost, the cost of the work shall be computed upon such current market cost. Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 203 : SPECIALIZED ARCHITECTURAL SERVICES (SAS) (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004) INTRODUCTION 1. Apart from the legal definition/s supplied under R.A. No. 9266, Architecture may also be defined as the blending of aesthetics, functions, space and materials resulting from the application of the technologies and skillsets of many different entities. Time and technology have moved to a level where specialized architectural services and allied architectural professionals are needed to complete, complement or supplement the necessary services for a building Project. Today, the plan/design professions, of which architecture has a primary part, are involved with a total commitment to improving the way we live. 2. The Architects main responsibility to the Owner is to produce a building that will house the activity it was intended for, that is well-planned, soundly constructed, aesthetically satisfying and within the financial limitation of the Project. 3. The Architects responsibility to society is to make sure that not the building alone but also its physical environment can enhance the lives of people by strictly adhering to international and state standards and prescriptions in regard to public health, safety and welfare. By engaging in the specialized architectural services guaranteed under several provisions of R.A. No. 9266, the Architect relates not only to purely plan/design and build professions but to the allied professions as well, to achieve totality in the building plan/design to be evolved. 4. The design of the building proper falls under the Architects Regular Services (SPP Document No. 202). 5. Plan/design services needed within and outside the building Project which require specializations by Architects fall under Specialized Architectural Services, listed under the pertinent provisions of R.A. No. 9266 and its 2004 IRR, foremost of which are:: a. Architectural Interiors (AI); and b. Site and Physical Planning (including Urban Design). 6. In the future, the specialist Architects involvement in providing high quality/value professional SAS services may eventually require securing a Certificate of Specialized Practice or a similar public instrument from the Professional Regulatory Board of Architecture (PRBoA) and/or the Professional Regulation Commission (PRC). 203-a. ARCHITECTURAL INTERIOR (AI) SERVICES 1. INTRODUCTION 1.1 In the plan/design of a building , the Architect works on a development concept. For the realization of this concept, the Architect builds his structure by making both the exterior and interior spaces contribute to the total development concept of the proposed building. The Architect plans, designs and develops the architectural interiors (AI) of buildings and residences such that they contribute to the physical, visual and intellectual/emotional comforts of the intended end-users. 2. EXPERTISE 2.1 Depending on the complexity of the Project, the Architect undertaking professional AI services must be sufficiently experience in the planning, design and detailing of AI elements. 3. SCOPE OF AI SERVICES 3.1 The Architect, upon designing a building, undertakes specific activities to control the spaces where these activities are to take place. The various spaces are designed to make the space fit the specific mood and the required activity. Due to the discovery of new plan/design techniques, building products and equipment, the AI has become a field of specialization for Architects. As such a specialist, the Architect offers the following services: a. Prescribes space plans, stacking plans and related computations for the different activities and spaces to be integrated in a building Project. b. Prepares furniture and equipment layouts for the proposed building and review/evaluation of specifications of AI components including all floor/wall/ceiling finishes, doors and partition systems, hardwares, modular or ready-assembled

furniture pieces/ systems, equipment, furnishings, fixtures, wayfinding and graphic devices including signage systems, etc. . b. c. Assists the Owner in conducting/ reviewing bids or negotiations with General Constructors, sub-constructors and suppliers of furniture, equipment, fixtures, etc. d. Prior to purchase by Owner and installation by the General Constructor or subconstructor, checks and approves samples of materials and shop drawings of AI components including all floor/wall/ceiling finishes, doors and partition systems, hardware, modular or ready-assembled furniture pieces/ systems, equipment, furnishings, fixtures, wayfinding and graphic devices including signage systems, etc. etc.. e. Conducts final inspection and approval of installed AI components and related items. 4. AI FEE 4.1 For Projects including extensive detailing of AI components such as custom floor/wall/ceiling construction and finishes, cabinet design, built-in components, equipment and special fittings, the Architect is paid nine percent (9.0%) of the cost of the AI work, specifically excluding engineering and other specialist services. The Recommended Professional Architural Fee (RPAF) for an Architects AI services may however vary from 7.2% to 12.0.0% of the Statement of the Probable Project Construction Cost (SPPCC), depending on the complexity of the AI works to be undertaken and depending on the capability and experience of the Architect. 4.2 The RPAF as stipulated above excludes the fee of any Engineering and/or Specialist Consultant/s working with the Architect. Should the Owner separately hire the services of the Engineers and/or Specialist Consultant/s, their professional fee shall be on the account of the Owner and paid directly by the Owner. In such a case, the Architects fee for coordinating the work and relating the work of the Engineers and/or Consultants to the design concept of the Architect will be an additional 3.0% of the cost of the AI work. 5. OTHER CONDITIONS ON ARCHITECTURAL INTERIOR (AI) SERVICES 5.1 The Architect with the appropriate specialization may undertake architectural interior (AI) services for a Project requiring architectural knowledge and skillsets. For Projects requiring interior design and/or furniture design), these should be done by an Architect with many years of continuous experience in AI services and who holds a valid and current registration certificate and PRC ID card as a Registered and Licensed Interior Designer (RLID) Under R.A. No. 8534 or its successor law. Such an Architect-RLID (or Architect-Interior Designer) should also possess the attendant administrative, technical and managerial ability. 2 Should other services be required by the Project, such as space planning and management studies/surveys, comparative analyses of furniture and systems, etc. should be performed by a duly-qualified Architect-Interior Designer acting as the prime state-regulated professional of the Project team. The costs for such services shall be for the account of the Owner. 203-b. SITE AND PHYSICAL PLANNING (SPP) SERVICES 1. INTRODUCTION When the Architect is commissioned to do physical planning for building sites such as Industrial Estates, Commercial, Institutional and Government/Civic Centers, Sports Complexes, Tourist Centers/ Tourism Estates/ Resorts, Amusement Parks, Educational Facilities, Residential and Housing Subdivisions and the like, the SPP services are as follows: a. Confers with the Owner on Project requirements and secures and/or generates a sufficient primary and secondary data base from which reliable projections and/or analyses can be made for translation to physical plans/designs. b. Examines laws, ordinances, rules and regulations affecting the Project. c. Prepares framework andconceptual master development plans (FRDPs and CMDPs) and report/s from relevant information gathered by other disciplines. d. Prepares preliminary through detailed master development plans (PMDPs/ DMDPs) showing the physical allocation of areas, roads and pedestrian access systems, basic utility layouts and building grounds, footprints, roofprints and/or building cast shadow projections and presents the same to the Owner, the Government and at public consultations as needed.. e. Prepares budgetary estimate of the cost of physical development covering the SPPCC for both the vertical and horizontal elements.

f.

Undertakes modifications, revisions and changes as may be required by the Owner and the Project within the engagement period. g. Prepares the finalized plans, reports and specifications needed for approval by the proper government agencies concerned. 2. SITE AND PHYSICAL PLANNING (SPP) SCHEDULE OF FEES 2.1 Type 1 2.1 The Physical Planning for building sites such as Industrial Estates, Commercial Centers, Sports Complexes, Resorts, Tourist Centers/Tourism Estates, Amusement Parks, Educational Facilities, Institutional and Government/Civic Centers, and Site Planning or Master Development Planning (MDP) of any complex consisting of such developments within a contiguous site. Basic RPAF rates for the maximum of five hectares (5.0 has.) for an Architect with PP Specialization Framework Development Plan (FRP) Conceptual Master Development Plan (CMDP) Preliminary Master Development Plan (PMDP) Detailed Master Development Plan (DMDP) P7,500.00* per hectare (ha.) RPAF Net to the Architect P10,500.00* per ha. RPAF Net to the Architect P14,500.00* per ha. RPAF Net to the Architect P18,500.00* per ha. RPAF Net to the Architect

* All References to fixed amount are based on the August 2009 purchasing value of the Philippine Peso. Adjustment of the RPAF for SPP services by an Architect with the requisite specialization shall be made at the time of the signing of the contract of service due to inflation and other factors. The RPAF rates for SPP services given above specifically exclude any form of architectural plan/design preparation. 2.2 Type 2 Subdivision Planning for residential and housing developments (under P.D. No. 957 and/or B.P. No. 220 and related laws) on properties within the Metropolitan Manila Area (MMA), large chartered cities, regional centers and provincial capitals. Basic RPAF rates for the maximum of three hectares (3.0 has.) for an Architect with PP Specialization Framework Development Plan (FRP) Conceptual Master Development Plan (CMDP) Preliminary Master Development Plan (PMDP) Detailed Master Development Plan (DMDP) P5,500.00* per hectare (ha.) RPAF Net to the Architect P7,500.00* per ha. RPAF Net to the Architect P12,500.00* per ha. RPAF Net to the Architect P16,500.00* per ha. RPAF Net to the Architect

2.3 Type 3 5.3 Subdivision Planning for residential and housing developments (under P.D. No. 957 and/or B.P. No. 220 and related laws) on properties located on other localities aside from those under Type 2.

Basic RPAF rates for the maximum of three hectares (3.0 has.) for an Architect with PP Specialization Framework Development Plan (FRP) Conceptual Master Development Plan (CMDP) Preliminary Master Development Plan (PMDP) Detailed Master Development Plan (DMDP) P3,500.00* per hectare (ha.) RPAF Net to the Architect P6,500.00* per ha. RPAF Net to the Architect P10,500.00* per ha. RPAF Net to the Architect P14,500.00* per ha. RPAF Net to the Architect

The RPAF rates above are based on the assumption that the land to be developed is moderately flat. If the land is rugged with rolling to steep terrain, the RPAF shall increased by twenty to thirty percent (20.0% - 30.0%). 3. OTHER CONDITIONS ON SITE AND PHYSICAL PLANNING (SPP) SERVICES 3.1 The Architect with the appropriate specialization may undertake the site and physical planning (SPP) of a Project requiring a composite arrangement of several buildings within a contiguous site of a moderate land area of a maximum of three to five (3.0 5.0) hectares (has.) depending on the type of development.. Any commission on the SPP a larger land area or of a more complex nature than Types 1 through 3 mentioned above, should be done by an Architect with several years of experience in SPP, has had additional and/or graduate/ post-graduate academic training in SPP and who holds a valid and current registration certificate and PRC ID card as a Registered and Licensed Environmnetal Planner (RLEnP) Under P.D. No. 1308 or its successor law. Such an Architect-RLEnP (or Architect-Planner) should most importantly possess administrative, technical and managerial ability aside from an equitable social commitment. 2 Should other services be required by the Project, such as environmental studies, feasibility study, market analysis, movement systems, impact analysis and others, said services should be performed by a duly-qualified Architect-Planner acting as the prime state-regulated professional of the Project planning team. 3 The cost for environmental studies/surveys, site investigation/s and titling of the parcels of land shall be for the account of the Owner. 4 The plan/design of buildings/structures and of landscaping elements is not part of SPP services. 5 For assistance in the preparation of detailed engineering (DE) drawings and specifications on roads, drainage, sewerage, power and communication system, additional RPAFranging from twenty to thirty percent (20.% - 30.0%) of the stated RPAF for Types 1 through 3 developments is to be charged for the Architects coordinative./ collaborative efforts. Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 204-a : FULLTIME SUPERVISION (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004)

1. INTRODUCTION 1.1 For the past 50 years in our country, the design and building construction process is undertaken by four principal members namely: a. The OWNER who orders for the implementation of a project; b. The ARCHITECT and his ENGINEER - CONSULTANTS who render design services and limited inspection work; c. The CONTRACTOR who performs the construction work; d. The individual or group of individuals who assist on the supervision and delivery of the work. 2. FULL-TIME SUPERVISION 2.1 Up to the early fifties when projects were manageable in size, the Architect was assisted by a construction inspector, traditio- nally called Clerk-of-Works. As projects become more complex, there is a need for a construction supervision group who will do the fulltime inspection at the jobsite. The Construction Supervision Group is normally recommended by the Architect based on their performance and hired by the Owner. He is responsible both to the Owner and the Architect. 3. FUNCTIONS The fundamental functions and primary responsibilities of the construction supervision group are: 3.1 Quality Control of Work He makes certain that the Contractor complies with the plans, specifications and called other contract documents and assures that workmanship is in accordance with sound and accepted construction practices. 3.2 Evaluation and Construction Work He assists the Architect and the Design Engineer in the evaluation of the work of the Contractor. 3.3 Keeping of Records, Reports and Contract Documents 4. DESCRIPTION OF TASKS 4.1 Quality Control a. Assist the Contractor in the interpretation of the Contract Documents. b. Obtain from the Architect additional details of information if, and when required at the jobsite for proper execution of the work. c. Conduct on-site observations and check the quality of the work, materials and equipment for consistency with the Contract Documents. d. Notify Contractor if any material or any portion of the work does not conform to specifications or if unacceptable in quality. Confirm these in writing. e. Follow-up and check daily on corrective work being undertaken. f. Check that materials are properly stored, handled, and used on the project. g. Inspect safety measures taken by the Contractor. h. Supervise/Perform sampling and testing of materials when necessary. Promptly report test results to those concerned. i. Check, in the company of Contractor and others concerned, testing of plumbing, electrical, air conditioning, mechanical and other installations. j. Disallow the installation of any material and equipment for which shop drawings have not been duly approved by the Architect. k. Forbid the use of materials, tools and equipment, or workmanship which do not conform with the plans and specifications. l. Require the removal or repair of defective or faulty construction; or of construction which could not be inspected in place; or the construction of a critical item, expressedly identified as such, and which was performed without inspection. m. Stop any work which is not being done in accordance with the plans and specifications and the Contract Agreement between the Owner and the Contractor. n. Before a project nears its completion stage, make a list of items for correction, and check each item as it is corrected before final inspection. 4.2 Evaluation a. Consider and evaluate suggestions or modifications which may be submitted by the Contractor to the Architect and report them with recommendations to the Architect for final decision.

b. Review and verify nature, quantities, and Contractors prices on change orders. c. Confirm, review and verify Emergency/Extra Work Orders claimed by the Contractor. d. Review with all concerned the requisitions for payment as submitted by the Contractor and forward them with recommendations to the Architect for disposition. e. Be alert to the various schedules of completion date and to conditions which may cause delay in completion, and report same to the Architect. When the construction work has been completed in accordance with the Contract Documents, advise the Architect that the work is ready for general inspection and acceptance. 4.3 Records a. Keep in the field office an orderly file of: Copy of the Contract Agreement Copy of Approved Plans and Specifications Copies of Building Permits and Licenses 4.4 Make daily Inspection Reports which include: a. Weather Conditions b. Manpower Availability and Distribution of Skills c. Construction Activities by Phase (Structural, Sanitary, Electrical, Mechanical, Architectural, etc.) d. Equipment Utilization e. Materials Delivered/Checked f. Correspondence/Memoranda Received g. Correspondence/Memoranda Transmitted h. Agreement/Decisions Made i. Official Visitors j. Observations/Recommendation 4.5 Keep in file the following documents: a. Progress and Accomplishment Reports b. Change Orders c. Payments Processed d. As-Built Drawings/Information e. Maintenance and Operation manuals of equipment certifications, guarantees, and the like for items furnished on the project. 5. OTHER FUNCTIONS OF THE CONSTRUCTION SUPERVISORY GROUP 5.1 Conduct regular coordination meetings with the Owner, the Architect-EngineerConsultant, the Contractor, and such other parties as may be required, or their designated representatives. 5.1 Attend conferences called by the Owner or the Architect/Engineer-Consultant. 5.2 Accompany the Owner, the Architect/Engineer-Consultant or their representative(s), and government inspectors during their visits to the project. 6. LIMITATION OF AUTHORITY 6.1 The Construction Supervision Group shall not enter into the field of responsibility of the Contractors project superintendent. 6.2 He shall not make decisions on matters that are the sole responsibility of the Architect and/or Design Engineer. 7. LEGAL RESPONSIBILITY 7.1 The Construction Supervision Group is responsible to the Owner on administrative matters. On technical matters he is responsible to the Architect and the Design Engineers. He does not have any legal responsibility as far as the present Civil Code is concerned. It is still the Architect and the Design Engineer who are responsible for their designs while the Contractor is responsible for his construction work. 8. QUALIFICATIONS 8.1 Full-Time Inspectors must be at least a college graduate who has a degree in Bachelor of Science in Architecture, Civil Engineering, Mechanical Engineering, Sanitary Engineer or Electrical Engineering. He must have some experience in designing and very knowledgeable in building materials and in construction. 9. COMPENSATION The Construction Supervision Group is usually recommended by the Architect and is paid by the Owner either on a salary basis or on an agreed flat rate per month. Overtime work is paid on a higher rate. 10. THE ARCHITECT AS FULL-TIME SUPERVISOR 10.1 When requested by the Owner, the Architect can also perform full-time supervisory services. As the Architect of the project, he is in a better position to interpret his drawings and documents for compliance by the Contractor. He can assign his staff to

undertake the full-time supervisory work and perform those works enumerated under articles 3, 4, and 5. 10.2 The services of the Architect as full-time supervisor can be compensated for by any of the following methods: a. Percentage Fee Method A fee of 1% to 1% of the Project Construction Cost. b. Multiple of Direct Personnel Expense Method (Refer to UAP Doc. 208) STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 204-b : CONSTRUCTION MANAGEMENT (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004) 1. INTRODUCTION 1.1 Due to the growing complexity of construction projects, there is a need to have a more effective cost control and faster project implementation scheme. The Construction Manager has emerged to fill this need in the construction industry. 1.2 The Construction Manager could be a member of the staff of the Owner or he could be an independent individual or firm hired by the Owner to manage the construction of a particular project. 2. FUNCTIONS 2.1 Coordination and Supervision a. Recommends the General Contractor and Specialty Trade Contractors that would work with the construction team. b. Coordinates and supervises all construction groups involved in the project. c. Approves methods and systems of construction. 2.2 Cost and Time Control a. Programming, planning and scheduling of all construction activities and sees to it that these are properly monitored during execution phase. b. Prepares Pert CMP and Cash Flow c. Reviews all Change Orders and Payments prior to approval of Owner. 2.3 Quality Control of Work and Keeping of Records The functions of the Construction Supervision Group become part of the responsibilities of the Construction Manager. (Refer to Doc. 204-A for complete functions of Construction Supervision Group). The Construction Manager may hire the Construction Supervision Group under his employ or it could be a separate group hired directly by the Owner but works under the control of the Construction Manager. 3. LIMITATION OF AUTHORITY 3.1 The Construction Manager shall not involve himself directly with the work of the Contractor such that it may be construed that he is relieving the Contractor of his responsibility as provided for in the Civil Code. 3.2 He shall not impose methods, systems or designs that will substantially affect the construction schedule and impair the design concept of the Architect. 3.3 He shall not interfere with the Architects design if such design generates the necessary environmental and aesthetic quality of the project. 4 LEGAL RESPONSIBILITY 4.1 The Construction Manager usually reports directly to the Owner and he is therefore responsible to the Owner on all aspects of the programming, coordination, quality control of the work and cost control. 4.2 However, he has no legal responsibility should the equipment fail to function as per design or should a portion of the building collapse. It is the Architect with his Design Engineers and the Contractor who are responsible by law for their designs and construction respectively. 5. QUALIFICATIONS 5.1 The Construction Manager may be an individual or a firm. 5.2 The individual or the principal of the firm must be a professional, preferably an Architect or Engineer, long experienced in the construction field and possessed with managerial talent and capabilities. 5.3 Those who were contractors or who have been in responsible charge of construction are usually capable of making the transition from Contractors to Construction Managers. 6. THE CONSTRUCTION MANAGER CONTRACT

6.1 Construction management contracts are professional service contracts normally negotiated between the Owner and the Construction Manager. A basic fixed fee of 1% to 3% of the estimated construction cost is the total compensation. The contract provides for reimbursement for the actual costs of certain designated services and general condition items. 7. OTHER CONSTRUCTION MANAGEMENT CONTRACTING CONCEPTS 7.1 To motivate the Construction Manager to reduce acquisition and operating costs, the services of the Construction Manager is compensated for by a range of incentive-type contracts and provisions. During the initial stages of acquisition, incentive type contracts are appropriate such as: a. Award Fee ProvisionsThe Construction Manager has the opportunity to obtain an award fee of specified maximum size if the measured cost-related values meet or exceed the specified target values. b. Price Adjustment ProvisionThe contract price is adjusted upward or downward in accordance with a prearranged formula. c. Operating and support cost factor provision provides a direct incentive on operating and support costs. 7.2 For the later stages of a project, contract types are used to encourage better construction management services. The preceding types of contracts for construction management services are used according to gross estimates and complexity of work. a. Firm Fixed Price The Owner will pay the Construction Manager a fixed fee. The fee will be unaffected by variations between the estimate and the bids or by change orders during the construction phase unless the Owner initiates an increase in scope. b. Fixed Price Incentive The Owner will pay the Construction Manager a fixed fee which is adjusted according to the difference between the final allowable costs and the target costs. c. Cost plus Incentive Fee (CPIF) or Cost plus Adjusted Fee (CPAF) Cost reimbursement type contracts will provisions for a fee that is adjusted by sharing formulas applied to the difference between the final allowable costs and the target costs. d. Cost Plus Fixed Fee The Owner will pay the construction management a fixed fee plus reimbursement of certain expenses incurred in the performance of basis services. 8. THE ARCHITECT AS THE CONSTRUCTION MANAGER 8.1 Trained in the coordination of various specialties, the Architect can also serve as the Construction Manager. He can easily supervise and make sure that all construction activities are properly monitored and followed and that all workmanship is of the quality desired with all costs incurred justified. Since construction management is not part of the regular services of the Architect, the services rendered by the Architect as a Construction Manager shall be compensated of separately.

MATRIX OF FUNCTIONS THE CONSTRUCTION TEAM 1. The Owner who orders for the implementation of a project; 2. The Architect and his Engineer-Consultants who render design services and limited inspection work; 3. The Contractor who performs the construction work; and 4. The individual or group of individuals called Clerk-of-Works, Resident Inspector or Works Engineer who is hired by the Owner to do full-time inspection work. He assists in the Construction Phase of the project and is responsible to the Architect on technical matters. 5. The individual or firm called the Construction Manager who assists on the supervision and delivery of the work. The Construction Manager may have a group of full-time inspectors in his staff or hire the necessary inspectors for the owner. The functions of the full-time inspectors are therefore included under the responsibility of the Construction Manager in this matrix.

FUNCTIONS

A. PRE-DESIGN PHASE A-1 Selection of prime professional Architect or Engineer A-2 Selection of Consultants A-3 Site Selection and Evaluation a. Utilities b. Transportation c. Cost d. Land-Use A-4 Feasibility Study a. Technical (definitive drawings and specifications) b. Socio-Economic c. Marketing d. Financial

*Owner might have acquired site already.

FUNCTIONS

e. Budgetary Estimate f. Programming & Scheduling A-5 Topographic Survey A-6 Soil Investigation A-7 Environmental Impact Study A-8 Design, Criteria, Applicable Codes & Regulations A-9 Clearances a. Human Settlements b. Subdivision Regulation Entity c.National Pollution Control Commission d. National Housing Authority e. Building Official A-10 Space & Functional Relationships B. DESIGN PHASE (Preparation of Contract Documents) B-1 Preliminary Design a. Outline Specifications b. Preliminary Estimate c. Presentation Drawings & Models B-2 Construction Documents a. Working Drawings b. Specifications c. General Conditions

FUNCTIONS

B-3 Procurement Specifications B-4 Bill of Materials B-5 Cost Estimates B-6 Approval of Contract Documents B-7 Authentication of Contract Documents (plans and specifications) C. BIDDING OR NEGOTIATION PHASE C-1 Selection of Const. Manager C-2 Selection of Gen. Contractor C-3 Selection of Specialty Trade Contractors C-4 Selection of Bids & Awards Committee C-5 Preparation of Bid Documents C-6 Distribution of Bid Documents C-7 Advertising C-8 Evaluation C-9 Awards of Contracts D. CONSTRUCTION PHASE D-1 Selection of Full-Time Inspectors D-2 Full-Time Inspection D-3 Part-Time Inspection D-4 Secure Building Permits & Licenses

* *

* Based on certain parameters to serve

only as guide on bidding

* *

*Recommendatory

*Recommendatory

FUNCTIONS

D-5 Payment of Building Permits & Licenses D-6 Provision of Temporary Filed Offices, & Utilities D-7 Pert CPM a. Preparation b. Review c. Approval D-8 Keeping of Field Records for the Owner a. Time Records b. Materials & Equipment c. Progress Reports d. Change Orders e. Payments f. As-Built Information g. Shop Drawings h. Filed Logbook i. Contract Documents j. Test Results k. Minutes of Meeting & Correspondences D-9 Request for Change Orders D-10 Issuance of Change Orders D-11 Evaluation of Change Orders D-12 Approval of Change Orders

FUNCTIONS

D-13 Progress Payments a. Billing b. Verification of Billing c. Certificate of Payment d. Payment D-14 Interpretation of Drawings, Specifications and Other Contract Documents D-15 Resolution of Conflict on Technical Matters Relative to Drawings, Specifications & Other Contract Documents D-16 Assist in Solving Construction Problems Caused by Unforeseen Contingencies & Exigencies D-17 Preparation of Shop Drawings D-18 Approval of Shop Drawings D-19 Quality Control a. Testing and Sampling of Materials at Site or Factory b. Inspection of Structural System c. Inspection of Mechanical System d. Inspection of Electrical System e. Inspection of Sanitary/ Plumbing System f. Inspection of Architectural Works & Finishes g. Inspection of Civil Works h. Overall Field Coordination

FUNCTIONS

D-20 Approval of Samples of Finishing Materials D-21 Coordination of Works of Various Contractors & Specialty Trade Contractors D-22 Adherence to Approved Schedule a. Equipment b. Labor c. Material/Deliveries D-23 Cost Control a. Cash Flow b. Purchasing of Materials/ Equipment/Services c. Value-Engineering d. Cost Records D-24 Safety Measures a. Preparation of Requirements b. Implementations c. Inspection D-25 Testing of Systems a. Sanitary/Plumbing b. Electrical c. Mechanical & Other Equipment d. Other Auxiliary Systems D-26 Substantial Completion a. Inspection b. Preparation of Check, List of Uncompleted Work and/or Defective Work

FUNCTIONS

D-27 Completion a. Preparation of Request for Final Inspection b. Certification from Government Agencies - Certificate of Occupancy - Certificate of Final Inspection of Electrical, Sanitary and Mechanical c. Certificate of Complete Payment of Contractors Labor, Materials and Equipment d. Preparation of As-Built Drawings e. Verification of As-Built Drawings f. Issuance of Operating Manuals g. Main Utility Connection h. Filing of report and Guarantee Bond i. Certificate of Final Payment - Verification of Billing - Issuance of Certificate - Acceptance - Payment E. POST-CONSTRUCTION PHASE E-1 Maintenance E-2 Issuance of Maintenance Guidelines & Operating Instructions E-3 Correction Measures on Deficiencies E-4 Start-Up of Plant Equipment & Correction Adjustment E-5 Final Report

LIMITATION OF AUTHORITY OF THE CONSTRUCTION SUPERVISORY GROUP AND THE CONSTRUCTION MANAGER 1. He shall not enter into the field of responsibility of the contractors project superintendent. 2. He shall not make decisions on matters that are the sole responsibility of the Architect and/or Design Engineer. Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 205 : POST-CONSTRUCTION SERVICES (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004) 1. INTRODUCTION

1.1. Building administration and management goes beyond maintenance and janitorial functions. It requires a complex professional who can perform a wide range or functions for the efficient and economical operation and maintenance of a building, facility or a complex. 1.2. In Post-Construction services, the channels of communication are kept open among the building owners, operators, architects, engineers, builders, manufacturers, building research groups, utility providers, equipment vendors and building administrators / property managers to provide access to information regarding the performance and upkeep of buildings. 1.3. The Architect may be engaged as the building administrator and/or property manager of a commercial, industrial, residential or institutional building, facility or complex to maximize the lifespan of the building in order to produce maximum economic returns. 2. SCOPE OF SERVICES 2.1. Building and Facilities Administration 2.1.1. 2.1.2. 2.1.3. 2.1.4. Building Maintenance. Ground and Landscaping Supervision Building Equipment Maintenance Business Development and Management

2.2. Post-Construction Evaluation

3. MANNER OF PROVIDING SERVICES 3.1. Building and Facilities Administration 3.1.1. Building Maintenance. The Architect shall: a. See to it that the building and all the parts thereof (structure, plumbing, electrical, partitions, finishes, etc.) are all in good condition b. Formulate and enforce rules for the proper use of the building and facility. c. Monitor security services, and d. Monitor maintenance and janitorial services (cleanliness of corridors, lobbies, stairs and other common areas, exits, parking areas, garbage collection)

3.1.2. Ground and Landscaping Supervision. The Architect shall: a. Supervise landscape contractors and gardeners for proper watering, pruning, trimming and maintenance of the landscape b. Maintain orderly entrances, exits and parking areas, and c. Maintain roads, walkways, and ramps

3.1.3. Building Equipment Maintenance. The Architect shall: a. Assist the proper third parties in seeing to it that all equipment (air-conditioning, sprinkler system, generators, transformers, telecommunications equipment, etc.) are properly maintained and in good working condition 3.1.4. Business Development and Management. The Architect shall a. Innovate schemes to attain maximum building occupancy b. Bill the tenants for rentals and utilities (electricity, water, telephone, cable, gas and other related dues) 3.2. Post-Construction Evaluation 3.2.1. Upon the request of the Owner, the Architect shall: a. Evaluate the initial design program vs. the actual use of the facility b. Determine the effectiveness of the various building systems and the materials systems in use c. Assist the proper third parties in evaluating the functional effectiveness of the design and construction process undertaken, and d. Study, research, and give solutions to any defects and failures such as shrinkage, water seepage and other problems in the building. This is referred to as forensic investigation of the buildings structural system 4. METHOD OF COMPENSATION 4.1. Percentage of gross rentals, maintenance and security fees 4.2. Monthly salary fee

Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 206 : COMPREHENSIVE ARCHITECTURAL SERVICES (CAS) (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004)

1. INTRODUCTION 1.1 The concept of Comprehensive Architectural Services (CAS) crystallized through the years in response to the demands of todays complex building projects. The transition of the architectural profession from providing basic and additional services to a comprehensive nature is due to the fact that a continuity of services related to planning, design and construction is necessary for the execution of a completely viable Project. 1.2 Comprehensive Architectural Services (CAS) is a range of state-regulated professional services that covers Pre-Design Services, Specialized Architectural Services, Construction Services and Post-Construction Services. 1.3 In this extended dimension, the Architect is the prime professional. He functions as creator, coordinator and author of the building plan/design with which a Project will be constructed. To perform such a role, the Architects have to be knowledgeable in a number of fields in addition to those that are concerned mainly with building plan/design for him/her to properly assist and serve the Owner. 1.4 It is not expected that the Architect will actually perform all the services. Rather, he is to act as the agent of the Owner in procuring and coordinating the necessary services required by a Project. 2. SCOPE OF COMPREHENSIVE ARCHITECTURAL SERVICES 1.1 Pre-Design Services (SPP Document No. 201) a. Economic Feasibility b. Project Packaging/Financing c. Architectural/Space Programming d. Site Selection and Analysis e. Site Utilization and Land Use Study f. Promotional Services g. Space/Management Study 2.2 Design Services: Regular Architectural Services (SPP Document No. 202) a. Schematic Design (concept-level), Design Development (Preliminary Design) and Detailed Design and Contract Documentation b. Working Drawings c. Specifications and Other Contract Documents d. Part-Time Construction Supervision (PCS) 2.3 Specialized Architectural Services (SPP Document No. 203) a. Architectural Interior (AI) b. Site and Physical Planning (SPP) 2.4 Construction Services (SPP Document No. 204) a. Full-Time Construction Supervision (FCS) b. Construction Management (CM) 2.5 Post-Construction Services (SPP Document No. 205) a. Building and Equipment Maintenance b. Building Administration 3. COMPREHENSIVE ARCHITECTURAL SERVICES (CAS) 3.1 Project Management for Services (PMS) When the Owner hires an Architect or a firm to coordinate the whole range of Comprehensive Architectural Services (CAS) for a Project, this constitutes Project Management for Services (PMS). 3.2 Project Management for Services (PMS) is therefore that group of a management activities over and above normal architectural services carried out during the pre-design, design and construction phases, that contribute to the control of time, cost and quality of construction of a Project. It is a procedure by which an Owner, desiring to embark on a project of unusual scope and complexity, engages a professional management service to provide technical consultations during the conceptual and design stages of a Project and also to provide for

organizing and directing consultation activities, including purchasing, supervision, inspection and acceptance. 3.3 It is the intention and the practice of project management not to impinge or relieve the designers and constructors of their respective normal duties and responsibilities in the design and construction of the Project. Project Management for Services (PMS) is supposed to augment, supplement and be complimentary to the functions of Architects, Engineers, Construction Manager (CM) and General Constructors in meeting the broad and complex requirements of usual projects. 4. THE PROJECT MANAGER FOR SERVICES (PMS) 4.1 Basic Functions In the Team Concept of construction, the Project Manager for Services or PCM (an individual or a firm) operates as a member of an Owner-Architect-Engineer-CMConstructor Team. In the Team Approach, each member of the team will have precedence and exercise leadership in his own sphere of operations or expertise. In accordance with this principle, the Architect and the other Consultants will have prime responsibility for the planning and design of the Project. b. The General Constructor shall be responsible for his men and equipment and the delivery of the Project as per the construction contract. The Owners role (as assisted by the PMS and/or by another entity internal to the Owners organization/constitution is to make decisions on the Project and to assure that funds are available to complete the Project within the budgeted estimates. c. The PMSs role is to plan, program and monitor the various activities, and act as an adviser on material costs and construction methods. His primary responsibility, therefore, is the exercise of overall cost control (assisted by the CM). It relieves the Owner of many of the anxieties that usually beset him/her/them, particularly those concerned with forecasting costs and completion dates. 4.2 Detailed Functions a. Pre-Construction Phase As early as practicable during design development, perhaps, concurrently with the Architects commission, the PMS should enter regular consultation with Architects and Engineers (A&E), the CM and with the Owner on all aspects of planning, design and implementation for the Project. Pre-bid management service might include, but not necessarily encompass all of or be limited to the following: a-1 PMS to advise Owner and the Architect on practical consequences of their decisions and plan/design options. Review A&E plans/designs, drawings and specifications for the purpose of advising on site conditions, appropriate materials alternatives, construction feasibility of various systems and the possible plan/design and cost implications of local availability of materials and labor. a-2 Prepare periodic cost evaluations and estimates related to both the overall budget and to the preliminary allocations of budget to the various systems. These cost estimates will be successively revised and refined as working drawings for each system are developed. The PMS (assisted by the CM) will advise the A&E Consultants and the Owner whenever the refined estimates shows the probability of exceeding the budget allocation, or whenever the construction time required for a given system is likely to prolong or delay completion schedule. a-3 Recommend for early purchase (by the Owner) of thespecified items of equipment and materials that require a long lead time for procurement and delivery and expedite purchases in general. a-4 Advise on the pre-packaging of bid/tender documents for the awarding of separate construction contracts/subcontracts for the various systems and trades. This will include the giving of advice on the sequence of document preparation to facilitate the phased construction work after completion of the contract documents and award of the construction contract. a-5 Consider the type and scope of work represented by each bid package in relation to time required for performance, availability of labor and materials, community relations and participate in the schedule of both plan/design and construction procedures. a-6 As construction progresses, the PMS may, with the cooperation of the A&E Consultant and the CM, work on an overall network schedulee.g. PERTCPM. a-7 Check bid packages, drawings and specifications to eliminate overlapping of jurisdictions among the various constructors. a-8 Review all contract documents to be sure that an entity is responsible for general requirements on the site and for temporary facilities. The PMS

should ascertain that specifications for such facilities and furnishings are adequate for the intended operation. Sometimes the general requirements are a separate contract under which temporary site buildings, general guardrails, some items of machinery, access and security measures are taken care of, either by a separate constructor or one of the entities doing other parts of the work. As early as possible, the PMS should set up a checklist of such general requirements to be sure that someone is responsible for each concern. a-9 Conduct pre-bid conferences among Constructors and manufacturers of systems and sub-systems to be sure that all bidders understand the components of the bid/tender documents and the management techniques that will be applied, including any computerized interfaces, network scheduling and cash flow controls. a-10 Review stipulations of the Owner with the bidders regarding the Project management personnel, services control authorities, insurance, bonding, liability and other aspects and requirements of the Project. a. Construction Phase The PMS (in collaboration with the CM) reviews all bids for compliance with stipulated conditions. The PMS also makes recommendations for awards and may, with the concurrence of the A&E Consultants, CM and Owner enter into the pre-qualifying and actual awarding process. On a phased construction project, the PMS (with the CM) will coordinate the awards with the planning schedule and provide the following services: b-1 Manage the general coordination and scheduling of work. b-2 Maintain his/her own supervisory and inspection staff at the jobsite as well as conducting factory inspections as required. b-3 Observe work in progress to assure compliance with drawings and specifications. b-4 Confer with Architects and Engineers when clarification or interpretation of the documents becomes necessary. b-5 Obtain and transmit in writing to all concerned any contract interpretations where any possible dispute may arise. b-6 Set up on-site lines of authority and communication to be sure progress of work of all Constractors is unimpeded and that the intent of the Architects and Engineers is accurately fulfilled. b-7 Set up assurances, perhaps in the form of organization charts, showing the project administrator exactly what on-site personnel and organization channels are provided and see that no changes are made without the written approval of the administrator. b-8 Establish procedures or coordination among the administrator, architects, engineers, separate constructors and the construction management (CM) organization. b-9 Conduct such conferences among successful bidders as may be necessary to maintain schedule and clarify any matter in dispute. b-10 Revise and refine estimates as construction proceeds and as required to incorporate approved changes as they occur. Monitor estimates and changes to be sure that neither the schedule nor the budget is in danger of being exceeded. b-11 Establish procedures for processing shop drawings, catalogs, and samples, the scheduling of material requirements, and prompt cash flow as job phases are completed. b-12 See that each constructors labor and equipment are adequate for the work and the schedule. b-13 Be aware of safety programs developed by each separate constructor and specially those safety provisions for the overall job as provided by the general requirements constructor. (The PMS should be sure that this attention to safety provisions does not relieve the separate constructors of their responsibilities or liabilities for safety or property damaged). b-14 Assist the Owner and the various Constructors in the development and administration of an overall labor relations program for the Project. b-15 Update and keep current the PERT CPM or other computerized overall control and be sure that all parties with the need to know are informed. b-16 Maintain records at the jobsite and elsewhere including, but not limited to, records of all contracts, shop drawings, samples, purchases, subcontracts, materials, equipment, applicable codes and standards, etc. These records are to be available to the A&E Consultants and Owner and may become property of the Owner at the time of final payment.

b-17 Maintain cost accounting records of all job components including separate accounting of the consequences of any change order and its effect of the schedule. b-18 Keep accurate progress reports during all stages of construction. b-19 Review and process all applications for progress payments. b-20 Review all requests for changes and submit recommendations to the A&E Consultants and the Owner. b-21 Implement any special Owner requirements regarding processing forms or job conditions. b-22 Be prepared to supply documentation required in the handling of claims or disputes (and be sure the cost of preparing any such submission is covered one way or another in the construction management agreement). b-23 Advise Owner to obtain from qualified surveyors such as certified records of site conditions, elevations, floor levels, etc., as may be required. b-24 Insure that Constructors maintain a current set of records working drawings and specifications. b-25 Set up a joint inspection of the entire Project at some specified interval prior to completion, the inspection to be made by the PMS with the Owner, the A&E Consultants, CM, the General Constructor and other interested parties. This inspection and the final inspection should be followed by decisions on the part of all concerned as to the most economical and/or expeditious ways of handling a punch list of incomplete and/or faulty installations 4.3 Note that the PMSs Service Agreement should stipulate that none of his inspection work will relieve any Constructor of his responsibility to provide acceptable materials or to properly perform the work in accordance with the drawings and specifications. Until such time as the lines of liability are more clearly defined, no part of the PMSs function should be construed as providing direct supervision or instruction of the work or methods of the Constructor. 5. LIMITATION OF AUTHORITY 5.1 The limitation of authority of the Project Manager for Services (PMS) is similar to that of the Construction Manager (CM). a. The PMS shall not involve himself/herself directly with the work of the Constructor such that it may be construed that he is relieving the Constructor of his responsibility as provided for in the Civil Code, specifically Art. 1723. b. The PMS shall not impose methods, systems or designs that will substantially affect the construction schedule and impair the design concept of the A&E Consultants. c. The PMS shall not interfere with the A&E Consultants plan/design, particularly if such plans/designs generate the necessary environmental and aesthetic quality of the Project. The PMS shall provide the necessary management support by applying his leadership and showing respect for co-professionals to be more effective participants in the Project Team. 6. CIVIL LIABILITY AND PROFESSIONAL RESPONSIBILITY 6.1 Based on the Civil Code, the PMS has no specifically defined civil liability insofar as plan/design preparation and construction is concerned. It is still the A&E Consultants who are responsible for the plan/design; while the General Constructor is solely responsible for the construction.While the Construction Manager (CM) may also not have a stated civil responsibility under Art. 1723 of the Civil Code, such responsibilities may be prescribed in detail under the CM service Agreement. It is for the foregoing reason why the CM and the PMS are not allowed to interfere in the field of design and construction as this may be construed as relieving the designers and the Constructors of their liabilities as provided under law. The PMS and the CM are however not exempt from their professional responsibilities under their respective professional regulatory laws (PRLs). If seriously flawed services or incompetencies are evident, the PCM and the CM can be charged at the Professional Regulation Commission (PRC) for which their certificates and PRC ID cards can be suspended or revoked after due process. 7. MANNER OF PROVIDING CAS 7.1 Normally, the Architect enters into a contract with the Owner to perform comprehensive architectural services (CAS). By the very nature of the CAS, the PMS assumes the role of the overall coordinator whose functions are outlined in Section 4 of this document. 7.2 To perform the variety of services indicated in the CAS, the Architect must make full use of his own capability as well as the services offered by other state-regulated professionals. The

PMS may expand his staff by hiring the experts needed or form a professional team consisting of the following: a. Architects b. Engineers c. Market Analyst d. Accountants e. General Constructors f. Registered and Licensed Real Estate Service Professionals (RLRESP) or Consultants g. Sociologists h. Registered and Licensed Environmental Planners (RLEnPs) I. Bankers j. Lawyers, etc. 7.3 If a PMS is hired by the Owner, it is the responsibility of the PMS to hire the Construction Manager (CM) either to be paid by the PMS or by the Owner on a salary or percentage basis of construction cost. In the same manner, the Full-Time Construction Supervisor (FCS) will either be with the staff of the PMS or hired by the Owner. 8. METHOD OF COMPENSATION 8.1 The Project Manager for Services (PMS) is compensated on a percentage basis of 2.0% to 5.0% of estimated Project Cost. 8.2 If the Architect as PMS performs Regular Architectural services for the same Project, he is compensated separately for these services as stipulated in SPP Document No. 202 or under the other applicable SPP Documents in case of other services. Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 207 : DESIGN-BUILD SERVICES (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004) 1. INTRODUCTION 1.1. In any building project, there is an intricate balance between time, quality and cost. The Architect may enter into a Design-Build Services agreement with his Client with the ultimate goal of delivering projects within the shortest possible time, with the lowest possible cost and at an acceptable standard of quality and performance. 1.2. Before entering into a Design-Build Service Agreement, the Architect will have to acquire additional training in construction supervision, project and financial management and gain practical knowledge and experience in construction. This will develop his expertise to implement the entire project from plan/design preparation through construction with maximum optimization 1.3. For certain modes of practice which go beyond the Regular Architects Services, additional legal requirements must be met. 2. SCOPE OF WORK The Architect enters into Contract with the Owner accepting full responsibility for both design and construction or supervision but with a clearly delineated and defined scope of work. In order to protect his professional license, the Architect will have to prepare separate contracts for the design and the construction components. Both contracts should provide an arbitration clause and other alternative measures to resolve possible disputes.

2.1. The Architect undertakes the following stages of the Regular Design Services: (Refer to Doc. 202 Regular Architects Services) 2.1.1. Schematic Design Phase 2.1.2. Design Development Phase 2.1.3. Contract Document Phase 2.2. The scope of work during the Construction Phase is no longer limited to regular coordination, periodic inspection, and assessment as part of the Regular Design Services. It now extends to construction supervision and/or undertaking the actual construction. 3. DUAL ROLE OF THE ARCHITECT 3.1. The Architect - of record (Aor) 3.1.1. The Architect is directly and professionally responsible for the total design of the project and assumes the attendant professional responsibility and civil liability for the plans, specifications and contract documents signed and sealed. (Art.1, Sec. 3.2.a of RA 9266)

3.2. The Architect in charge of construction (Aicc) 3.2.1. The Architect is directly and professionally responsible and liable for the construction supervision of the project. (Art.1, Sec. 3.2.b of RA 9266) ; or 3.2.2. The Architect is directly and professionally responsible and liable for the management and actual construction of the project. However, since RA 9266 does not classify construction as integral to the practice of Architecture, the Architect must secure a contractors license from DTICIAP-PCAB (Department of Trade & Industry Construction Industry Authority of the Philippines - Philippine Construction Accreditation Board), to be renewed on an annual basis. 4. MANNER OF PROVIDING SERVICES 4.1. Design Build by Administration 4.1.1. The ( will add more discussion here) a. b. The The

4.1.2. The Architects fee for Regular Architects services shall be in accordance with UAP Doc. 201 of the Architects Standards of Professional Practice. 4.2. Design - Construct 4.2.1. The a. b. The The

4.2.2. When the Architect undertakes the actual construction, he submits a proposal similar to a contractors bid. 5. METHOD OF COMPENSATION The Project Cost includes the cost of labor and/or materials, overhead costs, plus mark-up and profits, similar to a regular construction bid price. Segregating professional fees instead of consolidating them into a lump sum amount will be advantageous to both the Architect and the Client since it provides a clear basis for adjustment in case of changes in the scope of work. 5.1. Percentage of Construction Cost

5.1.1. This is the simplest and most widely used method of compensation because it is directly proportionate to the size and cost of the project. In case of changes, whether addition or deductions, there is no need to amend or supplement the Owner Architect Agreement. 5.2. Direct Personal Expenses x Multiplier. 5.2.1. This method may be applied only to construction supervision since it is based on technical hours spent on a project and does not measure the value of creative design. 5.2.2. The following parameters have to be agreed upon at the start of the project: a. Rate/hr (R) Rate per hour of the Architect, Consultant, and Technical staff : RA, RC, RT b. Man hours (H) Number of hours spent by the Architect, Consultants and Technical staff : HA, HC, HT c. Multiplier (M) - Factor which accounts for overhead and profit. Depending on the complexity of the project, experience of the Architect and the office set-up, this may range from 1.5 to 2.5. d. Reimbursable Expenses (E) Items to be charged to the Client and reimbursed to the Architect which include the following: i. Transportation, housing and living allowance of Consultant; ii. Transportation, per diem, housing and living allowance of local consultants and technical staff if assigned to place over 100 km from area of operation of Architect; iii. Cost of printing of extra sets of drawings, reports, maps, contract documents, etc., over the five (5) sets submitted to the Client; iv. Overseas and long distance calls; v. Technical and laboratory tests; vi. Licenses, fees, taxes needed for the project (other than contractors license) 5.2.3. The Total Cost of Service charged to the Client is as follows: {(RHA + RHC + RHT) x M} + E 5.3. Professional Fee Plus Expenses. This method is best used when there is a continuous relationship involving a series of projects. The fee is a fixed amount + reimbursement for the Architects technical time and overhead. An agreement on the general scope of work is necessary in order to set an equitable fee. 5.4. Lump Sum or Fixed Fee. In government projects, having a fixed fee eliminates paper work and time consuming processes particularly in the processing and approval of supplementary works by the auditing agency.

5.5. Per Diem plus Reimbursable Expense The Architect may be paid on a per diem basis plus reimbursable expenses such as travel, accommodation and living expenses when the Client requests the Architect to do work such as:

5.5.1. Attending board meetings or conferences 5.5.2. Conducting ocular inspection for site selection 5.5.3. Conferring with others regarding prospective investments and similar ventures 5.6. Mixed Methods of Compensation A combination of any of the methods may be applied

6. ADVANTAGES OF THE DESIGN BUILD SERVICES APPROACH 6.1. 6.2. 6.3. 6.4. 6.5. Gives the Client the option to deal with just one professional/entity Gives the Client options to avail of unique financial schemes Defines accountability Allows better coordination among professionals working in collaboration Allows construction to commence while design is still in progress (fast track) instead of following the conventional design-bid-construct process, 6.6. Compressed or accelerated project schedule translates to cost savings 6.7. Applies to both conventional and non-traditional projects, ranging from simple to complex projects. Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.
Member

STANDARD OF PROFESSIONAL PRACTICE (SPP) Document No. 208 : SELECTION OF THE ARCHITECT (Part of IRR of R.A. No. 9266 - The Architecture Act of 2004) 7. INTRODUCTION 7.1. There are many ways by which a Client can engage the services of an Architect. The most appropriate method of selecting an Architect will depend on the type and complexity of the project. 7.2. < note: Is there any other item which has to be discussed here?> 8. METHODS OF SELECTION 8.1. Direct Selection is used when undertaking a relatively small project. The Client selects his Architect on the basis of: 8.1.1. Reputation 8.1.2. Personal acquaintance or recommendation of a friend 8.1.3. Recommendation of a former client 8.1.4. Recommendation of another Architect 8.2. Comparative Selection is employed by committees representing institutions, corporations or public agencies. The selection process involves: 8.2.1.Invitation. The client issues an invitation with the Terms of Reference for the project. The selection committee established by the Client may consist of representatives from other state-regulated professions and/or the construction industry, as well as persons with related expertise. 8.2.2.Pre-qualification. Architectural firms submit information regarding their qualification and expertise. 8.2.3.Interview. The Architect explains his methodology in translating the design requirements of the proposed project. 8.2.4.Verification. The selection committee may visit buildings designed by the Architects and check references such as former clients and financial institutions 8.2.5.Evaluation & Ranking. The selection committee may adopt its own procedure in evaluating the entries and recommending the most capable firm.. 8.2.6.Negotiation. The Architect explains to the Client the Scope of Services and the Minimum Basic Fee as prescribed by the Architects Standard of Professional Practice 8.3. Architectural Design Competition is used for civic or monumental projects. Various architectural firms submit solutions to a particular design problem and are judged on the basis of comparative excellence. The winning firm is commissioned to undertake the detailed design of the actual project. 8.3.1. Advantages a. Opportunities will be open to all PRC-registered Architectural Firms

b.

The Client will have a wider range of options

8.3.2. Disadvantages a. Process may be expensive and time consuming

b. The time and effort required may discourage qualified firms from participating. c. Unscrupulous clients will seek free services under the guise of competition 2.3.1.Procedure. Competitions should be conducted: a. With the assistance of the UAP-IAPOA or one of its local chapters, and b. In accordance with the guidelines set forth by the UAP Document 209 (National Competition Code) 2.3.2. Participants a. Sponsor or Client A natural or juridical person

b. Competitors Registered and Licensed Filipino Architects (RLA), UAP IAPOA members in good standing. A foreign contestant must be registered in his/her country of origin and must secure a Temporary Special Permit from the Professional Regulation Commission (PRC) and must work in collaboration with a local counterpart RLA who will assume Civil Liabilities. c. Professional Adviser Registered and Licensed Architects (RLA), UAP IAPOA members in good standing d. Jury Composed of five (5) members who are known for their integrity, objectivity, impartiality and honesty. o Architect bona fide member of the UAP-IAPOA o Architect fellow UAP o Architect member of the Academe and a bona fide member of the UAP-IAPOA o An Industry partner o (note who is the 5th ?) 3. MANNER OF PROVIDING SERVICES This will be in accordance with the type of project. 4. METHOD OF COMPENSATION This will be covered by the respective type of services. Approved in the City of Manila this 23rd day of October 2009. Professional Regulatory Board of Architecture (PRBoA) Original Signed

ARMANDO N. ALL
Chairman Original Signed Original Signed

ANGELINE T. CHUA CHIACO SEGOVIA

MARIETTA B.

Member

Member